Payments to the Distributor In consideration of the payments made by the Fund to the Distributor under this Plan, the Distributor shall provide administrative support services and distribution assistance services to the Fund. Such services include distribution assistance and administrative support services rendered in connection with Shares (1) sold in purchase transactions, (2) issued in exchange for shares of another investment company for which the Distributor serves as distributor or sub-distributor, or (3) issued pursuant to a plan of reorganization to which the Fund is a party. If the Board believes that the Distributor may not be rendering appropriate distribution assistance or administrative support services in connection with the sale of Shares, then the Distributor, at the request of the Board, shall provide the Board with a written report or other information to verify that the Distributor is providing appropriate services in this regard. For such services, the Fund will make the following payments to the Distributor:
Certain Reimbursements to the Servicer The Servicer will be entitled to be reimbursed from amounts on deposit in the Collection Account with respect to a Collection Period for amounts previously deposited in the Collection Account but later determined by the Servicer to have resulted from mistaken deposits or postings or checks returned for insufficient funds. The amount to be reimbursed hereunder shall be paid to the Servicer on the related Distribution Date pursuant to Section 5.7(a)(i) upon certification by the Servicer of such amounts and the provision of such information to the Trust Collateral Agent. The Servicer will additionally be entitled to receive from amounts on deposit in the Collection Account with respect to a Collection Period any amounts paid by Obligors that were deposited in the Lockbox Account but that do not relate to (i) principal and interest payments due on the Receivables and (ii) any fees or expenses related to extensions due on the Receivables.
REIMBURSEMENT TO THE ADVISOR The Company shall not reimburse the Advisor for Total Operating Expenses to the extent that Total Operating Expenses (including the Asset Management Fee), in the four consecutive fiscal quarters then ended (the “Expense Year”) exceed (the “Excess Amount”) the greater of 2% of Average Invested Assets or 25% of Net Income for that period of four consecutive fiscal quarters. Any Excess Amount paid to the Advisor during a fiscal quarter shall be repaid to the Company. Reimbursement of all or any portion of the Total Operating Expenses that exceed the limitation set forth in the preceding sentence may, at the option of the Advisor, be deferred without interest and may be reimbursed in any subsequent Expense Year where such limitation would permit such reimbursement if the Total Operating Expense were incurred during such period. Notwithstanding the foregoing, if there is an Excess Amount in any Expense Year and the Independent Directors determine that all or a portion of such excess was justified, based on unusual and nonrecurring factors which they deem sufficient, the Excess Amount may be reimbursed to the Advisor. If the Independent Directors determine such excess was justified, then, after the end of any fiscal quarter of the Company for which there is an Excess Amount for the 12 months then ended paid to the Advisor, the Advisor, at the direction of the Independent Directors, shall cause such fact to be disclosed in the next quarterly report of the Company or in a separate writing and sent to the Stockholders within 60 days of such quarter end, together with an explanation of the factors the Independent Directors considered in determining that such Excess Amount was justified. Such determination shall be reflected in the minutes of the meetings of the Board. The Company will not reimburse the Advisor or its Affiliates for services for which the Advisor or its Affiliates are entitled to compensation in the form of a separate fee. All figures used in any computation pursuant to this Section 3.04 shall be determined in accordance with generally accepted accounting principles applied on a consistent basis.
Payments to the Company Except as provided in Section 3 hereof, after the Trust has become irrevocable, the Company shall have no right or power to direct the Trustee to return to the Company or to divert to others any of the Trust assets before all payments of benefits have been made to Plan participants and their beneficiaries pursuant to the terms of the Plans.
Distribution of Reports to the Trustee and the Company; Advances by the Master Servicer (a) Prior to the close of business on the Determination Date, the Master Servicer shall furnish a written statement to the Trustee, any Certificate Insurer, any Paying Agent and the Company (the information in such statement to be made available to Certificateholders by the Master Servicer on request) setting forth (i) the Available Distribution Amount and (ii) the amounts required to be withdrawn from the Custodial Account and deposited into the Certificate Account on the immediately succeeding Certificate Account Deposit Date pursuant to clause (iii) of Section 4.01(a). The determination by the Master Servicer of such amounts shall, in the absence of obvious error, be presumptively deemed to be correct for all purposes hereunder and the Trustee shall be protected in relying upon the same without any independent check or verification. (b) On or before 2:00 P.M. New York time on each Certificate Account Deposit Date, the Master Servicer shall either (i) deposit in the Certificate Account from its own funds, or funds received therefor from the Subservicers, an amount equal to the Advances to be made by the Master Servicer in respect of the related Distribution Date, which shall be in an aggregate amount equal to the aggregate amount of Monthly Payments (with each interest portion thereof adjusted to the Net Mortgage Rate), less the amount of any related Servicing Modifications, Debt Service Reductions or reductions in the amount of interest collectable from the Mortgagor pursuant to the Soldiers' and Sailors' Civil Relief Act of 1940, as amended, or similar legislation or regulations then in effect, on the Outstanding Mortgage Loans as of the related Due Date, which Monthly Payments were not received as of the close of business as of the related Determination Date; provided that no Advance shall be made if it would be a Nonrecoverable Advance, (ii) withdraw from amounts on deposit in the Custodial Account and deposit in the Certificate Account all or a portion of the Amount Held for Future Distribution in discharge of any such Advance, or (iii) make advances in the form of