CONSTRUCTION CONTRACTS ACT 2002. 6.1 The Company shall be entitled to exercise all or any powers available to the Company under the Construction Contracts Act 2002 including suspension of work, adjudication and seeking charging orders.
Appears in 7 contracts
Samples: www.ester.co.nz, find.nztradegroup.co.nz, find.nztradegroup.co.nz
CONSTRUCTION CONTRACTS ACT 2002. 6.1 The Company shall be entitled to exercise all or any powers available to the Company under the Construction Contracts Act 2002 including suspension of work, adjudication and seeking charging orders.
Appears in 1 contract
Samples: www.sselectrical.kiwi.nz
