File Management and Record Retention relating to CRF Eligible Persons or Households Grantee must maintain a separate file for every applicant, Eligible Person, or Household, regardless of whether the request was approved or denied. a. Contents of File: Each file must contain sufficient and legible documentation. Documents must be secured within the file and must be organized systematically.
CFR Part 200 or Federal Provision - Xxxx Anti-Lobbying Amendment - Continued If you answered "No, Vendor does not certify - Lobbying to Report" to the above attribute question, you must download, read, execute, and upload the attachment entitled "Disclosure of Lobbying Activities - Standard Form - LLL", as instructed, to report the lobbying activities you performed or paid others to perform. Compliance with all applicable standards, orders, or requirements issued under section 306 of the Clean Air Act (42 U.S.C. 1857(h)), section 508 of the Clean Water Act (33 U.S.C. 1368), Executive Order 11738, and Environmental Protection Agency regulations (40 CFR part 15). (Contracts, subcontracts, and subgrants of amounts in excess of $100,000) Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, ESC Region 8 and TIPS Members requires the proposer certify that in performance of the contracts, subcontracts, and subgrants of amounts in excess of $250,000, the vendor will be in compliance with all applicable standards, orders, or requirements issued under section 306 of the Clean Air Act (42 U.S.C. 1857(h)), section 508 of the Clean Water Act (33 U.S.C. 1368), Executive Order 11738, and Environmental Protection Agency regulations (40 CFR part 15). Does vendor certify compliance? Yes
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
No Construction as Employment Agreement Nothing contained in this Agreement shall be construed as giving Indemnitee any right to be retained in the employ of the Company or any of its subsidiaries.
How Are Contributions to a Xxxx XXX Reported for Federal Tax Purposes You must file Form 5329 with the IRS to report and remit any penalties or excise taxes. In addition, certain contribution and distribution information must be reported to the IRS on Form 8606 (as an attachment to your federal income tax return.)
Files Management and Record Retention relating to Grantee and Administration of this Agreement a. The Grantee shall maintain books, records, and documents in accordance with generally accepted accounting procedures and practices which sufficiently and properly reflect all expenditures of funds provided by Florida Housing under this Agreement. b. Contents of the Files: Grantee must maintain files containing documentation to verify all funds awarded to Grantee in connection with this Agreement, as well as reports, records, documents, papers, letters, computer files, or other material received, generated, maintained or filed by Grantee in connection with this Agreement. Grantee must also keep files, records, computer files, and reports that reflect any compensation it receives or will receive in connection with this Agreement.
Requirements Pertaining Only to Federal Grants and Subrecipient Agreements If this Agreement is a grant that is funded in whole or in part by Federal funds:
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
How Are Distributions from a Xxxx XXX Taxed for Federal Income Tax Purposes Amounts distributed to you are generally excludable from your gross income if they (i) are paid after you attain age 59½, (ii) are made to your beneficiary after your death, (iii) are attributable to your becoming disabled, (iv) subject to various limits, the distribution is used to purchase a first home or, in limited cases, a second or subsequent home for you, your spouse, or you or your spouse’s grandchild or ancestor, or (v) are rolled over to another Xxxx XXX. Regardless of the foregoing, if you or your beneficiary receives a distribution within the five-taxable-year period starting with the beginning of the year to which your initial contribution to your Xxxx XXX applies, the earnings on your account are includable in taxable income. In addition, if you roll over (convert) funds to your Xxxx XXX from another individual retirement plan (such as a Traditional IRA or another Xxxx XXX into which amounts were rolled from a Traditional IRA), the portion of a distribution attributable to rolled-over amounts which exceeds the amounts taxed in connection with the conversion to a Xxxx XXX is includable in income (and subject to penalty tax) if it is distributed prior to the end of the five-tax-year period beginning with the start of the tax year during which the rollover occurred. An amount taxed in connection with a rollover is subject to a 10% penalty tax if it is distributed before the end of the five-tax-year period. As noted above, the five-year holding period requirement is measured from the beginning of the five-taxable-year period beginning with the first taxable year for which you (or your spouse) made a contribution to a Xxxx XXX on your behalf. Previously, the law required that a separate five-year holding period apply to regular Xxxx XXX contributions and to amounts contributed to a Xxxx XXX as a result of the rollover or conversion of a Traditional IRA. Even though the holding period requirement has been simplified, it may still be advisable to keep regular Xxxx XXX contributions and rollover/ conversion Xxxx XXX contributions in separate accounts. This is because amounts withdrawn from a rollover/conversion Xxxx XXX within five years of the rollover/conversion may be subject to a 10% penalty tax. As noted above, a distribution from a Xxxx XXX that complies with all of the distribution and holding period requirements is excludable from your gross income. If you receive a distribution from a Xxxx XXX that does not comply with these rules, the part of the distribution that constitutes a return of your contributions will not be included in your taxable income, and the portion that represents earnings will be includable in your income. For this purpose, certain ordering rules apply. Amounts distributed to you are treated as coming first from your non-deductible contributions. The next portion of a distribution is treated as coming from amounts which have been rolled over (converted) from any non-Xxxx IRAs in the order such amounts were rolled over. Any remaining amounts (including all earnings) are distributed last. Any portion of your distribution which does not meet the criteria for exclusion from gross income may also be subject to a 10% penalty tax. Note that to the extent a distribution would be taxable to you, neither you nor anyone else can qualify for capital gains treatment for amounts distributed from your account. Similarly, you are not entitled to the special five- or ten- year averaging rule for lump-sum distributions that may be available to persons receiving distributions from certain other types of retirement plans. Rather, the taxable portion of any distribution is taxed to you as ordinary income. Your Xxxx XXX is not subject to taxes on excess distributions or on excess amounts remaining in your account as of your date of death. You must indicate on your distribution request whether federal income taxes should be withheld on a distribution from a Xxxx XXX. If you do not make a withholding election, we will not withhold federal or state income tax. Note that, for federal tax purposes (for example, for purposes of applying the ordering rules described above), Xxxx IRAs are considered separately from Traditional IRAs.
Conduct of Local Church Operations From the date of this Disaffiliation Agreement through and until the Closing, the Local Church: (a) will conduct its operations substantially in accordance with past practice and will use commercially reasonable efforts, subject to the foregoing, to maintain and preserve its operations and organization consistent with past practice and efficient and economical management, (b) will not take any action that is inconsistent with its charitable purposes under Section 501(c)(3) of the Code or that otherwise adversely affects its tax-exempt status, and (c) will not take any action that would cause its representations and warranties in this Disaffiliation Agreement not to remain true and correct as of Closing, except with the prior written consent of the Annual Conference.
