Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.
Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.
Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
Time limit for claims No Indemnified Party may make a Claim for indemnification under Section 6.1 in respect of any Claim unless notice in writing of the Claim, incorporating a statement setting out in reasonable detail the grounds on which the Claim is based, has been given by the Indemnified Party prior to the expiration of the applicable Survival Period as set forth in Part VI of Appendix B.
Infringement Claims You may submit an infringement claim notice to us at our Contact Formavailable here if you have a good faith belief that Your Content has been copied and made accessible through the Services (including as a part of the Service Content or Third Party Content) in violation of your Inte lectual Property Rights. A copyright infringement claims notice must include at (i) the identification of such a legedly infringing materials, including information su ficient for us to locate it within our Services, ( i) a demand that such a legedly infringing materials be removed or access disabled, ( i) a statement that you have a good faith belief that use of the material in the manner complained of is not authorized by the copyright owner, its agent, or the law; (iv) a statement that the information in the notification is accurate, and under penalty of perjury, that you are authorized to act on behalf of the owner of an exclusive right that is a legedly infringed; (v) contact information for you, such as address, phone number, and, if available, an email address; and (vi) must be signed by you or the person authorized to act on behalf of the owner of the a legedly infringed work (the “Notice Requirements”). Pursuant to 17 U.S.C. 512(c)(3), if the above Notice Requirements are not met, we may disregard the notice. Pursuant 17 U.S.C. 512(f), be advised that knowingly making a material misrepresentation that online material or activity is infringing or that material or activity was removed or disabled by mistake or misidentification, may subject you to heavy civil penalties. These penalties include monetary damages, including costs and attorneys' fees, incurred by the a leged infringer, by any copyright owner or copyright owner's authorized licensee, or by a service provider who is injured by your misrepresentation. If we make a decision to remove Your Content in response to a complaint, we may notify you and provide you with contact information for the complaining party. You may also object to such determination by writing to our designated agent, which must contain the fo lowing information pursuant to 17 U.S.C. 512(g)(3), (i) your physical or electronic signature; ( i) identification of the material that has been removed or to which access has been disabled and the location at which the material appeared before it was removed or access to it was disabled; ( i) a statement under penalty of perjury that the you have a good faith belief that the material was removed or disabled as a result of mistake or misidentification of the material to be removed or disabled; and (iv) your name, address, phone number, and a statement that you consent to the jurisdiction of Federal District Court for the judicial district in which the address is located, or if you are located outside of the United States, for any judicial district in which the service provider may be found, and that you wil accept service of process from the person who provided notification under subsection 17 U.S.C. 512(c)(1)(C) or an agent of such person.
Warranty Claims This Contractual Warranty is provided by Xxxxxxxxx Electric and covers defects in workmanship and materials in your Product. This warranty period lasts from the date of purchase at the point of sale to you, the original end user, unless otherwise agreed in writing (the "Warranty Period"). This Contractual Warranty is transferable to subsequent owners but only for the unexpired portion of the Warranty Period.
Claim of Infringement In the event that use of any facilities or equipment (including software), becomes, or in the reasonable judgment of the Party who owns the affected network is likely to become, the subject of a claim, action, suit, or proceeding based on intellectual property infringement, then said Party shall promptly and at its sole expense and sole option, but subject to the limitations of liability set forth below:
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
