DEFAULT BY THE PARTIES Sample Clauses

DEFAULT BY THE PARTIES. 5.1 The PURCHASER shall have the right to cancel this agreement if; 5.1.1 Construction and/or finishes are not as per schedule of minimum specifications (Annexure “C"); 5.2 The SELLER shall have the right to cancel this agreement and put the unit up for resale if; 5.2.1 Transfer of the property is delayed by the Purchaser for any reason. 5.2.2 If transfer of the property is delayed by the Purchaser and the Seller does not exercise his right to cancel as per clause 5.2.1, then the Purchaser shall be liable for occupational rental from date of occupation as set out in clause 2.1.15. 5.2.3 The Purchaser markets the property in any manner, by either placing advertisements or appointing an agent, or any other manner of marketing, before the property is registered in the name of the Purchaser. If the Purchaser breaches the agreement in terms of this paragraph, the Seller shall be entitled to cancel the agreement immediately, without any notice to the Purchaser. 5.2.4 It is specifically agreed that only the Agent will be allowed to market and / or sell the Property in any way, before the registration of the unit into the name of the Purchaser. 5.2.5 Should the Seller elect to cancel the agreement, the Seller shall be entitled, without prejudice to any other rights available to it, to claim damages, retain all such amounts paid as a genuine pre-estimate of damages as a result of such breach in which event the Purchaser shall be deemed to have authorised the Seller’s Conveyancers to pay the Seller such monies paid by him/her/it in terms of this agreement and / or repossess the section. 5.3 Save for the provisions of paragraph 5.2 above, if a party commits a breach of any of the provisions of this agreement and fails to remedy same within 3 (three) days after the dispatch (either by email and/or registered post) of the written notice to the defaulting party, then the aggrieved party may cancel this agreement. 5.4 In the event that an act of insolvency (as defined in the Insolvency Act 24 of 1936) has commenced or threatened to commence in respect of a Party, this Agreement shall be deemed automatically terminated.
Sample 1Sample 2See All (7)
AutoNDA by SimpleDocs
DEFAULT BY THE PARTIES. In the event that one party hereto is in material breach of this Agreement, the other party may provide written notice of that breach, and will provide a cure period of not less than 30 days. In the event that the material breach continues beyond the 30-day cure period, the other party will have the right to terminate the Agreement by providing written notice of said termination.
Sample 1Sample 2See All (4)
DEFAULT BY THE PARTIES. 15.1 Either party may terminate this Agreement immediately by providing a written notice to the other party if: (i) either party had breached any term of this Agreement which (in the case of a breach capable of being remedied) shall not have been remedied within seven (7) days of a written request to remedy the same; and (ii) either party had become insolvent, liquidated or bankrupt, has an administrator, receiver, liquidator appointed or ceases to continue business for any reason; 15.2 Upon termination, Clause 7 above shall apply. 15.3 This Clause 15 shall survive the termination and shall not be construed as waiver of rights for either Party against any liability whatsoever.
Sample 1
DEFAULT BY THE PARTIES. Except for default by reason of force majeure or upon a failure to pay amounts owed when due (in which event fifteen (15) days notice shall be required.) The defaulting party shall have forty-five (45) days from receipt of notice of default to cure any of the following events of default brought to its attention before the notifying party may immediately terminate this Agreement for cause as herein provided: The marketing party fails to provide proper user instructions, or misleading information to users pertaining to the products. The marketing party has forty-five (45) days from notification to correct the instructions and/or misinformation and to so notify customers and exert his best efforts to notify users that were not provided the correct information. It is the responsibility of the manufacture or supplying party of other critical components to establish the performance criteria. Either party becomes insolvent; or ceases to function as a going concern; or ceases to conduct its operation in the normal course of business; or a receiver for it or assignee for benefit of creditors is appointed; suffers an attachment or levy on a substantial portion of its assets; or files for relief under any bankruptcy, reorganization, liquidation or other insolvency proceeding; or it otherwise takes advantage of any insolvency law; or Either party breaches any other material provision of this Agreement.
Sample 1
DEFAULT BY THE PARTIES. Upon termination of this Agreement as a result of an uncured default by either of the Parties hereto pursuant to Section 5(b) above, any moneys received prior to such event by the Sellers shall be retained by the Sellers, and the Purchased Shares shall be allocated between Buyer and Sellers in proportion to the percentage of Payments that have been made. The Sellers shall receive back from Buyer the unpaid for Purchased Shares (pro rata in proportion to the relative amount sold as set forth in Exhibit A), and the parties shall notify the Authority of the allocation of Members Pipeline Capacity percentages resulting from such allocation. Buyer agrees to execute any documentation which may be required by the Authority to document the re-conveyance of the Purchased Shares and all related interests in the WISE project. If Buyer is in default, Buyer shall not receive any credit or refund for the costs or expenses paid by Buyer attributable to the use of the full Purchased Shares during the time prior to default. If Buyer has failed to make a payment required under this Agreement, Sellers may cure the default upon termination, but Buyer shall continue to be responsible to Sellers for any Late Fees or interest imposed by the Authority under the Organizational Agreement for late payment of costs. If Seller is in default, Buyer shall receive a refund for the costs and expenses paid by Buyer attributable to the use of the full Purchases Shares during the time of default but shall pay the pro-rated portion of such expenses based on the number of Purchased Shares it retains upon allocation of same after default per the above.
Sample 1
DEFAULT BY THE PARTIES. In the event of default by either of the Parties, the non- defaulting Party has the right to terminate this Agreement, in whole or in part, for cause if the non-defaulting Party provides the defaulting Party with written notice of such default and the defaulting Party fails to cure such default to the satisfaction of the non-defaulting Party within thirty (30) business days of receipt of such notice (or a greater time if permitted by the non- defaulting Party). The termination of this Agreement for default shall extinguish all rights, duties, and obligations of the Parties to each other hereunder. The allegation of default shall not relieve either Party from its respective obligations hereunder until such time as this Agreement has been actually terminated as set forth herein.
Sample 1
DEFAULT BY THE PARTIES 
Sample 1
AutoNDA by SimpleDocs

