Contractor’s Release. A document or language within a document such as an Application for Progress Payment or Application for Final Payment wherein the Contractor agrees to release and discharge County and the CEI or A/E from all claims and demands related to a designated portion of the Work, except any claims for retainage or disputed claims, upon receipt of payment from the County.
Contractor’s Release. 14.2.3 Failure to provide any of the items above shall be sufficient reason to withhold payment of the current Application for Progress Payment until delivered to the CEI or A/E or County.
Contractor’s Release. KNOW ALL MEN BY THESE PRESENTS that I, {insert name}, in my capacity as {insert title} of { name of Contractor} agree that upon receipt of the sum of $ from the CITY OF PORTSMOUTH NEW HAMPSHIRE as final and completed payment for the construction of: {name of project} do hereby on behalf of {name of Contractor} and its successors and assigns release, quit-claim and forever discharge the City of Portsmouth, New Hampshire, its successors and assigns, of and from all claims and demands arising from or in connection with the construction of the above-referenced project and the contract dated . All claims and demands shall include without limitation all actions, causes, suits, debts, dues, duties, sums of money, accounts, reckonings, bonds, bills, specifications, covenants, contracts, agreements, promises, damages and judgments whatsoever in law or equity against the City of Portsmouth, New Hampshire which Contractor ever had, now has or may have, for, upon or by reason of any matter, cause, or thing whatsoever; from the beginning of record time to the date of these presents.
Contractor’s Release. A document wherein the Contractor acknowledges receipt of full and final payment from the County in complete satisfaction of all the County’s obligations under this Contract and which releases and discharges County and the architect/engineer from all claims and demands arising from the work performed pursuant to the Contract Documents.
Contractor’s Release. A document wherein the contractor acknowledges receipt of full and final payment from the County in complete satisfaction of all the County’s obligations under the contract and which releases and discharges County and the architect/engineer from all claims and demands arising from the work performed pursuant to the contract documents.
Contractor’s Release. Contract No. (the “Contract”) By signing this Release,
Contractor’s Release. Any and all Contract modifications are a full release of SCC from any liability for any additional compensation or extension of time arising or resulting from the Work performed pursuant to a Contract modification. By execution of a Contract modification, the Contractor accepts the compensation and/or time extension provided in full accord and satisfaction for that Contract modification, and expressly waives, releases and relinquishes any and all additional claims and demands relating to, or arising out of, the matters covered by that Contract modification, including but not limited to direct or indirect cost, profit, or damages related to disruptions.
Contractor’s Release. 13.11.1 The acceptance of Final Payment by the Contractor shall constitute a waiver of all claims by the Contractor against the Authority and the Design Consultant, except those expressly reserved by the Contractor in writing at the time of Final Payment. Such reservation of rights shall state the specific amounts of the claims being reserved and the bases for such claims. Failure to state the specific amount of a claim shall result in a waiver of that claim. The Contractor shall be deemed to have waived all claims for which the notices required by law and the Contract Documents have not been provided.
Contractor’s Release. Contractor shall not be liable for any damage due to acts of God, unforeseen weather conditions, or circumstances beyond Contractor's reasonable control.
Contractor’s Release. All Contract Modifications constitute a full release of the City from any liability for any additional compensation or extension of time arising or resulting from the Work performed pursuant to the Contract Modification. By executing a Contract Modification, you accept the compensation and/or time extension provided in it in full accord and satisfaction for that Contract Modification, and you expressly waive, release and relinquish all additional claims and demands relating to or arising out of the matters covered by that Contract Modification, including direct or indirect cost, profit, or damages related to disruptions.
