Quality of Materials and workmanship The Contractor shall ensure that the Construction, Materials and workmanship are in accordance with the requirements specified in this Agreement, Specifications and Standards and Good Industry Practice.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Materials and Supplies The cost of materials and supplies is allowable. Purchases should be charged at their actual prices after deducting all cash discounts, trade discounts, rebates, and allowances received. Withdrawals from general stores or stockrooms should be charged at cost under any recognized method of pricing, consistently applied. Incoming transportation charges are a proper part of materials and supply costs.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
MATERIALS AND WORKMANSHIP (a) All equipment, material, and articles incorporated into the work covered by this Agreement shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this Agreement.
(b) Seller shall obtain Company approval of the machinery and mechanical and other equipment to be incorporated into the work. When required by Company, Seller shall also obtain Company's approval of the material or articles which Seller contemplates incorporating into the work. When so directed, Seller shall submit samples for approval at Seller's expense. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.
(c) References in the specifications or drawings to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. Seller may, with Company's written approval, use any equipment, material, article, or process that is equal to that specified, unless the words "No Substitution" follow the listing of the item in the specifications or drawings. Unless otherwise agreed, modifications due to use of “or equal” supplies, is at Seller’s expense.
(d) All work under this Agreement shall be performed in a skillful and workmanlike manner. Company may require, in writing, Seller to remove from the work any employee Company deems incompetent, careless, or otherwise objectionable.
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK
Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Clinical Studies The animal and other preclinical studies and clinical trials conducted by the Company or on behalf of the Company were, and, if still pending are, to the Company’s knowledge, being conducted in all material respects in compliance with all Applicable Laws and in accordance with experimental protocols, procedures and controls generally used by qualified experts in the preclinical study and clinical trials of new drugs and biologics as applied to comparable products to those being developed by the Company; the descriptions of the results of such preclinical studies and clinical trials contained in the Registration Statement and the Prospectus are accurate and complete in all material respects, and, except as set forth in the Registration Statement and the Prospectus, the Company has no knowledge of any other clinical trials or preclinical studies, the results of which reasonably call into question the clinical trial or preclinical study results described or referred to in the Registration Statement and the Prospectus when viewed in the context in which such results are described; and the Company has not received any written notices or correspondence from the FDA, the EMA, or any other domestic or foreign governmental agency requiring the termination, suspension or modification of any preclinical studies or clinical trials conducted by or on behalf of the Company that are described in the Registration Statement and the Prospectus or the results of which are referred to in the Registration Statement and the Prospectus.
Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing.
(b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time.
(c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request.
(d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation.
(e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.
