Construction Addendum & Completion Schedule Sample Clauses

Construction Addendum & Completion Schedule. After receipt of final unappealable award by the State of Kansas of the Lottery Gaming Facility Management Contract to Pinnacle and receipt of final plan approval from the Unified Government, Pinnacle and the Unified Government will agree upon a construction addendum to this agreement which will provide specific on-site and off-site infrastructure improvements to be constructed by Pinnacle and a schedule for the completion of such improvements (“Construction Addendum”).
Sample 1
AutoNDA by SimpleDocs
Construction Addendum & Completion Schedule. Further Study. After the Effecive Date of the Gaming Facility Contract, Entertainment and the Unified Government will agree upon a construction addendum to this Agreement which will provide specific on site and off site infrastructure improvements to be constructed, the timing of such construction, payment by Entertainment of all costs, and a schedule for the completion of the first phase of the Project. Within three (3) years after Project Completion, Entertainment, at its cost, shall cause an updated traffic study (the “Updated Study”) to be prepared to update the BWR. Study. The Updated Study shall be prepared by an engineer selected by Entertainment, provided that the Unified Government consents to such selection (such consent shall not be unreasonably withheld, conditioned or delayed). In the event that the Updated Study identifies additional off-site infrastructure improvements that are necessary as the direct result of impacts created by the Project after Project Completion (“Additional Improvements”), then Entertainment and the Unified Government shall negotiate in good faith to reach agreement on what Additional Improvements, if any, shall be funded by Entertainment. If Entertainment and the Unified Government are unable to reach agreement on what Additional Improvements shall be funded by Entertainment after such good faith negotiations, then such disagreement shall be submitted to binding arbitration administered by the American Arbitration Association (the “AAA”) by a single arbitrator selected by the AAA, (with the fees and expenses of such arbitrator shared equally by the Unified Government and Entertainment), provided that the total sum of all Additional Improvements that Entertainment may be obligated to fund shall not exceed One Million and no/100 Dollars ($1,000,000.00).
Sample 1

Related to Construction Addendum & Completion Schedule

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.

  • Work Schedule (A) Where an employee has an established schedule, a change in workdays or shifts will be posted no less than 14 calendar days in advance and will reflect at least a two workweek schedule; however, the state will make a good faith effort to reflect a one month schedule. (B) In the event of a declared emergency the notice requirement of this Section may be void. (C) The state will continue to observe the scheduling structures currently in place at each agency and agrees to bargain any change in the overall practice of how schedules are established.

  • Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Project Description In two or three brief sentences, provide a concise description of your exhibition. Include the subject matter, type of objects to be included (paintings, sculpture, manuscripts, etc.), those responsible for organizing the exhibition, and catalogue author(s).

  • Construction Documents Phase Bidding or Negotiation Phase:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!