Design Professional Indemnification and Defense Obligations
Design Professional Indemnification and Defense Obligations Sample Clauses
Related to Design Professional Indemnification and Defense Obligations
Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. 16.2 To the furthest extent permitted by California law, Developer shall also defend Indemnitees, at its own expense, including but not limited to attorneys’ fees and costs, against all Claims caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Facilities Lease by Developer, its Subcontractors, vendors, or suppliers. However, without impacting Developer’s obligation to provide an immediate and ongoing defense of Indemnitees, Developer’s defense obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent caused by the sole negligence, active negligence, or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. The District shall have the right to accept or reject any legal representation that Xxxxxxxxx proposes to defend the Indemnitees. If any Indemnitee provides its own defense due to failure to timely respond to tender of defense, rejection of tender of defense, or conflict of interest of proposed counsel, Developer shall reimburse such Indemnitee for any expenditures. Developer’s defense obligation shall not be construed to negate, abridge, or otherwise reduce any right or obligation of defense that would otherwise exist as to any Indemnitee or other person described herein. Developer’s defense obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any provision of law, any failure or alleged failure to timely and properly fulfill all of its obligations under the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developer’s obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. Developer shall give prompt notice to the District in the event of any Claim(s). 16.3 Without limitation of the provisions herein, if Xxxxxxxxx’s obligation to indemnify and hold harmless the Indemnitees or its obligation to defend Indemnitees as provided herein shall be determined to be void or unenforceable, in whole or in part, it is the intention of the Parties that these circumstances shall not otherwise affect the validity or enforceability of Developer’s agreement to indemnify, defend, and hold harmless the rest of the Indemnitees, as provided herein. Further, Developer shall be and remain fully liable on its agreements and obligations herein to the fullest extent permitted by law.
Review of Indemnification Obligations (i) Notwithstanding the foregoing, in the event any Reviewing Party shall have determined (in a written opinion, in any case in which Independent Legal Counsel is the Reviewing Party) that Indemnitee is not entitled to be indemnified, exonerated or held harmless hereunder under applicable law, (A) the Company shall have no further obligation under Section 2(a) to make any payments to Indemnitee not made prior to such determination by such Reviewing Party and (B) the Company shall be entitled to be reimbursed by Indemnitee (who hereby agrees to reimburse the Company) for all Expenses theretofore paid in indemnifying, exonerating or holding harmless Indemnitee (within thirty (30) days after such determination); provided, however, that if Indemnitee has commenced or thereafter commences legal proceedings in a court of competent jurisdiction to secure a determination that Indemnitee is entitled to be indemnified, exonerated or held harmless hereunder under applicable law, any determination made by any Reviewing Party that Indemnitee is not entitled to be indemnified hereunder under applicable law shall not be binding and Indemnitee shall not be required to reimburse the Company for any Expenses theretofore paid in indemnifying, exonerating or holding harmless Indemnitee until a final judicial determination is made with respect thereto (as to which all rights of appeal therefrom have been exhausted or lapsed). Indemnitee’s obligation to reimburse the Company for any Expenses shall be unsecured and no interest shall be charged thereon. (ii) Subject to Section 2(b)(iii) below, if the Reviewing Party shall not have made a determination within forty-five (45) days after receipt by the Company of the request therefor, the requisite determination of entitlement to indemnification shall, to the fullest extent not prohibited by law, be deemed to have been made and Indemnitee shall be entitled to such indemnification, absent (A) a misstatement by Indemnitee of a material fact, or an omission of a material fact necessary to make Indemnitee’s statement not materially misleading, in connection with the request for indemnification or (B) a prohibition of such indemnification under applicable law; provided, however, that such 45-day period may be extended for a reasonable time, not to exceed an additional thirty (30) days, if the person, persons or entity making the determination with respect to entitlement to indemnification in good faith requires such additional time for the obtaining or evaluating of documentation and/or information relating thereto. (iii) Notwithstanding anything in this Agreement to the contrary, no determination as to entitlement of Indemnitee to indemnification under this Agreement shall be required to be made prior to the final disposition of the Claim.
