Control of Defense and Settlement. Contractor shall promptly provide Notice to the County of any proposed settlement, and Contractor may not, without County’s prior written consent (which the County will not unreasonably withhold, condition, or delay), settle such claim or consent to entry of any third-party judgment. Nothing in this section precludes Contractor from allowing County to undertake control of the defense.
Appears in 3 contracts
Samples: Contract for Aquatic Invasive Species Watercraft Inspection Services, Contract for Aquatic Invasive Species Watercraft Inspection Services, Contract for Aquatic Invasive Species Watercraft Inspection Services
Control of Defense and Settlement. Contractor shall promptly provide Notice to the County of any proposed settlement, and Contractor may not, without County’s prior written consent (which the County will not unreasonably withhold, condition, or delay), settle such claim or consent to entry of any third-third- party judgment. Nothing in this section precludes Contractor from allowing County to undertake control of the defense.
Appears in 1 contract
Samples: Service Agreement
Control of Defense and Settlement. Contractor shall promptly provide Notice to the County of any proposed settlement, and Contractor may not, without County’s prior written consent (which the County will not unreasonably withhold, condition, or delay), settle such claim or consent to entry of any third-party judgment. Nothing in this section precludes Contractor from allowing County to undertake from undertaking control of the defense.
Appears in 1 contract
Samples: Contract
