Emergency Generator Tenant shall have the right to tie into and use the emergency generator to be installed by Landlord as part of the Base Building Work for use by tenants of the Unit (the “Unit Generator”). Tenant shall be responsible, at its sole cost and expense, for installing, maintaining, repairing and replacing its connection between the Premises and the Unit Generator, and all associated cabling. Tenant shall be permitted to use up to an average of three (3) xxxxx per square foot of usable area in the Premises from the Unit Generator, and at no time shall Tenant exceed that use limitation with respect to the Unit Generator. Except to the extent that Tenant ties into the Unit Generator as part of the Initial Tenant Work in accordance with the provisions of the Work Letter, installation of such tie-in and any related cabling, conduit and appurtenances will be governed by the applicable provisions of this Lease relating to Tenant Work. Tenant will submit to Landlord at least thirty (30) days prior to the proposed installation date Tenant’s proposed plans and specifications relating to the tie-in to the Unit Generator and all associated lines. Tenant may not commence any work to tie into the Unit Generator until it has received Landlord’s prior written approval (not to be unreasonably withheld, delayed or conditioned) of such plans and specifications. Tenant, at its sole cost and expense, shall comply with all applicable Legal Requirements and Title Matters and Landlord’s reasonable directives relating to the installation, operation, maintenance and repair of such tie-in, including (i) obtaining and maintaining (or causing to be obtained and maintained) and complying with the provisions of all applicable permits relating to the tie into and use of the Unit Generator. Tenant may not use the Unit Generator for any purpose other than solely in connection with Tenant’s occupancy of the Premises for the Permitted Use and in accordance with any applicable permit(s) pertaining to the Unit Generator. Except for permitted subtenants and assignees. Tenant may not use the Unit Generator to serve other occupant(s) of the Development.
Emergency Repairs In the event Emergency Repairs are needed at the Hotels, Manager shall be required to use its good faith efforts to obtain Lessee’s verbal approval of any Emergency Repairs prior to making any expenditure therefor. In the event Manager is unable to contact Lessee to obtain its verbal approval of Emergency Repairs, then Manager is authorized to enter into contracts occasioned by such emergency that provide for expenditures not contemplated by the Annual Business Plan up to a sum of $50,000, and provided the same may be incurred under the Loan Documents. Manager will promptly give Lessee written notice of any Emergency Repairs made by Manager.
Generator Subject to the provisions of this Section 29.36, Tenant shall be entitled to install, operate and maintain a generator and any other equipment related thereto, including, without limitation, a fuel system, wiring and shaft space (“Generator”) next to the Building at Tenant’s sole cost and expense (without paying any additional fee or rental to Landlord for the use thereof). Prior to the installation of the Generator, Tenant shall inspect the proposed location to determine a suitable location for the Generator, and Tenant shall submit written plans and specifications relative to the type, size and proposed location (including any proposed screening) of the Generator to Landlord for its review and written approval. Tenant shall be solely responsible for the cost of acquisition, installation, operation, and maintenance of the Generator; and Tenant shall install, maintain and operate the Generator in accordance with all federal, state, and local laws, statutes, ordinances, rules and regulations, including without limitation, obtaining and maintaining any and all permits, approvals and licenses required to install and operate the Generator by any governmental authority having jurisdiction. Landlord and Tenant agree that, upon the expiration of earlier termination of the Lease Term, Tenant shall not be required to remove the Generator, any associated cabling, wiring and screening or other improvements. Tenant shall not be entitled to grant or assign to any third party (other than a permitted assignee of Tenant’s rights under the Lease or a permitted subtenant relative to the Premises (or a portion thereof)) the right to use the Generator without Landlord’s prior written consent (which consent may be granted or withheld in Landlord’s discretion). Upon reasonable advance notice to Tenant (and provided Landlord reasonably coordinates with Tenant and provides an alternate source of backup generator capacity during said transition), Landlord shall be entitled to cause the Generator to be moved to another location near the Building, at Landlord’s cost and expense. Tenant shall pay all personal property taxes on the Generator. Tenant shall also pay any increases in the real property taxes of the Building due to the installation of the Generator within thirty (30) days of receipt of notice from Landlord which includes proof of such increase in taxes. Tenant’s indemnity obligations under Section 5.4.1.5 of the Lease, relating to the use of Hazardous Materials, shall apply to the use and operation of the Generator. Finally, Tenant’s insurance obligations under Section 10.3 of the Lease shall apply to the Generator.
Emergency If a well goes out of control or a fire, blow out, sabotage or other emergency occurs prior to the effective date of a Party’s withdrawal, the withdrawing Party shall remain liable for its Participating Interest share of the costs of such emergency, regardless of when they are incurred.
Emergency Services HMO policy and procedures, Covered Services, claims adjudication methodology, and reimbursement performance for Emergency Services must comply with all applicable state and federal laws, rules, and regulations including 42 C.F.R. §438.114, whether the provider is in-network or Out-of-Network. HMO policies and procedures must be consistent with the prudent layperson definition of an Emergency Medical Condition and the claims adjudication processes required under the Contract and 42 C.F.R. §438.114. The HMO must pay for the professional, facility, and ancillary services that are Medically Necessary to perform the medical screening examination and stabilization of a Member presenting with an Emergency Medical Condition or an Emergency Behavioral Health Condition to the hospital emergency department, 24 hours a day, 7 days a week, rendered by either the HMO's Network or Out-of-Network providers. The HMO cannot require prior authorization as a condition for payment for an Emergency Medical Condition, an Emergency Behavioral Health Condition, or labor and delivery. The HMO cannot limit what constitutes an Emergency Medical Condition on the basis of lists of diagnoses or symptoms. The HMO cannot refuse to cover Emergency Services based on the emergency room provider, hospital, or fiscal agent not notifying the Member’s PCP or the HMO of the Member’s screening and treatment within 10 calendar days of presentation for Emergency Services. The HMO may not hold the Member who has an Emergency Medical Condition liable for payment of subsequent screening and treatment needed to diagnose the specific condition or stabilize the patient. The HMO must accept the emergency physician or provider’s determination of when the Member is sufficiently stabilized for transfer or discharge.
