Contractor’s obligation to indemnify Owner’s Indemnitees for claims arising out of or related to infringement of patent rights and copyrights are as set forth in Paragraph 7.14.
Contractor’s obligation to indemnify Owner’s Indemnitees for claims arising out of or related to infringement of patent rights Sample Clauses
Related to Contractor’s obligation to indemnify Owner’s Indemnitees for claims arising out of or related to infringement of patent rights
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Indemnification for Third Party Claims (a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents. (b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents. (c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that: (i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party; (ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and (iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld. (d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement. (e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.
Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:
INDEMNIFICATION FOR INFRINGEMENT The terms of this Section 10 do not apply to the Community Edition Licensees. Licensor will defend or settle, at its own expense, any claim against Licensee asserting a copyright, trademark or trade secret which concerns the Product used within the scope of the Agreement hereunder. Licensor shall indemnify Licensee against any loss, expense or liability including reasonable attorney's fees from any damages alleged against Licensee. Licensor's obligations under this Section are conditioned on Licensee promptly notifying Licensor in writing after Licensee first receives notice of any such claim, action or allegation of infringement and, Licensor being given sole control of the defense of any action and all negotiations for its settlement or compromise, with the reasonable assistance of Licensee. Licensor shall not be liable for any costs or expenditures incurred by Licensee without Licensor's prior written consent. If an injunction or order is obtained against Licensee's use of the Product by reason of the allegations of infringement, or if in Licensor's opinion the Product is likely to become the subject of a claim of infringement, Licensor shall, at its expense: (a) Procure for Licensee the right to continue using the Product; or (b) Modify or replace the Product with a compatible, functionally equivalent, non-infringing Product(s); or (c) If neither (a) nor (b) is reasonably practical in Licensor's judgment, remove the Product and issue Licensee a pro rata credit based upon the License fees paid for the Product prorated over a thirty-six (36) month period from the date of shipment of the Product. Thereafter, termination shall proceed in accordance with the terms of Section 4. Licensor shall have no obligation under this Section to the extent the alleged infringement results from (i) modification of the Product other than by Licensor; (ii) the combination of the Product with products not provided by Licensor; or (iii) use of any older version of the Product when use of a newer version made available to Licensee would have avoided the infringement. This Section 10 is Licensor's entire liability and Licensee's sole and exclusive remedy in the event of intellectual property infringement of any kind.
Indemnification in Third Party Proceedings Subject to Section 10 below, the Company shall indemnify Indemnitee to the fullest extent permitted by the Code, as the same may be amended from time to time (but, only to the extent that such amendment permits Indemnitee to broader indemnification rights than the Code permitted prior to adoption of such amendment), if Indemnitee is a party to or threatened to be made a party to or otherwise involved in any proceeding, for any and all expenses, actually and reasonably incurred by Indemnitee in connection with the investigation, defense, settlement or appeal of such proceeding.
Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Procedures for Indemnification of Third Party Claims (a) If an Indemnified Party shall receive notice or otherwise learn of the assertion of any Third Party Claim or of the commencement by any such Person of any Action with respect to which an Indemnifying Party may be obligated to provide indemnification to such Indemnified Party pursuant to this Section 12.4, such Indemnified Party shall give such Indemnifying Party written notice thereof within 20 days after becoming aware of such Third Party Claim. Any such notice shall describe the Third Party Claim in reasonable detail. Notwithstanding the foregoing, the failure of any Indemnified Party or other Person to give notice as provided in this Section 12.4 shall not relieve the Indemnifying Party of its obligations under this Section 12.4, except to the extent that such Indemnifying Party is actually prejudiced by such failure to give notice. (b) An Indemnifying Party may elect to defend (and to seek to settle or compromise), at such Indemnifying Party’s own expense and by such Indemnifying Party’s own counsel, any Third Party Claim. Within 30 days after the receipt of notice from an Indemnified Party in accordance with Section 12.4(a) (or sooner, if the nature of such Third Party Claim so requires), the Indemnifying Party shall notify the Indemnified Party of its election whether the Indemnifying Party will assume responsibility for defending such Third Party Claim, which election shall specify any reservations or exceptions. After notice from an Indemnifying Party to an Indemnified Party of its election to assume the defense of a Third Party Claim, such Indemnified Party shall have the right to employ separate counsel and to participate in (but not control) the defense, compromise, or settlement thereof, but the fees and expenses of such counsel shall be the expense of such Indemnified Party except as set forth in the next sentence. If the Indemnifying Party has