Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.
Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.
Lease Extension Lessee may request Lessor to extend the original Scheduled Expiration Date of each Lease Agreement for an additional period of three (3) years by appropriately completing, executing and delivering to Agent a written request in the form of Exhibit G(2), together with an attachment thereto setting forth the terms upon which Lessee would propose for the requested extension (a "Lease Extension Request"). Lessee shall deliver each Lease Extension Request to Agent not more than twelve (12) months and not less than nine (9) months before the original Scheduled Expiration Date. Agent shall promptly deliver to Lessor and each Participant three (3) copies of each Lease Extension Request received by Agent. If Lessor or a Participant, in its sole and absolute discretion, consents to a Lease Extension Request, such Person shall evidence such consent by executing and returning two (2) copies of such Lease Extension Request to Agent not later than the last Business Day which is not less than seven (7) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement. Any failure by Lessor or any Participant so to execute and return a Lease Extension Request shall be deemed a denial thereof. If Lessee shall deliver a Lease Extension Request to Lessor pursuant to the first sentence of this Subparagraph 2.09(b), then not later than the last Business Day which is not less than six (6) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement, Agent shall notify Lessee, Lessor and the Participants in writing whether (i) Agent has received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case the definition of "Scheduled Expiration Date" set forth in Subparagraph 2.02(a) of the applicable Lease Agreement shall be deemed extended to the date which is three (3) years after the original Scheduled Expiration Date (subject to the receipt by Agent of any amounts payable by Lessee in connection with such extension), or (ii) Agent has not received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case such Lease Extension Request shall be deemed denied. Lessee acknowledges that neither Lessor nor any Participant has promised (either expressly or implicitly), or has any obligation or commitment, to extend or consent to the extension of the Scheduled Expiration Date for either Lease Agreement at any time.
Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.
Due Date Extension If any payment of principal or Yield with respect to any Advance falls due on a day which is not a Business Day, then such due date shall be extended to the next following Business Day, and additional Yield shall accrue and be payable for the period of such extension at the rate applicable to such Advance.
Contract Term Extension “Contract Term Extension” means an extension of the term of this contract, at the request of Purchaser, under this Subsection. This Subsection does not obligate Contracting Officer to grant Contract Term Extension.
Listing Period Extension The Commission shall be due if the Property is sold, conveyed, exchanged, optioned, or otherwise transferred within _ _ days (“Extension Period”) after the expiration of the Listing Period to anyone with whom the Broker or Agency has negotiated unless the Property is listed, in good faith, with another real estate agency. The term “negotiation” shall include providing information about the Property, showing the Property, or presenting an offer on the Property. All rights under this Section shall terminate upon the expiration of the Extension Period.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
(a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv);
(b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13);
(c) occurrence of a Force Majeure Event;
(d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and
(e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement.
(ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder.
(iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim.
(iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension.
(v) If the event or circumstance giving rise to the notice has a continuing effect:
(a) a fully detailed claim shall be considered as interim;
(b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and
(c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Initial Contract Term The Initial Contract Term shall be for two years. The Initial Contract Term shall begin on October 1, 2021, or on the last date the Contract is signed by all Parties, whichever is later. The Contract shall expire on October 1, 2023, unless terminated earlier in accordance with the Special Contract Conditions or Additional Special Contract Conditions.