any combination of (i) and (ii) aggregating the amount of such Advance. Any portion of the Amount Held for Future Distribution so used shall be replaced by the Master Servicer by deposit in the Certificate Account on or before 11:00 A.M. New York time on any future Certificate Account Deposit Date to the extent that funds attributable to the Mortgage Loans that are available in the Custodial Account for deposit in the Certificate Account on such Certificate Account Deposit Date shall be less than payments to Certificateholders required to be made on the following Distribution Date. The Master Servicer shall be entitled to use any Advance made by a Subservicer as described in Section 3.07(b) that has been deposited in the Custodial Account on or before such Distribution Date as part of the Advance made by the Master Servicer pursuant to this Section 4.04. The amount of any reimbursement pursuant to Section 4.02(a) in respect of outstanding Advances on any Distribution Date shall be allocated to specific Monthly Payments due but delinquent for previous Due Periods, which allocation shall be made, to the extent practicable, to Monthly Payments which have been delinquent for the longest period of time. Such allocations shall be conclusive for purposes of reimbursement to the Master Servicer from recoveries on related Mortgage Loans pursuant to Section 3.10. The determination by the Master Servicer that it has made a Nonrecoverable Advance or that any proposed Advance, if made, would constitute a Nonrecoverable Advance, shall be evidenced by an Officers' Certificate of the Master Servicer delivered to the Company and the Trustee. If the Master Servicer determines as of the Business Day preceding any Certificate Account Deposit Date that it will be unable to deposit in the Certificate Account an amount equal to the Advance required to be made for the immediately succeeding Distribution Date, it shall give notice to the Trustee of its inability to advance (such notice may be given by telecopy), not later than 3:00 P.M., New York time, on such Business Day, specifying the portion of such amount that it will be unable to deposit. Not later than 3:00 P.M., New York time, on the Certificate Account Deposit Date the Trustee shall, unless by 12:00 Noon, New York time, on such day the Trustee shall have been notified in writing (by telecopy) that the Master Servicer shall have directly or indirectly deposited in the Certificate Account such portion of the amount of the Advance as to which the Master Servicer shall have given notice pursuant to the preceding sentence, pursuant to Section 7.01, (a) terminate all of the rights and obligations of the Master Servicer under this Agreement in accordance with Section 7.01 and (b) assume the rights and obligations of the Master Servicer hereunder, including the obligation to deposit in the Certificate Account an amount equal to the Advance for the immediately succeeding Distribution Date. The Trustee shall deposit all funds it receives pursuant to this Section 4.04 into the Certificate Account.
Reports to the Trust The Adviser shall prepare and furnish to the Trust such reports, statistical data and other information in such form and at such intervals as the Trust may reasonably request.
Delivery of Documents to the Investment Manager The Sub-Adviser has furnished the Investment Manager with true, correct and complete copies of each of the following documents: (a) The Sub-Adviser's Form ADV as filed with the Securities and Exchange Commission as of the date hereof; (b) The Sub-Adviser's most recent balance sheet; (c) Separate lists of persons who the Sub-Adviser wishes to have authorized to give written and/or oral instructions to Custodians of Company assets for the Fund; and (d) The Code of Ethics of the Sub-Adviser, as in effect on the date hereof. The Sub-Adviser will furnish the Investment Manager from time to time with copies, properly certified or otherwise authenticated, of all amendments of or supplements to the foregoing, if any. Such amendments or supplements will be provided within 30 days of the time such materials become available to the Sub-Adviser. Any amendments or supplements to the foregoing will not be deemed effective with respect to the Investment Manager until the Investment Manager's receipt thereof. The Sub-Adviser will provide additional information as the Investment Manager may reasonably request in connection with the Sub-Adviser's performance of its duties under this Agreement.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
DELIVERY OF DOCUMENTS TO THE ADVISER The Sub-Adviser has furnished, and in the future will furnish, the Adviser with true, correct and complete copies of each of the following documents: (a) The Sub-Adviser's most recent Form ADV; (b) The Sub-Adviser's most recent balance sheet; and (c) The current Code of Ethics of the Sub-Adviser, adopted pursuant to Rule 17j-1 under the 1940 Act, and annual certifications regarding compliance with such Code. In addition, the Sub-Adviser will furnish the Adviser with (i) a summary of the results of any future examination of the Sub-Adviser by the Commission or other regulatory agency with respect to the Sub-Adviser's activities hereunder; and (ii) copies of its policies and procedures adopted pursuant to Rule 206(4)-7 under the Advisers Act. The Sub-Adviser will furnish the Adviser with all such documents as soon as practicable after such documents become available to the Sub-Adviser, to the extent that such documents have been changed materially. The Sub-Adviser shall furnish the Adviser with any further documents, materials or information as the Adviser may reasonably request in connection with Sub-Adviser's performance of its duties under this Agreement, including, but not limited to, information regarding the Sub-Adviser's financial condition, level of insurance coverage and any certifications or sub-certifications which may reasonably be requested in connection with Fund registration statements, Form N-CSR filings or other regulatory filings, and which are appropriately limited to Sub-Adviser's responsibilities under this Agreement.
Payments to the Agent (a) On each date on which an Obligor or a Lender is required to make a payment under a Finance Document, that Obligor or Lender shall make the same available to the Agent (unless a contrary indication appears in a Finance Document) for value on the due date at the time and in such funds specified by the Agent as being customary at the time for settlement of transactions in the relevant currency in the place of payment. (b) Payment shall be made to such account in the principal financial centre of the country of that currency with such bank as the Agent specifies.