Defense and Indemnification 12.1 Consultant agrees to indemnify, defend (with attorneys approved by City), and hold harmless the City, and its officers, officials, agents and employees (the “Indemnified Parties”) from any and all claims, demands, costs or liability that arise out of, or pertain to, or relate to the Consultant, its employees, agents, and subcontractors performance of services under this Agreement. Consultant’s duty to indemnify under this section shall not include liability for damages for death or bodily injury to persons, injury to property, or other loss, damage or expense arising from the sole negligence or willful misconduct by the City or its elected officials, officers, agents, and employees. Consultant's indemnification obligations shall not be limited by the insurance provisions of this Agreement. The Parties expressly agree that any payment, attorney's fees, costs or expense City incurs or makes to or on behalf of an injured employee under the City's self-administered workers' compensation is included as a loss, expense, or cost for the purposes of this section, and that this section will survive the expiration or early termination of this Agreement. 12.2 This indemnity is in addition to any other rights or remedies which City may have under the law or this Agreement. In the event of any claim or demand made against any party which is entitled to be indemnified hereunder, City may, at its sole discretion, reserve, retain or apply any monies due to Consultant under this Agreement for the purpose of resolving such claims; provided however, that City may release such funds if Consultant provides City with reasonable assurances of protection of the City's interest. The City shall, in its sole discretion determine whether such assurances are reasonable. 12.3 Consultant agrees that its duty to defend arises upon an allegation of liability based upon the performance of services under this Agreement by Consultant, its officers, agents, representatives, employees, sub-consultants, or anyone for whom Consultant is liable and that an adjudication of Consultant’s liability is not a condition precedent to Consultant's duty to defend.
LEGAL INDEMNIFICATION For the purposes of legal costs, it shall include those costs of an Association approved para-legal service. (A) Subject to the other provisions of this Article, a member charged with and finally acquitted of a criminal or statutory offence because of acts done in the performance or attempted performance of his employment or duties, shall be indemnified for the necessary and reasonable legal costs incurred in the defence of such charges. (B) Members shall not be indemnified for legal costs arising from the actions or omissions of members acting in their capacity as private citizens. For the purpose of Clause 29.1 (A) a Member: shall be deemed to have been "Finally Acquitted", where charges are withdrawn or where he is discharged following a preliminary inquiry; and shall be deemed not to have been "Finally Acquitted" where the member is given an absolute or conditional discharge or where, if as a result of charges laid he is subsequently found guilty of, or pleads guilty to, other charges arising out of the same incident or incidents. 29.2 When a member is a defendant in a civil action for damages because of acts done in the course of his employment or duties he shall be indemnified for the necessary and reasonable legal costs incurred in the defence of such an action in the following circumstances only: (i) where the Board is not joined in the action as a party pursuant to s. 50 of the Police Services Act, and the Board does not defend the action on behalf of itself and the member as joint tortfeasors at the Board's sole expense; (ii) where the Board is joined as a party or elects to defend the action, but the Solicitor retained on behalf of the Board and the member is of the view that it would be improper for him to act for both the Board and the member in that action. 29.3 Where during an inquest under the Coroner's Act a member's conduct is called into question because of acts done in the performance of his duties, the member shall be indemnified for any necessary and reasonable legal costs directly arising from the protection of the member's interest at such inquiry, but only if: (i) the Chief of Police or the Board does not provide counsel to represent the York Regional Police, at the Board's expense; or (ii) in the opinion of counsel retained by the Chief of Police or the Board to represent the York Regional Police, it would be improper for him to represent the member and the Chief and/or the Board before that inquiry. 29.4 To qualify for financial assistance under 29.1, 29.2 or 29.3, the member shall obtain the Board's approval of counsel to be retained by the member by application to the Board through the Chief. The Board's approval of counsel shall not be withheld unreasonably. 29.5 The Board will not consider any application for financial assistance which relates to the legal representation of a member in connection with a grievance or complaint made under the provisions of the Police Services Act, 1990 of this Collective Agreement or for the legal defence of a member resulting from a discipline charge made under the Police Services Act, 1990, Regulations made under that Act and all amendments thereto. 29.6 Where an investigation is commenced under Part VII of the Police Services Act and it appears to the Chief of Police that a member requires legal counsel in responding to the investigation, the Chief of Police may arrange for legal counsel to provide counsel to the member in connection with the investigation of such terms as the Chief considers appropriate. As soon as practicable, the Chief shall bring his action and his recommendation to the attention of the Board who may approve or alter the terms of retention of such legal counsel or the Chief's recommendation in respect thereof. Neither the Board nor the Chief shall provide legal counsel after the completion of the investigation or the laying of information(s), as Article 29 of the Civilian Collective Agreement is intended to govern such matters. 29.7 All sections under Article 29 (Legal Indemnification) are subject to review and re- negotiation by either the Board or the Association when the Regulations of the Police Services Act are proclaimed in force. If changes cannot be negotiated then either party reserves the right to submit the terms of this Article to arbitration. 29.8 A member who becomes involved in a matter which may entitle him/her to legal indemnification under this clause is entitled to receive funds from the Board for a retainer and/or for interim payment of legal costs as reasonably requested by the member’s counsel to a maximum of $5,000.00 provided the member undertakes to indemnify the Board for such funds advanced to him if the member is finally determined not to be eligible for indemnification in accordance with this Agreement.