Related to DEFAULT BY THE PARTIES

  • Default by the Company If the Company shall fail at Closing Time or at the Date of Delivery to sell the number of Securities that it is obligated to sell hereunder, then this Agreement shall terminate without any liability on the part of any nondefaulting party; provided, however, that the provisions of Sections 1, 4, 6, 7 and 8 shall remain in full force and effect. No action taken pursuant to this Section shall relieve the Company from liability, if any, in respect of such default.

  • Default by Seller If the sale contemplated hereby is not consummated because of a default by Seller in its obligation to sell the Property in accordance with this Agreement after Purchaser has performed or tendered performance of all of its obligations in accordance with this Agreement, then Purchaser, as its sole and exclusive remedy shall elect either (a) to terminate this Agreement, in which event all other rights and obligations of the Seller and the Purchaser hereunder (except those set forth herein which expressly survive a termination of this Agreement) shall terminate immediately; or (b) to waive such matter or condition and proceed to Closing, with no reduction in the Purchase Price. In the event of such termination, the Exxxxxx Money shall be refunded by the Escrow Agent to the Purchaser and Seller shall pay Purchaser’s Transaction Costs up to the amount of the Purchaser’s Transaction Costs Cap. Notwithstanding the preceding sentence, if, at Closing, the Seller fails to comply in any material respect with any of its obligations contained in Section 6.2 or Section 6.4 (the “Closing Obligations”), and if all conditions precedent to the Seller’s obligations hereunder have been satisfied and the Purchaser has fully performed all of its obligations under the Agreement, the Purchaser shall have, in addition to the Purchaser’s remedies contained in the preceding sentence, the option to waive all other actions, rights, or claims for damages for such failure, other than costs and expenses incurred in enforcing this Agreement, and to bring an equitable action to enforce the Closing Obligations by specific performance; provided, (a) the Purchaser shall provide written notice of the Purchaser’s intention to enforce the Closing Obligations by specific performance, and (b) the Purchaser’s suit for specific performance shall be filed against the Seller in a court having jurisdiction in the county and state in which the Property is located, on or before sixty (60) days following the Closing Date, failing which, the Purchaser shall be barred from enforcing the Closing Obligations by specific performance and shall be deemed to have elected to terminate this Agreement as provided herein.

