Work Schedule (A) Where an employee has an established schedule, a change in workdays or shifts will be posted no less than 14 calendar days in advance and will reflect at least a two workweek schedule; however, the state will make a good faith effort to reflect a one month schedule.
(B) In the event of a declared emergency the notice requirement of this Section may be void.
(C) The state will continue to observe the scheduling structures currently in place at each agency and agrees to bargain any change in the overall practice of how schedules are established.
Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.
Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof.
6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement.
6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement.
6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER.
6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing.
6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8.
6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Drawings and Specifications 9.1 A complete list of all Drawings that form a part of the Contract Documents are to be found as an index on the Drawings themselves, and/or may be provided to Developer and/or in the Table of Contents.
9.2 Materials or Work described in words that so applied have a well-known technical or trade meaning shall be deemed to refer to recognized standards, unless noted otherwise.
9.3 Trade Name or Trade Term It is not the intention of the Contract Documents to go into detailed descriptions of any materials and/or methods commonly known to the trade under “trade name” or “trade term.” The mere mention or notation of “trade name” or “trade term” shall be considered a sufficient notice to Developer that it will be required to complete the work so named, complete, finished, and operable, with all its appurtenances, according to the best practices of the trade.
9.4 The naming of any material and/or equipment shall mean furnishing and installing of same, including all incidental and accessory items thereto and/or labor therefor, as per best practices of the trade(s) involved, unless specifically noted otherwise.
9.5 Contract Documents are complementary, and what is called for by one shall be binding as if called for by all. As such, Drawings and Specifications are intended to be fully cooperative and to agree. However, if Developer observes that Drawings and Specifications are in conflict with the Contract Documents, Developer shall promptly notify District and Architect in writing, and any necessary changes shall be made as provided in the Contract Documents.
9.6 Figured dimensions shall be followed in preference to scaled dimensions, and Developer shall make all additional measurements necessary for the work and shall be responsible for their accuracy. Before ordering any material or doing any work, each Developer shall verify all measurements at the building and shall be responsible for the correctness of same.
9.7 Should any question arise concerning the intent or meaning of the Contract Documents, including the Plans and Specifications, the question shall be submitted to the District for interpretation. If a conflict exists in the Contract Documents, these Construction Provisions shall control over the Facilities Lease, which shall control over the Site Lease, which shall control over Division 1 Documents, which shall control over Division 2 through Division 49 documents, which shall control over figured dimensions, which shall control over large-scale drawings, which shall control over small-scale drawings. In no case shall a document calling for lower quality and/or quantity of material or workmanship control. However, in the case of discrepancy or ambiguity solely between and among the Drawings and Specifications, the discrepancy or ambiguity shall be resolved in favor of the interpretation that will provide District with the functionally complete and operable Project described in the Drawings and Specifications.
9.8 Drawings and Specifications are intended to comply with all laws, ordinances, rules, and regulations of constituted authorities having jurisdiction, and where referred to in the Contract Documents, the laws, ordinances, rules, and regulations shall be considered as a part of the Contract Documents within the limits specified.
9.9 As required by Section 4-317(c), Part 1, Title 24, CCR: “Should any existing conditions such as deterioration or non-complying construction be discovered which is not covered by the DSA-approved documents wherein the finished work will not comply with Title 24, California Code of Regulations, a construction change document, or a separate set of plans and specifications, detailing and specifying the required repair work shall be submitted to and approved by DSA before proceeding with the repair work.”
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Plans and Specifications After Landlord receives and approves Tenant’s Space Plan as provided above, Tenant will cause Tenant’s Architect to prepare the Plans and Specifications for the Tenant Improvements. Landlord will approve or disapprove (specifically describing any reasons for disapproval) the Plans and Specifications in writing within ten (10) Business Days after receiving them. If Landlord disapproves the Plans and Specifications, Tenant will provide appropriately revised Plans and Specifications to Landlord for approval (or disapproval) within five (5) Business Days on the same basis as set forth above. After Landlord’s approval, Tenant will submit the Plans and Specifications for permits and construction bids. No deviation from the Building Standard will be permitted in the Space Plan or the Plans and Specifications, provided reasonable deviations with respect to the ceiling, lighting, painting, flooring and wall covering may be permitted with Landlord’s approval. Landlord will not approve any deviations which Landlord believes (a) do not conform to applicable codes, ordinances and other Laws or are disapproved by any governmental agency, (b) require services beyond the level normally provided to other tenants in the Building, or (c) are of a nature or quality that are inconsistent with Landlord’s overall plan or objectives for the Building. No approval by Landlord of any deviation constitutes an acknowledgment by Landlord that such deviations are in conformance with applicable codes, ordinances and other Laws. In the event that Landlord’s approval shall be required in this Tenant Improvements Agreement, then notwithstanding anything to the contrary set forth in the Lease, Landlord’s approval shall not be unreasonably withheld, conditioned, or delayed.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Milestone Schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.
