Duty to Collect and Update Sample Clauses

Duty to Collect and Update. During the Term, comScore shall continuously collect, produce and update the comScore Data.
Sample 1Sample 2

Related to Duty to Collect and Update

  • Duty to Correct During the one year period of the warranty and guaranty, any defects of material or workmanship that become apparent shall be the responsibility of the Contractor until and unless the Contractor can show abuse or design defect. The Contractor shall immediately correct all defects that become known during the one year period at no cost to the Owner unless notice is given to the Design Professional, Owner and Using Agency, prior to correcting the defect that the cause of the defect is the result of abuse or design deficiency.

  • Duty to Cooperate If the Parties disagree on any aspect of the proposed Motion for Preliminary Approval and/or the supporting declarations and documents, Class Counsel and Defense Counsel will expeditiously work together on behalf of the Parties by meeting in person or by telephone, and in good faith, to resolve the disagreement. If the Court does not grant Preliminary Approval or conditions Preliminary Approval on any material change to this Agreement, Class Counsel and Defense Counsel will expeditiously work together on behalf of the Parties by meeting in person or by telephone, and in good faith, to modify the Agreement and otherwise satisfy the Court’s concerns.

  • Limitation on Duty to Collect Custodian shall not be required to enforce collection, by legal means or otherwise, of any money or property due and payable with respect to Securities held for the Fund if such Securities are in default or payment is not made after due demand or presentation.

  • Right to Request and Act on Instructions Agent may at any time request instructions from Lenders with respect to any actions or approvals which by the terms of this Agreement or of any of the Financing Documents Agent is permitted or desires to take or to grant, and if such instructions are promptly requested, Agent shall be absolutely entitled to refrain from taking any action or to withhold any approval and shall not be under any liability whatsoever to any Person for refraining from any action or withholding any approval under any of the Financing Documents until it shall have received such instructions from Required Lenders or all or such other portion of the Lenders as shall be prescribed by this Agreement. Without limiting the foregoing, no Lender shall have any right of action whatsoever against Agent as a result of Agent acting or refraining from acting under this Agreement or any of the other Financing Documents in accordance with the instructions of Required Lenders (or all or such other portion of the Lenders as shall be prescribed by this Agreement) and, notwithstanding the instructions of Required Lenders (or such other applicable portion of the Lenders), Agent shall have no obligation to take any action if it believes, in good faith, that such action would violate applicable Law or exposes Agent to any liability for which it has not received satisfactory indemnification in accordance with the provisions of Section 11.6.

  • Duty to Inform Lessor If Lessee knows, or has reasonable cause to believe, that a Hazardous Substance has come to be located in, on, under or about the Premises, other than as previously consented to by Lessor, Lessee shall immediately give written notice of such fact to Lessor, and provide Lessor with a copy of any report, notice, claim or other documentation which it has concerning the presence of such Hazardous Substance.

  • CUSTOMER REMEDIES 5.1. If the Supplier (a) fails to deliver the Goods and/or the Goods do not comply with any of the undertakings or warranties set out in clause 2 and/or (b) fails to deliver and/or perform the Services in accordance with any of the warranties or undertakings contained in clause 4 and/or by the applicable date(s), the Customer shall, without limiting or affecting other rights or remedies available to it, have one or more of the following rights to: 5.1.1. terminate the Agreement with immediate effect by giving written notice to the Supplier; 5.1.2. reject the Goods (in whole or in part) whether or not title has passed and to return them to the Supplier at the Supplier’s own risk and expense; 5.1.3. require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods; 5.1.4. require Supplier to re-perform, rectify or replace the affected Services and/or Deliverables; 5.1.5. refuse to accept any subsequent performance of the Services and/or delivery of the Goods which the Supplier attempts to make; 5.1.6. recover from the Supplier any costs incurred by the Customer in obtaining substitute goods and/or services from a third party; 5.1.7. require a refund from the Supplier of sums paid in advance for Services that the Supplier has not provided and/or Goods that it has not delivered; and 5.1.8. claim damages for any additional costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier’s breach. 5.2. Notwithstanding any other rights or remedies available to Customer if the Goods are not delivered by the applicable date, the Customer may, at its option, claim or deduct 3% of the price of the Goods for each week’s delay in delivery, up to a maximum of 15% of the total price of the Goods. In the event such delay continues for six (6) weeks or more, Customer may terminate the Agreement with immediate effect upon given Supplier written notice. 5.3. These Terms shall extend to any substituted or remedial services and/or repaired or replacement goods supplied by the Supplier. 5.4. The Customer’s rights under the Agreement are in addition to its rights and remedies implied by statute and common law.