  • Default by Owner If one or more of the following Events of Default shall occur and be continuing, that is to say: (a) breach by Owner of the representations, warranties and covenants of the Owner as set forth in Section 6.02 above); then, and in each and every such case (except in instances where the Event of Default has been cured within thirty (30) days after the date on which written notice of such default, requiring the same to be remedied, shall have been given to the Owner by the Servicer), the Servicer, by notice in writing to the Owner, may immediately terminate all of its responsibilities, duties and obligations as servicer under this Agreement. On or after the receipt by the Owner of such written notice, all responsibilities, duties and obligations of the Servicer to service the Mortgage Loans under this Agreement shall on the date set forth in such notice pass to and be vested in the successor appointed pursuant to Section 10 herein.

  • Default by Purchaser IF PURCHASER FAILS TO CONSUMMATE THIS AGREEMENT FOR ANY REASON OTHER THAN SELLER’S DEFAULT OR THE PERMITTED TERMINATION OF THIS AGREEMENT BY EITHER SELLER OR PURCHASER AS PROVIDED FOR IN THIS AGREEMENT, SELLER WILL BE ENTITLED, AS ITS SOLE REMEDY, TO TERMINATE THIS AGREEMENT AND RECEIVE THE DEPOSIT AS LIQUIDATED DAMAGES FOR THE BREACH OF THIS AGREEMENT. IT IS AGREED BETWEEN SELLER AND PURCHASER THAT THE ACTUAL DAMAGES TO SELLER IN THE EVENT OF SUCH BREACH ARE IMPRACTICAL TO ASCERTAIN, AND THE AMOUNT OF THE DEPOSIT IS A REASONABLE ESTIMATE THEREOF. NOTWITHSTANDING THE FOREGOING, SELLER SHALL RETAIN ALL ITS RIGHTS PURSUANT TO THIS AGREEMENT, AT LAW, OR IN EQUITY, AND NOTHING CONTAINED IN THIS SECTION 12.1, WILL LIMIT THE LIABILITY OF PURCHASER UNDER (I) ANY INDEMNITY PROVIDED BY PURCHASER UNDER THIS AGREEMENT; (II) ANY OF THE DOCUMENTS AND INSTRUMENTS EXECUTED AND DELIVERED TO SELLER PURSUANT TO THE TERMS AND CONDITIONS OF THIS AGREEMENT, OR (III) ANY ACTIONS COMMENCED AFTER CLOSING WITH RESPECT TO ANY OBLIGATION OR REPRESENTATION OF EITHER SELLER OR PURCHASER, WHICH BY THE TERMS OF THIS AGREEMENT SURVIVES CLOSING, INCLUDING BUT NOT LIMITED TO, PROVISIONS REGARDING CONFIDENTIALITY AND PAYMENT OF BROKERAGE FEES.

  • Default by Contractor To the maximum extent permitted by applicable law, failure to comply with any of the terms and/or conditions of this Contract, including these General Conditions, shall constitute default by Contractor and grounds for termination of this Contract. Contractor shall be liable for any and all damages suffered by District due to the failure by Contractor or Contractor’s subcontractor(s) to comply with this Contract.

  • Default by Buyer THE PARTIES HAVE AGREED THAT SELLER’S ACTUAL DAMAGES IN THE EVENT OF A FAILURE TO CONSUMMATE THE SALE DUE TO BUYER’S DEFAULT WOULD BE EXTREMELY DIFFICULT OR IMPRACTICABLE TO DETERMINE. AFTER NEGOTIATION, THE PARTIES HAVE AGREED THAT, CONSIDERING ALL THE CIRCUMSTANCES EXISTING ON THE DATE OF THIS AGREEMENT, THE AMOUNT OF THE XXXXXXX MONEY IS A REASONABLE ESTIMATE OF THE DAMAGES THAT SELLER WOULD INCUR IN THE EVENT OF BUYER’S DEFAULT. IN THE EVENT BUYER FAILS, WITHOUT LEGAL EXCUSE, TO COMPLETE THE PURCHASE OF THE PROPERTY, THE XXXXXXX MONEY MADE BY BUYER SHALL BE FORFEITED TO SELLER AS LIQUIDATED DAMAGES AND THE SOLE AND EXCLUSIVE REMEDY AVAILABLE TO SELLER FOR SUCH FAILURE. BY PLACING THEIR INITIALS BELOW, EACH PARTY SPECIFICALLY CONFIRMS THE ACCURACY OF THE STATEMENTS MADE ABOVE AND THE FACT THAT EACH PARTY WAS REPRESENTED BY COUNSEL WHO EXPLAINED, AT THE TIME THIS AGREEMENT WAS MADE, THE CONSEQUENCES OF THIS LIQUIDATED DAMAGES PROVISION. THIS SECTION 8.1 IS NOT INTENDED TO LIMIT SELLER’S RIGHTS UNDER SECTIONS 2.2, 2.3 AND 10.2 OF THIS AGREEMENT.

