Contractor Undertakings. The Contractor undertakes with the Authority that for so long as this Agreement remains in full force:
Contractor Undertakings. The Contractor undertakes with the Authority and the Related Organisations that for so long as this Contract remains in full force: it shall: upon becoming aware that any litigation, arbitration, administrative or adjudication or mediation proceedings before or of any court, arbitrator or Relevant Authority ("Legal Proceedings") may be threatened or pending and immediately after the commencement of such Legal Proceedings; or in respect of Legal Proceedings which are against a sub-contractor, within twenty (20) Business Days after becoming aware that such Legal Proceedings may be threatened or pending or within twenty (20) Business Days after the commencement of such Legal Proceedings, give the Authority notice of such Legal Proceedings which would adversely affect, to an extent which is material in the context of this Contract, the Contractor's ability to perform its obligations under this Contract; it shall not, without the prior written consent of the Authority, (and whether by a single transaction or by a series of transactions whether related or not) sell, transfer, lend or otherwise dispose of (other than by way of security) the whole or any part of its business or assets which would materially affect the ability of the Contractor to perform its obligations under this Contract; it shall not cease to be resident in the United Kingdom or transfer in whole or in part its undertaking, business or trade outside the United Kingdom; and it shall not undertake the performance of its obligations under this Contract for the provision of the Services otherwise than through itself or a sub-contractor. Status of Warranties All warranties, representations, undertakings, indemnities and other obligations made, given or undertaken by the Contractor in this Contract are cumulative and none shall be given a limited construction by reference to any other. 6AUTHORITY WARRANTIES
Contractor Undertakings. The Contractor undertakes with the Authority that for so long as this Agreement remains in full force: it will upon becoming aware that any litigation, arbitration, administrative or adjudication or mediation proceedings before or of any court, arbitrator or Relevant Authority may be threatened or pending and immediately after the commencement thereof (or within twenty (20) Business Days of becoming aware the same may be threatened or pending or with twenty (20) Business Days after the commencement thereof where the litigation or arbitration or administrative or adjudication or mediation proceedings is against a Sub-Contractor) give the Authority notice of such litigation, arbitration, administrative or adjudication or mediation proceedings which would adversely affect, to an extent which is material in the context of the Project, the Contractor's ability to perform its obligations under this Agreement; it will not without the prior written consent of the Authority (and whether by a single transaction or by a series of transactions whether related or not) sell, transfer, lend or otherwise dispose of (other than by way of security) the whole or any part of its business or assets which would materially affect the ability of the Contractor to perform its obligations under this Agreement; it will not cease to be resident in the United Kingdom or transfer in whole or in part its undertaking, business or trade outside the United Kingdom; it will not undertake the performance of its obligations under this Agreement for the provision of the Services otherwise than through itself or a Sub-Contractor; it shall not without the written consent of the Authority (such consent not to be unreasonably withheld or delayed) incorporate any company or purchase or acquire or subscribe for any shares in any company save where such company is involved in the provision of the Services or Works; it shall not without the written consent of the Authority (such consent not to be unreasonably withheld or delayed) make any loans or grant any credit or give any guarantee or indemnity to or for the benefit of any person or otherwise voluntarily or for consideration assume any liability (whether actual or contingent) in respect of any obligation of any other person except in the ordinary course of business and/or as contemplated by the Project Documents, Ancillary Documents and/or Financing Agreements; and it shall not change or cease its business or start any other business which is mate...
Contractor Undertakings. The Contractor hereby undertakes with the Authority that until the earlier of the Expiry Date and the Termination Date:-
Contractor Undertakings. If Contractor becomes reasonably aware that any Satellite after Launch contains or is predicted to contain a Defect or Anomaly, Contractor shall correct such Defect or Anomaly in accordance with the provisions of Article 14.3.1 or 14.3.2, as applicable.
Contractor Undertakings. The Contractor undertakes with the Authority that for so long as this Contract remains in force: it will not undertake the performance of its obligations under this Contract for the provision of the Services otherwise than through itself or a Sub-Contractor.
Contractor Undertakings. The Contractor undertakes with the City Council that for so long as this Agreement remains in full force:
Contractor Undertakings. The Contractor undertakes to the Authority that, for the Contract Period, it will, and (other than in respect of Clauses 16.2(h), (i) and (i)) will ensure (if appropriate) that each of the Subcontractors under a Material Subcontract will if appropriate:
Contractor Undertakings. 10.2.1 The Contractor undertakes that for so long as this Contract remains in force:
