Common use of DELAY/DISRUPTION Clause in Contracts

DELAY/DISRUPTION. The Contractor shall coordinate the DO work effort with the Maintenance Team, on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less in duration. Minor delays and/or disruptions are considered normal rather than unusual occurrences during the performance of requirements ordered under this contract. If, during DO performance, delays greater than a minor delay indicated above are encountered, the Contractor shall immediately (verbally) notify the Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, and action taken to minimize impact.

DELAY/DISRUPTION. The Contractor shall coordinate the DO work effort with the Maintenance Team, Team on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight four (8) 4) hours or less in duration. Minor delays and/or disruptions are considered normal rather than unusual occurrences during the performance of requirements ordered under this contract. If, during DO performance, delays greater than a minor delay indicated above are encountered, the Contractor shall immediately (verbally) notify the Contracting OfficerOfficer and COR, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, and action taken to minimize impact.

DELAY/DISRUPTION. The Contractor shall coordinate the DO work effort with the Maintenance Team, on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight two (8) 2) hours or less in duration. Minor delays and/or disruptions are considered normal rather than unusual occurrences during the performance of requirements ordered under this contract. If, during DO performance, delays greater than a minor delay indicated above are encountered, the Contractor shall immediately (verbally) notify the Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, and action taken to minimize impact.