Emergencies 10.3.1 In an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor's discretion, to prevent threatened damage, injury or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Paragraph 4.3 and Article 7.
Electrical Service Subject to the limitation of this Paragraph 4, furnish electrical service to the Premises, including providing and installing all Building standard replacement lighting tubes. If Tenant uses more electrical power than Landlord in good faith considers reasonable or normal for office use, Tenant will pay Landlord on a monthly basis the cost of such excess power consumed by Tenant. Consumption will be determined, at Landlord’s election, either (a) by a survey performed by a reputable consultant selected by Landlord, or (b) through separate meters or submeters installed, maintained and read by Landlord at Tenant’s cost. For purposes of this Paragraph 4 only, “month” and “monthly” shall mean any billing period used by the utility or other power provider supplying electricity. All installations of electrical futures, appliances and equipment within the Premises shall be subject to Landlord’s prior approval, and if they affect the temperature or humidity otherwise maintained, Landlord may, at Tenant’s sole cost and expense (to be paid within (30) days after delivery of written demand supported by invoices or other reasonably satisfactory evidence), install supplemental air conditioning units. Tenant’s use of electricity shall never exceed Tenant’s share of the capacity of existing feeders to the Building or of the risers, wiring installations and transformers serving the floor(s) containing the Premises. Landlord shall provide up to 3.5 xxxxx per usable square foot (demand) of riser and floor panel electrical capacity averaged over the floor being serviced. EXHIBIT C Tenant shall be allocated an approximate 2.0 xxxxx per usable square foot for power and 1.5 xxxxx per usable square foot for lighting. Any risers or wiring necessary to meet Tenant’s excess electrical requirements will be installed by Landlord on Tenant’s request, at Tenant’s sole cost and expense (to be paid in advance), but only if in Landlord’s reasonable good faith belief they are necessary and will not cause damage to the Building or a dangerous condition, entail excessive or unreasonable alterations, repairs or expense, or disturb other occupants.
Floor Load Tenant shall not place a load upon any floor of the Premises that exceeds 50 pounds per square foot “live load”. Landlord reserves the right to reasonably designate the position of all Equipment which Tenant wishes to place within the Premises, and to place limitations on the weight thereof.
Lighting Landlord will furnish both Building Standard and non-Building Standard lamps, bulbs, ballasts and starters that are part of the Leasehold Improvements for purchase by Tenant at Landlord's cost, plus Landlord's standard administration fee. Landlord will install non-Building Standard items at Landlord's scheduled rate for this service.
Electrical During the Term of this Lease, there shall be available to the Leased Premises electrical facilities comparable to those supplied in other comparable office buildings in the vicinity of the Building to provide sufficient power for normal lighting and office machines of similar low electrical consumption, and one personal computer for each desk station, but not for any additional computers or extraordinary data processing equipment, special lighting and any other item of electrical equipment which requires a voltage other than one hundred ten (110) volts single phase and is not typically found in an office, as determined by Landlord in its sole, but reasonable discretion; and provided, however, that if the installation of such electrical equipment requires additional air conditioning capacity above that normally provided to tenants of the Building or above standard usage of existing capacity as determined by Landlord in its sole, but reasonable discretion, then the additional air conditioning installation and/or operating costs attributable thereto shall be paid by Tenant. Tenant agrees not to use any apparatus or device in, upon or about the Leased Premises which may in any way increase the amount of such electricity usually furnished or supplied to the Leased Premises, and Tenant further agrees not to connect any apparatus or device to the wires, conduits or pipes or other means by which such electricity is supplied, for the purpose of using additional or unusual amounts of electricity, without the prior written consent of Landlord. At all times, Tenant’s use of electric current shall never exceed Tenant’s share of the capacity of the feeders to the Building or the risers or wiring installation. Tenant shall not install or use or permit the installation or use in the Leased Premises of any computer or electronic data processing or ancillary equipment or any other electrical apparatus designed to operate on electrical current in excess of 110 volts and 5 amps per machine, without the prior written consent of Landlord, which consent shall not be unreasonably withheld, conditioned or delayed. If Tenant shall require electrical current in excess of that usually furnished or supplied for use of the Leased Premises as general office space, Tenant shall first procure the written consent of Landlord (which consent shall not be unreasonably withheld, conditioned or delayed) to the use thereof and Landlord or Tenant may (i) cause a meter to be installed in or for the Leased Premises, or (ii) if Tenant elects not to install said meter, Landlord may reasonably estimate such excess electrical current. The cost of any meters (including, without limitation, the cost of any installation) or surveys to estimate such excess electrical current shall be paid by Tenant. Landlord’s approval of any space plan, floor plan, construction plans, specifications, or other drawings or materials regarding the construction of the Tenant Improvements or any alterations shall not be deemed or construed as consent by Landlord under this paragraph to Tenant’s use of such excess electrical current as provided above. Tenant agrees to pay to Landlord, promptly upon demand therefor, all costs of such excess electrical current consumed as calculated by said meters (at the rates charged for such services to the Building by the municipality or the local public utility) or the excess amount specified in said estimate, as the case may be, plus any additional expense incurred in keeping account of the electrical current so consumed, which additional expense Landlord shall advise Tenant within a reasonable time after request by Tenant.