Indemnification Claims An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall promptly furnish the Controlling Party with such information as it may have or receive with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. The fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (x) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 5.3 or (y) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
Additional Indemnification (a) Notwithstanding any limitation in Sections 3, 4, or 5, the Company shall indemnify Indemnitee to the fullest extent permitted by applicable law if Indemnitee is a party to or threatened to be made a party to any Proceeding (including a Proceeding by or in the right of the Company to procure a judgment in its favor) against all Expenses, judgments, fines and amounts paid in settlement actually and reasonably incurred by Indemnitee in connection with the Proceeding. (b) For purposes of Section 7(a), the meaning of the phrase “to the fullest extent permitted by applicable law” shall include, but not be limited to: i. to the fullest extent permitted by the provision of the DGCL that authorizes or contemplates additional indemnification by agreement, or the corresponding provision of any amendment to or replacement of the DGCL, and ii. to the fullest extent authorized or permitted by any amendments to or replacements of the DGCL adopted after the date of this Agreement that increase the extent to which a corporation may indemnify its officers and directors.
Indemnification Process 20.2.1 As used in this Section 20, “Indemnified Person” means a person whom an Indemnifying Party is obligated to indemnify, defend and/or hold harmless under Section 20.1. 20.2.2 An Indemnifying Party’s obligations under Section 20.1 shall be conditioned upon the following:
Successful Defense; Partial Indemnification To the extent that Indemnitee has been successful on the merits or otherwise in defense of any action, suit or proceeding referred to in Section 1 hereof or in defense of any claim, issue or matter therein, Indemnitee shall be indemnified against expenses (including attorneys’ fees) actually and reasonably incurred in connection therewith. For purposes of this Agreement and without limiting the foregoing, if any action, suit or proceeding is disposed of, on the merits or otherwise (including a disposition without prejudice), without (i) the disposition being adverse to Indemnitee, (ii) an adjudication that Indemnitee was liable to the Corporation, (iii) a plea of guilty or nolo contendere by Indemnitee, (iv) an adjudication that Indemnitee did not act in good faith and in a manner Indemnitee reasonably believed to be in or not opposed to the best interests of the Corporation, and (v) with respect to any criminal proceeding, an adjudication that Indemnitee had reasonable cause to believe Indemnitee’s conduct was unlawful, Indemnitee shall be considered for the purposes hereof to have been wholly successful with respect thereto. If Indemnitee is entitled under any provision of this Agreement to indemnification by the Corporation for some or a portion of the expenses (including attorneys’ fees), judgments, fines or amounts paid in settlement actually and reasonably incurred by Indemnitee or on Indemnitee’s behalf in connection with any action, suit, proceeding or investigation, or in defense of any claim, issue or matter therein, and any appeal therefrom but not, however, for the total amount thereof, the Corporation shall nevertheless indemnify Indemnitee for the portion of such expenses (including attorneys’ fees), judgments, fines or amounts paid in settlement to which Indemnitee is entitled.
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
