Common use of Disputes; Venue Clause in Contracts

Disputes; Venue. Any dispute will be referred to Company’s Director for Supply Management and an officer of Contractor for resolution. If Company and Contractor cannot reach an agreement within a reasonable time, Company and Contractor will have the right to pursue litigation. If litigation is initiated to enforce or interpret any term of this Agreement, the Parties agree that (a) the action will be brought in the Superior Court of the County of San Diego, California (or, if the federal courts have exclusive jurisdiction over the subject matter of the dispute, in the U.S. District Court for the Southern District of California), and the Parties submit to the exclusive jurisdiction of said court, and (b) unless Company provides Notice to Contractor to the contrary, in no event will the litigation of any controversy or the settlement thereof delay the performance of this Agreement.

Disputes; Venue. Any dispute will be referred to Company’s Director for Supply Management and an officer of Contractor for resolution. If Company and Contractor cannot reach an agreement within a reasonable time, Company and Contractor will have the right to pursue litigation. If litigation is initiated to enforce or interpret any term of this Agreement, the Parties agree that (a) the action will be brought in the Superior Court of the County of San Diego[Los Angeles], California (or, if the federal courts have exclusive jurisdiction over the subject matter of the dispute, in the U.S. District Court for the Southern [Central] District of California), and the Parties submit to the exclusive jurisdiction of said court, and (b) unless Company provides Notice to Contractor to the contrary, in no event will the litigation of any controversy or the settlement thereof delay the performance of this Agreement.