Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made--
(i) In the contract price or delivery schedule or both; and
(ii) In such other provisions of the contract as may be affected.
(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.
Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.
Equitable Adjustment Trading volume amounts, price/volume amounts and similar figures in the Transaction Documents shall be equitably adjusted (but without duplication) to offset the effect of stock splits, similar events and as otherwise described in this Agreement and Warrants.
Section 754 Adjustments To the extent an adjustment to the adjusted tax basis of any Company asset, pursuant to Code Section 734(b) or Code Section 743(b) is required, pursuant to Regulations Section 1.704-1(b)(2)(iv)(m)(2) or 1.704-1(b)(2)(iv)(m)(4), to be taken into account in determining Capital Accounts as the result of a distribution to a Unit Holder in complete liquidation of such Unit Holder’s interest in the Company, the amount of such adjustment to Capital Accounts shall be treated as an item of gain (if the adjustment increases the basis of the asset) or loss (if the adjustment decreases such basis) and such gain or loss shall be specially allocated to the Unit Holders in accordance with their interests in the Company in the event Regulations Section 1.704-1(b)(2)(iv)(m)(2) applies, or to the Unit Holder to whom such distribution was made in the event Regulations Section 1.704-1(b)(2)(iv)(m)(4) applies.
Determination of Adjustments If any questions will at any time arise with respect to the Exercise Price or any adjustment provided for in Section 4.8, such questions will be conclusively determined by the Company’s Auditors, or, if they decline to so act any other firm of certified public accountants in the United States of America that the Company may designate and who will have access to all appropriate records and such determination will be binding upon the Company and the Holders of the Warrants.
True-Up Adjustments From time to time, until the Retirement of the Recovery Bonds, the Servicer shall identify the need for True-Up Adjustments and shall take all reasonable action to obtain and implement such True-Up Adjustments, all in accordance with the following:
Adjustments Upon Changes in Capitalization As used herein, the term "Adjustment Event" means an event pursuant to which the outstanding shares of the Company are increased, decreased or changed into, or exchanged for a different number or kind of shares or securities, without receipt of consideration by the Company, through reorganization, merger, recapitalization, reclassification, stock split, reverse stock split, stock dividend, stock consolidation or otherwise. The term "Adjustment Event" shall also mean to include: (i) any issuance by the Company of the Company's securities (excluding securities issued to the Company's employees, directors, consultants and others similarly situtated) below fair market value for such securities as determined at the time of issuance; and (ii) any issuance at a price below the purchase price per Share for the common stock underlying the Options, as adjusted. Upon the occurrence of an Adjustment Event, (i) appropriate and proportionate adjustments shall be made to the number and kind and exercise price for the shares subject to the Options, and (ii) appropriate amendments to this Agreement shall be executed by the Company and the Optionee if the Board of Directors in good faith determines that such an amendment is necessary or desirable to reflect such adjustments. If determined by the Board of Directors to be appropriate, in the event of an Adjustment Event which involves the substitution of securities of a corporation other than the Company, the Board of Directors shall make arrangements for the assumptions by such other corporation of the Options. Notwithstanding the foregoing, any such adjustment to the Options shall be made without change in the total exercise price applicable to the unexercised portion of the Options, but with an appropriate adjustment to the number of shares, kind of shares and exercise price for each share subject to the Options. The good faith determination by the Board of Directors as to what adjustments, amendments or arrangements shall be made pursuant to this Section, and the extent thereof, shall be final and conclusive, provided that the Options herein are adjusted in a manner that is no less favorable than the manner of adjustment used as to any other options issued by the Company to its employees, directors, consultants or in any transaction. No fractional Shares shall be issued on account of any such adjustment or arrangement.
Share Adjustments If the Company's outstanding shares of Common Stock are increased or decreased or changed into or exchanged for a different number or kind of shares or other securities of the Company by reason of any recapitalization, reclassification, stock split, combination of shares, stock dividend, or transaction having similar effect, the Board shall proportionately and appropriately adjust the number and kind of shares that are subject to this Option and the Exercise Price Per Share, without any change in the aggregate price to be paid therefor upon exercise of this Option.
ADJUSTMENTS FOR CHANGES IN CAPITAL STRUCTURE Subject to any required action by the stockholders of the Company, in the event of any change in the Stock effected without receipt of consideration by the Company, whether through merger, consolidation, reorganization, reincorporation, recapitalization, reclassification, stock dividend, stock split, reverse stock split, split-up, split-off, spin-off, combination of shares, exchange of shares, or similar change in the capital structure of the Company, or in the event of payment of a dividend or distribution to the stockholders of the Company in a form other than Stock (other than regular, periodic cash dividends paid on Stock pursuant to the Company’s dividend policy) that has a material effect on the Fair Market Value of shares of Stock, appropriate and proportionate adjustments shall be made in the number and kind of shares of stock or other property subject to the Award, in order to prevent dilution or enlargement of the Participant’s rights under the Award. For purposes of the foregoing, conversion of any convertible securities of the Company shall not be treated as “effected without receipt of consideration by the Company.” Any and all new, substituted or additional securities or other property (other than regular, periodic cash dividends paid on Stock pursuant to the Company’s dividend policy, subject to Section 5.3) to which Participant is entitled by reason of ownership of shares acquired pursuant to this Award will be immediately subject to the provisions of this Award on the same basis as all shares originally acquired hereunder. Any fractional share resulting from an adjustment pursuant to this Section shall be rounded down to the nearest whole number. Such adjustments shall be determined by the Committee, and its determination shall be final, binding and conclusive.
Adjustments for Stock Splits, Etc Wherever in this Agreement there is a reference to a specific number of shares of Common Stock or Preferred Stock of the Company of any class or series, then, upon the occurrence of any subdivision, combination or stock dividend of such class or series of stock, the specific number of shares so referenced in this Agreement shall automatically be proportionally adjusted to reflect the affect on the outstanding shares of such class or series of stock by such subdivision, combination or stock dividend.