  • Default by Developer Developer shall be in default under this Agreement (a) Developer fails to make any of the payments of money required by the terms of this Agreement, and Developer fails to cure or remedy the same within ten (10) days after the City has given Developer written notice specifying such default; or (b) Developer fails to keep or perform any covenant or obligation herein contained on Developer's part to be kept or performed, and Developer fails to remedy the same within thirty (30) days after the City has given Developer written notice specifying such failure and requesting that it be remedied; provided, however, that if any event of default shall be such that it cannot be corrected within such period, it shall not constitute an event of default if corrective action is instituted by Developer within such period and diligently pursued until the default is corrected; or (c) Without limiting the generality of the foregoing, Developer shall assign or transfer the Project and/or this Agreement in violation of the terms and conditions set forth in Article V; or (d) Developer shall file a voluntary petition under any bankruptcy law or an involuntary petition under any bankruptcy law is filed against any such party in a court having jurisdiction and said petition is not dismissed within thirty (30) days or Developer, makes an assignment for the benefit of its creditors; or a custodian, trustee or receiver is appointed or retained to take charge of and manage any substantial part of the assets of Developer and such appointment is not dismissed within sixty (60) days; or any execution or attachment shall issue against Developer whereupon the District, or any part thereof, or any interest therein of Developer under this Agreement shall be taken and the same is not released prior to judicial sale thereunder (each of the events described in this subsection being deemed a default under the provisions of this Agreement); or (e) Developer breaches the representations and warranties set forth in this Agreement and fails to cure or correct same within thirty (30) days of notice from the City.

  • Default by Tenant 14.1 The following shall be deemed a default by Tenant under the terms of the Lease (“Event of Default”): a. The failure by Tenant to pay any rent or other sum of money due hereunder within ten (10) days after written notice from Landlord that such payment has not been made; b. The failure by Tenant to perform any other of the terms, conditions or covenants of this Lease to be observed or performed by Tenant for more than thirty (30) days after written notice from Landlord of such default, unless such default is of a nature that it cannot practicably be cured within a thirty (30) day period and Tenant is proceeding with due diligence to cure such default; c. The making by Tenant of an assignment for the benefit of creditors; d. The filing of a petition by or against Tenant for adjudication as a bankrupt under the Bankruptcy Act, as now or hereafter amended or supplemented, or for reorganization within the meaning of Chapter XI of the Bankruptcy Act, or the commencement of any action or proceeding for the dissolution or liquidation of Tenant, whether instituted by or against Tenant, or for the appointment of a receiver or trustee of the property of Tenant, provided that no such filing or proceeding instituted by a third party shall be regarded as a default hereunder if Tenant shall promptly move to have the same dismissed, rescinded or rendered inoperative and Tenant prosecutes such action with due diligence and continues to perform and discharge all of the covenants and obligations on its part to be performed or discharged under this Lease during the pendency of such proceedings. 14.2 Upon the occurrence of an Event of Default, Landlord shall have the immediate right of re-entry and possession of the Leased Premises, which right shall remain continuous until such time as Tenant shall have cured such Event of Default. Notwithstanding such re-entry and possession of the Leased Premises by Landlord, Tenant shall remain liable for the rent and other sums payable hereunder whether or not the Leased Premises are relet by Landlord an for all expenses which Landlord may incur in re-entering the Leased Premises and repairing and maintaining the same less such proceeds, if any, which may result from the reletting of the Leased Premises. 14.3 Additionally, upon the occurrence of any Event of Default, Landlord shall have the right to terminate this Lease by written notice of such intention to Tenant. In the event Landlord elects to terminate this Lease, Tenant’s liability for rent and other sums payable hereunder and to perform any other term, condition, covenant or agreement on its part to be performed under this Lease shall cease and terminate as to any period subsequent to the date on which Landlord delivers to Tenant written notice of such termination. Tenant shall remain liable, however, for all rent and the performance of all terms conditions and agreements relating to matters prior to the date of such termination. 14.4 Additionally, the parties agree that any default by the co-tenant, SenCer, Inc. can be treated by Landlord as a default by Tenant as though it was Tenant’s own default. Tenant will be given the opportunity to cure such default under the terms of this Agreement. Failure of Tenant to successfully cure said default shall give Landlord the right to implement any remedy authorized under the terms of this agreement.

