Transportation and Delivery Prices shall include all charges for packing, handling, freight, distribution, and inside delivery. Transportation of goods shall be FOB Destination to any point within thirty (30) days after the Customer places an Order. A Contractor, within five (5) days after receiving a purchase order, shall notify the Customer of any potential delivery delays. Evidence of inability or intentional delays shall be cause for Contract cancellation and Contractor suspension.
Shipment and Delivery Seller grants the Company the right at any time to specify the carrier and/or method of transportation to be employed in conveying any part or all of the Goods covered herein. In the event that Seller uses an unauthorized carrier and/or method of transportation, then all shipping expenses shall be assumed by Seller. Unless otherwise stated in the Order, all Goods will be shipped FCA shipment point. FCA shall be interpreted in accordance with the version of Incoterms valid at the time of the Seller’s acceptance of the Order. The Seller shall be responsible for preparing and filing all export documentation for all shipments. The Company shall not be obligated to accept early deliveries, partial deliveries or excess deliveries. If Goods are incorrectly delivered, the Seller shall be responsible for any additional expense incurred in delivering the Goods to the correct destination. The delivery date set forth on the Order is of the essence of the Contract. If the Seller anticipates that it will not be able to deliver the Goods upon the agreed delivery date, then the Seller shall immediately notify the Company thereof in writing; provided, however, that such notice shall not relieve the Seller of its responsibilities and liabilities with respect to on-time delivery hereunder. In such event, the Company may request that the Seller expedite delivery to the maximum extent possible at the Seller’s sole expense. If the Seller does not deliver the Goods by the agreed delivery date, then the Company shall be entitled to liquidated damages as agreed between the parties, up to and including the total Order value. Notwithstanding the foregoing, the Company reserves the right to claim repayment for any and all costs, losses, expenses and damages incurred by the Company that are attributable to the Seller’s delay in delivery. Such liquidated damages shall be paid at the Company’s written demand. Partial deliveries shall not relieve the Seller from liability for any late delivery hereunder. If the Seller discovers that it has shipped any non-conforming Goods to the Company, it shall immediately (and not more than 24 hours after such discovery) notify the Company thereof in writing; provided, however, that such notice shall not relieve the Seller of its responsibilities and liabilities with respect to defective goods hereunder.
Description of Goods; Sale and Delivery Seller shall sell, transfer, and deliver to Buyer the goods described on the Description/Proposal attached hereto and made a part of as Exhibit "A" subject to such terms as are set forth in the Description/Proposal and in this Agreement.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
SUPPLY AND DELIVERY All services supplied shall be deemed to have been supplied when notified by the Company. If you claim that some services have not been supplied or rendered, you must notify the Company within 14 days of notification of supply.
Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.
Payment and Delivery Payment for the Option Shares shall be made on the Option Closing Date by wire transfer in Federal (same day) funds, payable to the order of the Company upon delivery to you of certificates (in form and substance satisfactory to the Underwriters) representing the Option Shares (or through the facilities of DTC) for the account of the Underwriters. The Option Shares shall be registered in such name or names and in such authorized denominations as the Representative may request in writing at least two (2) full Business Days prior to the Option Closing Date. The Company shall not be obligated to sell or deliver the Option Shares except upon tender of payment by the Representative for applicable Option Shares.
Services and Deliverables The Services and the required Deliverables for the Services are specified below. SPID: Service outlet: MDS ID: Funding ID: Service Type Output Measure Quantity per annum Number of Service Users Funding amount per annum (excl. GST) $ $ $ Description of Services Funding amount one-off (excl. GST) $ Geographic Catchment Area: SPID: Service outlet: MDS ID: Funding ID: Service Type Output Measure Quantity per annum Number of Service Users Funding amount (excl. GST) $ $ $ Description of Services Funding amount one-off (excl. GST) $ Geographic Catchment Area: *Note: Refer to clause 4.3 in the Funding and Service Details about permitted variations in Output Quantities.
Shipping and Delivery a. The prices are the delivered price to any Purchasing Entity. All deliveries shall be F.O.B. destination, freight pre-paid, with all transportation and handling charges paid by the Contractor. Responsibility and liability for loss or damage shall remain the Contractor’s until final inspection and acceptance when responsibility shall pass to the Purchasing Entity except as to latent defects, fraud and Contractor’s warranty obligations. The minimum shipment amount, if any, will be found in the special terms and conditions. Any order for less than the specified amount is to be shipped with the freight prepaid and added as a separate item on the invoice. Any portion of an Order to be shipped without transportation charges that is back ordered shall be shipped without charge.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