  • Notification of Breach / Compliance Reports The Adviser shall notify the Trust immediately upon detection of (i) any material failure to manage any Fund in accordance with its investment objectives and policies or any applicable law; or (ii) any material breach of any of the Funds’ or the Adviser’s policies, guidelines or procedures. In addition, the Adviser shall provide a quarterly report regarding each Fund’s compliance with its investment objectives and policies, applicable law, including, but not limited to the 1940 Act and Subchapter M of the Code, as applicable, and the Fund’s policies, guidelines or procedures as applicable to the Adviser’s obligations under this Agreement. The Adviser agrees to correct any such failure promptly and to take any action that the Board may reasonably request in connection with any such breach. Upon request, the Adviser shall also provide the officers of the Trust with supporting certifications in connection with such certifications of Fund financial statements and disclosure controls pursuant to the Xxxxxxxx-Xxxxx Act. The Adviser will promptly notify the Trust in the event (i) the Adviser is served or otherwise receives notice of any action, suit, proceeding, inquiry or investigation, at law or in equity, before or by any court, public board, or body, involving the affairs of the Trust (excluding class action suits in which a Fund is a member of the plaintiff class by reason of the Fund’s ownership of shares in the defendant) or the compliance by the Adviser with the federal or state securities laws or (ii) an actual change in control of the Adviser resulting in an “assignment” (as defined in the 0000 Xxx) has occurred or is otherwise proposed to occur.

  • Waiver of Right to Contest Liens (a) The New First Lien Collateral Agent, for and on behalf of itself and the New First Lien Secured Parties, agrees that it shall not (and hereby waives any right to) take any action to contest or challenge (or assist or support any other Person in contesting or challenging), directly or indirectly, whether or not in any proceeding (including in any Insolvency Proceeding), the validity, priority, enforceability, or perfection of the Liens of the ABL Collateral Agent and the ABL Secured Parties in respect of Receivables Collateral or the provisions of this Agreement. Except to the extent expressly set forth in this Agreement, the New First Lien Collateral Agent, for itself and on behalf of the New First Lien Secured Parties, agrees that it will not take any action that would interfere with any Exercise of Secured Creditor Remedies undertaken by the ABL Collateral Agent or any ABL Secured Party under the ABL Documents with respect to the Common Collateral. Except to the extent expressly set forth in this Agreement, the New First Lien Collateral Agent, for itself and on behalf of the New First Lien Secured Parties, hereby waives any and all rights it may have as a junior lien creditor or otherwise to contest, protest, object to, or interfere with the manner in which the ABL Collateral Agent or any ABL Secured Party seeks to enforce its Liens in any Common Collateral. (b) The ABL Collateral Agent, for and on behalf of itself and the ABL Secured Parties, agrees that it and they shall not (and hereby waives any right to) take any action to contest or challenge (or assist or support any other Person in contesting or challenging), directly or indirectly, whether or not in any proceeding (including in any Insolvency Proceeding), the validity, priority, enforceability, or perfection of the respective Liens of the New First Lien Collateral Agent or the New First Lien Secured Parties in respect of the Common Collateral or the provisions of this Agreement.

  • No Duty to Confirm The Relevant Trustee shall have no duty or obligation to verify or confirm the accuracy of any of the information or numbers set forth in the Servicer’s Certificate delivered by the Servicer to the Relevant Trustee, and the Relevant Trustee shall be fully protected in relying upon such Servicer’s Certificate.

  • Waiver of Right to Trial by Jury EACH PARTY TO THIS AGREEMENT HEREBY EXPRESSLY WAIVES ANY RIGHT TO TRIAL BY JURY OF ANY CLAIM, DEMAND, ACTION OR CAUSE OF ACTION ARISING UNDER ANY LOAN DOCUMENT OR IN ANY WAY CONNECTED WITH OR RELATED OR INCIDENTAL TO THE DEALINGS OF THE PARTIES HERETO OR ANY OF THEM WITH RESPECT TO ANY LOAN DOCUMENT, OR THE TRANSACTIONS RELATED THERETO, IN EACH CASE WHETHER NOW EXISTING OR HEREAFTER ARISING, AND WHETHER FOUNDED IN CONTRACT OR TORT OR OTHERWISE; AND EACH PARTY HEREBY AGREES AND CONSENTS THAT ANY SUCH CLAIM, DEMAND, ACTION OR CAUSE OF ACTION SHALL BE DECIDED BY COURT TRIAL WITHOUT A JURY, AND THAT ANY PARTY TO THIS AGREEMENT MAY FILE AN ORIGINAL COUNTERPART OR A COPY OF THIS SECTION WITH ANY COURT AS WRITTEN EVIDENCE OF THE CONSENT OF THE SIGNATORIES HERETO TO THE WAIVER OF THEIR RIGHT TO TRIAL BY JURY.