Delays and Extensions. The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.
Delays and Extensions. The CONSULTANT agrees that no charges or claim for damages shall be made by him for any delays or hindrances from any cause whatsoever during the progress of any portion of the services specified in this Contract. Such delays or hindrances, if any, shall be compensated for by an extension of time for such period as may be determined by the LOCAL PUBLIC AGENCY in the exercise of its honest and reasonable judgement, it being understood, however, the permitting of the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LOCAL PUBLIC AGENCY of any or its rights herein.
Delays and Extensions. Delays or hindrances, that are not a result of CONSULTANT error, shall be compensated for by an extension of time for such periods as may be determined by mutual agreement of CONSULTANT and LOCAL PUBLIC AGENCY. Additional costs incurred due to the delay shall also be determined by mutual agreement of CONSULTANT and LOCAL PUBLIC AGENCY.
Delays and Extensions. The ENGINEER agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the services specified in this Agreement. Any such delays shall be compensated for by an extension of time for such period as may be determined by the OWNER, subject to the ENGINEER's approval. However, it being understood, that the permitting of the ENGINEER to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the OWNER of any of its rights herein.
Delays and Extensions. HWC agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the services specified in this Agreement. Any such delays shall be compensated for by an extension of time for such period as may be reasonably determined by the CLIENT, subject to HWC’s approval. However, it being understood, that the permitting of HWC to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the CLIENT of any of its rights herein.
Delays and Extensions. Time adjustment may occur when the negotiated scope of work is increased or reduced through mutual agreement of the State and the Consultant. Extensions of time may be granted for the following reasons:
a) Delays in major portions of the work caused by excessive time used in processing of submittals, delays caused by the State, or other similar items which are beyond the control of the Consultant.
b) Additional work ordered in writing by the Sponsor.
c) Department Design Standards have changed or expectations have changed from the time of negotiation.
Delays and Extensions. Time is of the essence concerning performance of this Contract; however, the CONSULTANT will be granted time extensions for delays beyond the CONSULTANT’s control. Time extensions will be equal to the length of the delay or as otherwise agreed upon in writing between the CONSULTANT and HCAOG.
Delays and Extensions. 8.1 Should circumstances arise which may cause a delay in, or deviation from, the performance by the service provider of its obligations under this agreement, the service provider shall:
8.1.1 take all reasonable steps to avoid or reduce the delay
8.1.2 provide the AGSA with immediate written notice of such circumstances and request an extension or condonation. Such written request shall fully set out the reasons for the anticipated delay and the anticipated time frame for the delays as well as the impact and deadlines of the deliverables as a whole.
8.2 The AGSA shall consider the request for extension or condonation, but shall be under no obligation to grant the request, except where the AGSA has contributed to or caused the delay.
Delays and Extensions a. Extensions of time may be granted for the following reasons:
i. Delays in major portions of the work caused by excessive time used in processing of submittals, delays caused by the State, or other similar items which are beyond the control of the Consultant.
ii. Additional work ordered in writing by the State.
b. Extensions of time will not be granted for the following reasons:
i. Underestimating complexity of work.
ii. Redoing work rejected by the State.
Delays and Extensions. The Consultant agrees that no change or claim for damages shall be made by if for any minor delays from any cause whatsoever during the progress of any portion of the services specified in the Agreement. Any such delays shall be compensated for by an extension of time for such period as may be determined by the City, subject to the Consultant’s approval. However, it being understood, that permitting the Consultant to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the City or any of its rights herein.
