During the Construction Phase Sample Clauses

During the Construction Phase the Owner shall furnish information or services required of the Owner by the Contract Documents with reasonable promptness. The Owner shall also furnish any other information or services under the Owner’s control and relevant to the Construction Manager’s performance of the Work with reasonable promptness after receiving the Construction Manager’s written request for such information or services.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
During the Construction Phase the Construction Manager shall employ at a minimum on a full time basis a site based superintendent, together with such additional superintendence, project management, engineering and clerical support as may be reasonably required and appropriate to the stage of construction (as per the Construction Manager Designated Services and Method of Payment, Exhibit A). The Superintendent and Project Manager shall not be changed except with the consent of the Principal Representative, unless the Superintendent or Project Manager proves to be unsatisfactory to the Construction Manager or ceases to be in its employ. The Construction Manager shall employ the services of at least one person fully qualified and with a minimum of 5 years experience in critical path scheduling on projects of similar size and scope for the duration of the Work.
Sample 1Sample 2Sample 3See All (6)
During the Construction Phase of the Project, the District may require that the contractors submit all notices and communication relating to the Project directly to the Program Manager.
Sample 1Sample 2
During the Construction Phase. SCHEDULE LIMITS Workers’ Compensation Florida Statutory Coverage Commercial General Liability $2,000,000. General Aggregate ......................................................... $1,000,000. Personal/Advertising Injury .......................................................... $1,000,000. Each Occurrence (The County of Volusia shall be named as an additional insured under all of the above Commercial General Liability coverage.) Auto Liability $1,000,000. CSL
Sample 1
During the Construction Phase the ARCHITECT shall 1.4.1 Arrange and attend Preconstruction conference(s). 1.4.2 Reject work that does not conform to the contract documents. The ARCHITECT will not guarantee the performance of the contractor. 1.4.3 Consult and advise the OWNER and issue all instructions in regard to the contract documents to the contractor(s) requested by the OWNER. 1.4.4 Prepare change orders with supporting documentation and data as necessary for the OWNER’S approval and execution in accordance with the contract documents, and may authorize minor changes in the work not involving an adjustment in the contract sum or an extension of the contract time which is not inconsistent with the intent of the contract documents. 1.4.5 Review and approve contractor’s submittals such as shop drawings, product data and samples, but only for the purpose of checking for conformance with information given and the design concept expressed in the contract documents. The ARCHITECT’S action shall be taken with such reasonable promptness as to cause no delay in the work or in the construction of the OWNER or of separate contractors, while allowing sufficient time in the ARCHITECT’S professional judgment to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities or for substantiating instructions for installation or performance of equipment or systems designed by the contractor, all of which remain the responsibility of the contractor to the extent required by the contract documents. The ARCHITECT’S review shall not constitute approval of safety precautions or, unless otherwise specified by the ARCHITECT of construction methods, techniques, means, sequences or procedures. The ARCHITECT approval of a specific item shall not indicate approval of an assembly of which the item is a component. When professional certification of performance characteristics of materials, systems or equipment is required by the contract documents, the ARCHITECT shall be entitled to rely upon such certification to establish that the materials, systems or equipment will meet the performance criteria required by the contract documents. 1.4.6 Provide the contractor(s) with two copies and the OWNER with one copy of all reviewed submittals, shop drawings, laboratory tests, and samples. 1.4.7 Based upon the ARCHITECT’S observations and best knowledge of evaluations of the contractor’s applications for p...
Sample 1
During the Construction Phase the Architect progress payments shall use a percentage of completion of the Project construction that does not exceed the percentage as is reflected on the current certified Contractor’s
Sample 1

Related to During the Construction Phase

  • Pre-Construction Phase Employer’s Liability, Workers’ Compensation, Comprehensive General Liability and Comprehensive Automobile Liability in the amounts as set forth in the UGSC.

  • PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement. 6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services. 6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards. 6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal. 6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows: 6.4.1 A pre-established lump sum amount; or 6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or 6.4.3 As otherwise agreed in advance and in writing.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Construction Phase Part 1 –

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!