No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
AUDITS AND INVESTIGATIONS 27.1 Each invoice paid by UNDP shall be subject to a post-payment audit by auditors, whether internal or external, of UNDP or by other authorized and qualified agents of UNDP at any time during the term of the Contract and for a period of three (3) years following the expiration or prior termination of the Contract.
Cooperation with Investigations You agree to cooperate with us in the investigation of unusual transactions, poor quality transmissions, and resolution of customer claims, including by providing, upon request and without further cost, any originals or copies of items deposited through the Service in your possession and your records relating to such items and transmissions.
AUDITS AND EXAMINATIONS 8.1. Each Party to this Agreement will be responsible for the accuracy and quality of its data as submitted to the other Party involved. Subject to each Party’s reasonable security requirements and except as may be otherwise specifically provided in this Agreement, either Party, at its own expense, may audit the other Party’s books, records and other documents directly related to billing and invoicing once in any twelve (12) month period for the purpose of evaluating the accuracy of the other Party’s billing and invoicing. "
Costs of Litigation The parties agree that the prevailing party in any action brought with respect to or to enforce any right or remedy under this Agreement shall be entitled to recover from the other party or parties all reasonable costs and expenses of any nature whatsoever incurred by the prevailing party in connection with such action, including without limitation reasonable attorneys' fees and prejudgment interest.
COMPLAINTS AND INVESTIGATIONS 1. This article applies to complaints or allegations made externally and not from normal supervisory activities.
Response/Compliance with Audit or Inspection Findings A. Grantee must act to ensure its and its Subcontractors’ compliance with all corrections necessary to address any finding of noncompliance with any law, regulation, audit requirement, or generally accepted accounting principle, or any other deficiency identified in any audit, review, or inspection of the Contract and the services and Deliverables provided. Any such correction will be at Grantee’s or its Subcontractor's sole expense. Whether Xxxxxxx's action corrects the noncompliance shall be solely the decision of the System Agency.
Litigation; Compliance with Laws (a) There are no actions, suits or proceedings at law or in equity by or before any Governmental Authority now pending or, to the knowledge of any Company, threatened against or affecting any Company or any business, Property or rights of any such Person (i) that involve any Loan Document or the Transactions or (ii) as to which there is a reasonable possibility of an adverse determination and that, if adversely determined, could reasonably be expected, individually or in the aggregate, to result in a Material Adverse Effect.
LIMITATIONS ON REVERSE ENGINEERING, DECOMPILATION AND DISASSEMBLY You may not reverse engineer, decompile, or disassemble the Software, except and only to the extent that such activity is expressly permitted by applicable law notwithstanding this limitation.
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
