Design Document Preparation Sample Clauses

Design Document Preparation. Symbotic shall prepare and, no later than thirty (30) days prior to the Project SOW Date, provide to Walmart the drawings and specifications for the installation of the Modules at each applicable Project Site (all Site drawings and specifications for Work prepared by Symbotic, the “Design Documents”). Walmart shall have the opportunity to review and accept the Design Documents prior to execution of a Project SOW. Any Dispute relating to the Design Documents or the acceptance thereof shall be escalated to a representative appointed by each Party holding the title Vice President or higher and having the decision-making authority to resolve the Dispute on behalf of such party (“Senior Representatives”) with a goal of resolving such Dispute within ten (10) Business Days after either Party notifies the other of such Dispute. In the event that the Senior Representatives cannot resolve the Dispute within such time frame, the Parties shall engage in an expedited dispute resolution process pursuant to Section 17.2 (Expedited Arbitration). When providing the Design Documents to Walmart, Symbotic shall identify all material inconsistencies between the condition of each Site and the Design Documents other than latent defects or inconsistencies that a reasonable inspection would not have uncovered. In connection with such escalation, the Senior Representatives shall also determine the impact a delay on the finalization of the Design Document has had on the Project Time Schedule, if any, and whether any modifications to the Project Time Schedule are reasonably required due to such delay.
Sample 1
AutoNDA by SimpleDocs
Design Document Preparation. Engineer will provide engineering and supporting special services to bring the schematic designs for the recommended for Short-Range (Work Area C) and Longer- Range (Work Area G) treatments. Design efforts would include civil, structural and traffic engineering for the preparation of 30% Design, 60% Design, 90% Design and 100% Design drawing submittals for review by PCCA and other agencies as needed. Special services would include topographic survey, property boundary survey, and geotechnical testing and design.
Sample 1

Related to Design Document Preparation

  • Site Preparation Contractor shall not begin a project for which the site has not been prepared, unless Contractor does the preparation work at no cost, or until Region 4 ESC includes the cost of site preparation in a purchase order. Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre-installation requirements.

  • Joint Preparation The preparation of this Agreement has been a joint effort of the parties and the resulting documents shall not, solely as a matter of judicial construction, be construed more severely against one of the parties than the other.

  • Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

  • Selection of Architect/Construction Drawings Tenant shall retain the architect/space planner designated by Tenant and reasonably approved by Landlord (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.2. Tenant shall retain the engineering consultants selected by Tenant (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life safety, and sprinkler work in the Premises, which work is not part of the Base Building. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease shall specifically apply to the Construction Drawings.

  • Document Review The Company and the Executive hereby acknowledge and agree that each (i) has read this Agreement in its entirety prior to executing it, (ii) understands the provisions and effects of this Agreement, (iii) has consulted with such attorneys, accountants and financial and other advisors as it or he has deemed appropriate in connection with their respective execution of this Agreement, and (iv) has executed this Agreement voluntarily and knowingly.

  • Product Documentation You should review the policy documents carefully to ensure they accurately reflect the cover, conditions, limits, and other terms that you require. Particular attention should be paid to policy conditions and warranties as failure to comply with these could invalidate your policy. It is important that you retain and keep safely all documents associated with your policy so that you can refer to them in the event of a claim.

  • Costs of negotiation, preparation etc The Borrowers shall pay to the Agent on its demand the amount of all expenses incurred by the Agent or the Security Trustee in connection with the negotiation, preparation, execution or registration of any Finance Document or any related document or with any transaction contemplated by a Finance Document or a related document.

  • Appropriate Documentation The Company will have received, in a form and substance reasonably satisfactory to Company, dated the Closing Date, all certificates and other documents, instruments and writings to evidence the fulfillment of the conditions set forth in this Article 6 as the Company may reasonably request.

  • Document Imaging Investor shall be entitled, in its sole discretion, to image or make copies of all or any selection of the agreements, instruments, documents, and items and records governing, arising from or relating to any of Company’s loans, including, without limitation, this Agreement and the other Transaction Documents, and Investor may destroy or archive the paper originals. The parties hereto (i) waive any right to insist or require that Investor produce paper originals, (ii) agree that such images shall be accorded the same force and effect as the paper originals, (iii) agree that Investor is entitled to use such images in lieu of destroyed or archived originals for any purpose, including as admissible evidence in any demand, presentment or other proceedings, and (iv) further agree that any executed facsimile (faxed), scanned, emailed, or other imaged copy of this Agreement or any other Transaction Document shall be deemed to be of the same force and effect as the original manually executed document.

  • Required Documentation The AGENCY is responsible for ensuring that all documents required by this Contract are current and available for the COUNTY’S review upon request. These documents may include, but are not limited to, certificate(s) of insurance, job descriptions and background check confirmations of staff.

Time is Money Join Law Insider Premium to draft better contracts faster.