Termination for Convenience TIPS may, by written notice to Vendor, terminate this Agreement for convenience, in whole or in part, at any time by giving thirty (30) days’ written notice to Vendor of such termination, and specifying the effective date thereof.
TERMINATION FOR CAUSE BY CITY 4.05.1 If Contractor defaults under this Agreement, the Director may terminate this Agreement after providing Contractor written notice and an opportunity to cure the default as provided below. The City’s right to terminate this Agreement for Contractor’s default is cumulative of all rights and remedies that exist now or in the future. Default by Contractor occurs if: 4.05.1.1 Contractor fails to perform any of its material duties under this Agreement; 4.05.1.2 Contractor becomes insolvent; 4.05.1.3 all or a substantial part of Contractor’s assets are assigned for the benefit of its creditors; or 4.05.1.4 a receiver or trustee is appointed for Contractor. 4.05.2 If a default occurs and the Director determines that the City wishes to terminate the Agreement, then the Director must deliver a written notice to Contractor describing the default and the proposed termination date, with a copy of the notice to the CPO. The date must be at least 30 days after Contractor receives notice. The Director, at his or her sole option, may extend the termination date to a later date. If Contractor cures the default before the proposed termination date, then the proposed termination is ineffective. If Contractor does not cure the default before the termination date, then the Director may terminate this Agreement on the termination date, at no further obligation of the City. 4.05.3 To effect final termination, the Director must notify Contractor in writing, with a copy of the notice to the CPO. After receiving the notice, Contractor shall, unless the notice directs otherwise, immediately discontinue all services under this Agreement and promptly cancel all orders or subcontracts chargeable to this Agreement.
Termination for fault 19.3.1 The Commonwealth may terminate this Agreement by notice where the Grantee has: (a) failed to comply with an obligation under this Agreement and the Commonwealth believes that the non‐compliance is incapable of remedy or where clause 19.2.2(b) applies; (b) provided false or misleading statements in relation to the Grant; or (c) become bankrupt or insolvent, entered into a scheme of arrangement with creditors, or come under any form of external administration. 19.3.2 The Grantee agrees, on receipt of the notice of termination, to: (a) stop the performance of the Grantee’s obligations; (b) take all available steps to minimise loss resulting from the termination; and (c) report on, and return any part of the Grant to the Commonwealth, or otherwise deal with the Grant, as directed by the Commonwealth.
Term; Termination of Agreement This Agreement shall continue in force for a period of one year from the date hereof, subject to an unlimited number of successive one-year renewals upon mutual consent of the parties. It is the duty of the Independent Directors to evaluate the performance of the Advisor annually before renewing the Agreement, and each such renewal shall be for a term of no more than one year.
CFR PART 200 Termination Termination for cause and for convenience by the grantee or subgrantee including the manner by which it will be eff ected and the basis for settlement. (All contracts in excess of $10,000) Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for cause after giving the vendor an appropriate opportunity an d up to 30 days, to cure the causal breach of terms and conditions. ESC Region 8 and TIPS Members reserves the right to terminate any agreement in excess of $10,000 resulting from this procurement process for convenience with 30 days notice in writing to the awarded vendor. The vendor would be compensated for work performed and goods procured as of the termination date if for convenience of the ESC Region 8 and TIPS Members. Any award under this procurement process is not exclusive and the ESC Region 8 and TIPS reserves the right to purchase goods and services from other vendors when it is in the best interest of t he ESC Region 8 and TIPS. Does vendor agree? Yes
Term; Termination; Rights on Termination The term of this Agreement shall begin on the date hereof and continue for three (3) years, and, unless terminated sooner as herein provided, shall continue thereafter on a year-to-year basis on the same terms and conditions contained herein in effect as of the time of renewal (such initial three year period and any extensions thereof being referred to herein as the "Term"). This Agreement and Employee's employment may be terminated in any one of the following ways:
Termination of Service for Cause Upon a termination of the Participant’s Service by the Company for Cause the Option, including the Vested Portion, shall immediately terminate and be forfeited without consideration.
Termination for Convenience of City The City shall have the right at any time by written notice to Contractor to terminate and cancel this contract, without cause, for the convenience of the City, and Contractor shall immediately stop work. In such event City shall not be liable to Contractor except for payment for actual work performed prior to such notice in an amount proportionate to the completed contract price and for the actual costs of preparations made by Contractor for the performance of the cancelled portions of the contract, including a reasonable allowance of profit applicable to the actual work performed and such preparations. Anticipatory profits and consequential damages shall not be recoverable by Contractor.
Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3. 9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party: (a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach. (b) Becomes insolvent or admits its inability to pay its debts generally as they become due. (c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing. (d) Is dissolved or liquidated or takes any corporate action for such purpose. (e) Makes a general assignment for the benefit of creditors. (f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business. 9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”): (a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment; (b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days; (c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
Termination for Cause by Company Although the Company anticipates the continuation of a mutually rewarding employment relationship with Executive, the Company may terminate Executive’s employment immediately at any time for Cause. For purposes of this Agreement, “Cause” is defined as: (a) acts or omissions constituting gross negligence, recklessness or willful misconduct on the part of Executive with respect to Executive’s obligations or otherwise relating to the business of the Company; (b) Executive’s material breach of this Agreement, including, without limitation, any breach of Section 8, Section 9 or Section 11; (c) Executive’s breach of the Company’s Employee Nondisclosure and Assignment Agreement (a signed copy of which was delivered to the Company with the Original Agreement) (the “Nondisclosure Agreement”); (d) Executive’s conviction or entry of a plea of nolo contendere for fraud, misappropriation or embezzlement, or any felony or crime of moral turpitude; (e) Executive’s inability to perform the essential functions of Executive’s position, with or without reasonable accommodation, due to a mental or physical disability; (f) Executive’s willful neglect of duties as determined in the sole and exclusive discretion of the Board, provided that Executive has received written notice of the action or omission giving rise to such determination and has failed to remedy such situation to the satisfaction of the Board within thirty (30) days following receipt of such written notice, unless Executive’s action or omission is not subject to cure, in which case no such notice shall be required, or (g) Executive’s death. In the event Executive’s employment is terminated in accordance with this Section 7.1, Executive shall be entitled to receive only Executive’s Base Salary then in effect, prorated to the date of Executive’s termination of employment with the Company (the “Termination Date”), and all amounts and benefits earned or incurred pursuant to Sections 5 and 6 through the Termination Date. All other Company obligations to Executive pursuant to this Agreement will be automatically terminated and completely extinguished as of the Termination Date, but will be subject to the surviving provisions of this Agreement set forth in Section 14.8. Executive will not be entitled to receive the Severance Package described in Section 7.2. Any termination pursuant to this Section 7.1 shall be evidenced by a resolution or written consent of the Board, and the Company shall provide Executive with a copy of such resolution or written consent, certified by the Secretary of the Company, upon Executive’s written request.