elected to assume the defense of the Third Party Claim but has specified, and continues to assert, any reservations or exceptions in such notice, then, in any such case, the reasonable fees and expenses of one separate counsel for all Indemnified parties shall be borne by the Indemnifying Party, but the Indemnifying Party shall be entitled to reimbursement by the Indemnified Party for payment of any such fees and expenses to the extent that it establishes that such reservations and exceptions were proper. (c) If an Indemnifying Party elects not to assume responsibility for defending a Third Party Claim, or fails to notify an Indemnified Party of its election as provided in Section 12.4(b) such Indemnified Party may defend such Third Party Claim at the cost and expense of the Indemnifying Party. (d) Unless the Indemnifying Party has failed to assume the defense of the Third Party Claim in accordance with the terms of this Agreement, no Indemnified Party may settle or compromise any Third Party Claim without the consent of the Indemnifying Party. No Indemnifying Party shall consent to entry of any judgment or enter into any settlement of any pending or threatened Third Party Claim in respect of which any Indemnified Party is or could have been a party and indemnity could have been sought hereunder by such Indemnified Party without the consent of the Indemnified Party if (i) the effect thereof is to permit any injunction, declaratory judgment, other order or other nonmonetary relief to be entered, directly or indirectly against such Indemnified Party and (ii) such settlement does not include an unconditional release of such Indemnified Party from all liability on claims that are the subject matter of such Third Party Claim.
Third Party Claims The obligation of an indemnifying party to ------------------ indemnify another party to this Agreement under the provisions of this Article with respect to claims resulting from the assertion of liability by Persons not parties to this Agreement (including governmental claims for penalties, fines and assessments) shall be subject to the following terms and conditions: (a) The indemnified party shall give prompt written notice to the indemnifying party of any assertion of liability by a third party which might give rise to a claim for indemnification, which notice shall state the nature and basis of the assertion and the amount thereof, to the extent known, provided, however, that no delay on the part of the indemnified party in giving notice shall relieve the indemnifying party of any obligation to indemnify unless (and then solely to the extent that) the indemnifying party is prejudiced by such delay. (b) If any action, suit or proceeding (a "Legal Action") is brought against an indemnified party with respect to which the indemnifying party may have an obligation to indemnify, the Legal Action shall be defended by the indemnifying party and such defense shall include all proceedings and appeals which counsel for the indemnified party shall reasonably deem appropriate. (c) Notwithstanding the provisions of the previous subsection of this Article, until the indemnifying party shall have assumed the defense of any such Legal Action, the defense shall be handled by the indemnified party. Furthermore, (i) if the indemnified party shall have reasonably concluded that there are likely to be defenses available to the indemnified party that are different from or in addition to those available to the indemnifying party; (ii) if the indemnifying party fails to provide the indemnified party with evidence reasonably acceptable to the indemnified party that the indemnifying party has sufficient financial resources to defend and fulfill its indemnification obligation with respect to the Legal Action; (iii if the Legal Action involves other than money damages and seeks injunctive or other equitable relief; or (iv) if a judgment against the indemnified party will, in the good faith opinion of the indemnified party, establish a custom or precedent which will be materially adverse to the best interests of its continuing business, the indemnifying party shall not be entitled to assume the defense of the Legal Action and the defense shall be handled by the indemnified party. If the defense of the Legal Action is handled by the indemnified party under the provisions of this subsection, the indemnifying party shall pay all legal and other expenses reasonably incurred by the indemnified party in conducting such defense. (d) In any Legal Action initiated by a third party and defended by the indemnifying party (i) the indemnified party shall have the right to be represented by advisory counsel and accountants, at its own expense, (ii) the indemnifying party shall keep the indemnified party fully informed as to the status of such Legal Action at all stages thereof, whether or not the indemnified party is represented by its own counsel, (iii) the indemnifying party shall make available to the indemnified party, and its attorneys, accountants and other representatives, all books and records of the indemnifying party relating to such Legal Action and (iv) the parties shall render to each other such assistance as may be reasonably required in order to ensure the proper and adequate defense of the Legal Action. (e) In any Legal Action initiated by a third party and defended by the indemnifying party, the indemnifying party shall not make any settlement of any claim without the written consent of the indemnified party, which consent shall not be unreasonably withheld. Without limiting the generality of the foregoing, it shall not be deemed unreasonable to withhold consent to a settlement involving injunctive or other equitable relief against the indemnified party or its assets, employees or business, or relief which the indemnified party reasonably believes could establish a custom or precedent which will be adverse to the best interests of its continuing business.
