Debarment and Suspension A. The Contractor certifies by entering into this Contract that neither it nor its principals nor any of its subcontractors are presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from entering into this Contract by any federal agency or by any department, agency or political subdivision of the State of Indiana. The term “principal” for purposes of this Contract means an officer, director, owner, partner, key employee or other person with primary management or supervisory responsibilities, or a person who has a critical influence on or substantive control over the operations of the Contractor.
B. The Contractor certifies that it has verified the state and federal suspension and debarment status for all subcontractors receiving funds under this Contract and shall be solely responsible for any recoupment, penalties or costs that might arise from use of a suspended or debarred subcontractor. The Contractor shall immediately notify the State if any subcontractor becomes debarred or suspended, and shall, at the State’s request, take all steps required by the State to terminate its contractual relationship with the subcontractor for work to be performed under this Contract.
Debarment/Suspension Contractor is prohibited from making any award or permitting any award at any tier to any party which is debarred or suspended or otherwise excluded from or ineligible for participation in federal assistance programs under Executive Order 12549, Debarment and Suspension. Contractor and its subcontractors shall comply with the Certification Requirements for Recipients of Grants and Cooperative Agreements Regarding Debarments and Suspensions.
BANKRUPTCY, DEBARMENT, OR SUSPENSION CERTIFICATION Supplier certifies and warrants that it is not in bankruptcy or that it has previously disclosed in writing certain information to Sourcewell related to bankruptcy actions. If at any time during this Contract Supplier declares bankruptcy, Supplier must immediately notify Sourcewell in writing. Supplier certifies and warrants that neither it nor its principals are presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from programs operated by the State of Minnesota; the United States federal government or the Canadian government, as applicable; or any Participating Entity. Supplier certifies and warrants that neither it nor its principals have been convicted of a criminal offense related to the subject matter of this Contract. Supplier further warrants that it will provide immediate written notice to Sourcewell if this certification changes at any time.
CERTIFICATION REGARDING DEBARMENT OR SUSPENSION Contractor certifies that neither Contractor or its principals; its subcontractors or their principals; the sub-recipients (if applicable) or their principals are suspended, debarred, proposed for debarment, voluntarily excluded from covered transactions, or otherwise disqualified by any federal department or agency from doing business with the Federal Government pursuant to Executive Orders 12549 and 12689. Contractor specifically covenants that neither the Contractor or its principals, its sub-contractors or their principals, or the sub-recipients (if applicable) or their principals are included on the Excluded Parties List System (“EPLS”) maintained by the General Services Administration (“GSA”).
TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice.
§ 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination.
§ 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause.
§ 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements.
§ 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:
Dismissal or Suspension Grievances (a) In the case of a dispute arising from an employee’s dismissal, the grievance may be filed directly at Step 3, within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal.
(b) In the case of a dispute arising from an employee’s suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within (30) days of the employee receiving notice of suspension.
Dismissal or Suspension Grievance (a) In the case of a dispute arising from an employee's dismissal, the grievance may be filed directly at arbitration within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal.
(b) In the case of a dispute arising from an employee's suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within thirty (30) days of the employee receiving notice of suspension.
No Suspension Trading in the Common Stock shall not have been suspended on the Exchange and the Common Stock shall not have been delisted from the Exchange.
SUSPENSION & DEBARMENT Contractor represents and warrants as previously certified in Contractor’s Bidder’s Certification, that neither Contractor nor its principals or affiliates presently are nor have ever been debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in any governmental contract by any governmental department or agency within the United States.