  • Default by Lessee If Lessee fails to make payment of any Monthly Rental within five days of delivery by Lessor of notice of any Monthly Rental that is past due, or fails to cure any other default under this Agreement within ten days of delivery by Lessor of such default, then a “Lessee Event of Default” shall exist and Lessor shall have the following remedies, which shall be cumulative rather than exclusive: (a) the right to terminate this Agreement, and the grant of the Lease hereunder, which termination right may be exercised by written notice by Lessor to Lessee, and which termination shall be effective as of the date of such notice; (b) the right to immediately enter upon and repossess the Designated Boat Slip and all appurtenances thereto, by forcible entry and detainer suit, or otherwise; (c) the right to remove Lessee’s Craft (and any personal property then inside Lessee’s Craft from its mooring, and to store Lessee’s Craft (and such personal property), with all risk of loss belonging solely to Lessee, and with no liability whatsoever to Lessor, and with all costs of storage being deemed to be including among the past due Monthly Rental under this Agreement; (d) the right to make any required repairs to the Designated Boat Slip, or to expend any other sums required to cure any defaults by Lessee under this Agreement, with all such sums expended being deemed to be included among the past due Monthly Rental under this Agreement; (e) the right to terminate Lessee’s rights of possession with regard to the Designated Boat Slip and all appurtenances thereto, without demand or notice of any kind and without terminating this Agreement, in which event Lessor may, but shall be under no obligation to, relet all or any part of the Designated Boat Slip for credit to Lessee’s account, on such terms and conditions as Lessor in its sole discretion shall deem appropriate; and (f) the right to exercise Lessor’s rights under the Texas Uniform Commercial Code with regard to the security interest granted to Lessor in the Secured Property. In the event of any Lessee Event of Default, Lessor shall have the right to recover from Lessee, whether by way of sale of the Secured Property, or by means of execution and levy on a judgment, or by means of voluntary payment by Lessee, or by some combination thereof: (a) all Monthly Rental that is past due, including any late payment fees due in connection therewith, (b) all Monthly Rental to come due during the remainder of the Term (assuming that Lessor has not terminated this Agreement and the Lease hereunder), (c) Lessor’s reasonable and necessary attorneys’ fees and costs of court, (d) pre-judgment at the lesser of 8% per annum or the maximum allowed by law, and (e) post-judgment interest at lesser of 10% per annum or the maximum allowed by law.

  • Events of Default by Tenant If (1) Tenant abandons or surrenders all or any part of the Premises prior to the expiration of the Term of the Lease or (2) Tenant fails to pay Rent or Additional Rent within five (5) days after notice from Landlord of delinquency, (3) Tenant fails to fulfill any of the terms or conditions of this Lease or any other lease heretofore made by Tenant for space in the Premises and the same is not cured within thirty (30) days after written notice thereof from Landlord, unless the same cannot be cured within said thirty (30) day period, in which case Tenant shall have such additional time as is reasonably necessary to cure such default, not to exceed ninety (90) days in any and all events, provided that Tenant commences such cure within said thirty (30) day period and thereafter diligently prosecutes the same to completion, or (4) the appointment of a trustee or a receiver to take possession of all or substantially all of Tenant’s assets occurs, or if the attachment, execution or other judicial seizure of all or substantially all of Tenant’s assets located at the Premises, or of Tenant’s interest in this Lease, occurs, and in the case of an involuntary appointment only, the same is not dismissed within ninety (90) days from said appointment, or (5) Tenant or any of its successors or assigns or any guarantor of this Lease (“Guarantor”) should file any voluntary petition in bankruptcy, reorganization or arrangement, or an assignment for the benefit of creditors or for similar relief under any present or future statute, law or regulation relating to relief of debtors, or (6) Tenant or any of its successors or assigns or any Guarantor should be adjudicated bankrupt or have an involuntary petition in bankruptcy, reorganization or arrangement filed against it and the same not be dismissed within ninety (90) days of the date of the filing thereof, or (7) Tenant shall permit, allow or suffer to exist any lien, judgment, writ, assessment, charge, attachment or execution upon Landlord’s or to the Premises, and/or the fixtures, improvements and furnishings located thereon, except as otherwise permitted herein; then, Tenant shall be in default hereunder.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!