Limitation of Liability of JCM JCM shall not be liable for any error of judgment or mistake of law or for any loss arising out of any investment or for any act or omission taken with respect to the Trust, except for willful misfeasance, bad faith or gross negligence in the performance of its duties, or by reason of reckless disregard of its obligations and duties hereunder and except to the extent otherwise provided by law. As used in this Section 14, "JCM" shall include any affiliate of JCM performing services for the Trust contemplated hereunder and directors, officers and employees of JCM and such affiliates.
LIMITATION OF LIABILITY OF ADVISER You may rely on information reasonably believed by you to be accurate and reliable. Except as may otherwise be required by the 1940 Act or the rules thereunder, neither you nor your shareholders, members, officers, directors, employees, agents, control persons or affiliates of any thereof shall be subject to any liability for, or any damages, expenses or losses incurred by the Trust in connection with, any error of judgment, mistake of law, any act or omission connected with or arising out of any services rendered under, or payments made pursuant to, this Agreement or any other matter to which this Agreement relates, except by reason of willful misfeasance, bad faith or gross negligence on the part of any such persons in the performance of your duties under this Agreement, or by reason of reckless disregard by any of such persons of your obligations and duties under this Agreement. Any person, even though also a director, officer, employee, member, shareholder or agent of you, who may be or become an officer, director, trustee, employee or agent of the Trust, shall be deemed, when rendering services to the Trust or acting on any business of the Trust (other than services or business in connection with your duties hereunder), to be rendering such services to or acting solely for the Trust and not as a director, officer, employee, member, shareholder or agent of you, or one under your control or direction, even though paid by you.
EXCLUSION OF LIABILITY All statements made in the Proclamation of Sale and Conditions of Sale or otherwise relating to the Property are made without responsibility on the part of the Assignee/Bank, the Solicitors and Auctioneers or either of them. No such statement may be relied upon as a statement or representation of fact. All bidders must satisfy themselves by inspection or otherwise as to the correctness of any such statements and neither the Assignee/Bank, the Solicitors, the Auctioneer nor any person in their employment has any authority to make or give any representation or warranty whatsoever in relation to the Property.
Limitation of Liability of Manager As an inducement to your undertaking to render services pursuant to this Agreement, the Trust agrees that you shall not be liable under this Agreement for any error of judgment or mistake of law or for any loss suffered by the Fund in connection with the matters to which this Agreement relates, provided that nothing in this Agreement shall be deemed to protect or purport to protect you against any liability to the Trust, the Fund or its shareholders to which you would otherwise be subject by reason of willful misfeasance, bad faith or gross negligence in the performance of your duties, or by reason of your reckless disregard of your obligations and duties hereunder.
Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY.
10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00.
10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF
10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE;
10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR
10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH:
10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS;
10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT;
10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR
10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER.
10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5.
10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY.
10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.
Limitation of Liability of the Adviser The Adviser shall not be liable for any error of judgment or mistake of law or for any loss arising out of any investment or for any act or omission in the execution and management of the Fund, except for willful misfeasance, bad faith or gross negligence in the performance of its duties and obligations hereunder. As used in this Article 6, the term "Adviser" shall include Directors, officers and employees of the Adviser as well as that corporation itself.
Limitation of Liability of Sub-Adviser The Sub-Adviser shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust or the Fund or the Adviser in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on the Sub-Adviser's part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement. Any person, even though also employed by the Sub-Adviser, who may be or become an employee of and paid by the Trust or the Fund shall be deemed, when acting within the scope of his employment by the Trust or the Fund, to be acting in such employment solely for the Trust or the Fund and not as the Sub-Adviser's employee or agent.
LIMITATION OF LIABILITY OF THE MANAGER The Manager shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Fund in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on the Manager's part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement.
Limitation of Liability No provision hereof, in the absence of any affirmative action by the Holder to exercise this Warrant to purchase Warrant Shares, and no enumeration herein of the rights or privileges of the Holder, shall give rise to any liability of the Holder for the purchase price of any Common Stock or as a stockholder of the Company, whether such liability is asserted by the Company or by creditors of the Company.
Disclaimers and Limitation of Liability EXCEPT AS EXPRESSLY SET FORTH HEREIN, ALL SERVICES TO BE PROVIDED BY FLG AND FLG MEMBER (FOR PURPOSES OF THIS PARAGRAPH 6, COLLECTIVELY “FLG”) HEREUNDER ARE PROVIDED “AS IS” WITHOUT ANY WARRANTY WHATSOEVER. CLIENT RECOGNIZES THAT THE “AS IS” CLAUSE OF THIS AGREEMENT IS AN IMPORTANT PART OF THE BASIS OF THIS AGREEMENT, WITHOUT WHICH FLG WOULD NOT HAVE AGREED TO ENTER INTO THIS AGREEMENT. FLG EXPRESSLY DISCLAIMS ALL OTHER WARRANTIES, TERMS OR CONDITIONS, WHETHER EXPRESS, IMPLIED, OR STATUTORY, REGARDING THE PROFESSIONAL SERVICES, INCLUDING ANY, WARRANTIES OF MERCHANTABILITY, TITLE, FITNESS FOR A PARTICULAR PURPOSE AND INFRINGEMENT. NO REPRESENTATION OR OTHER AFFIRMATION OF FACT REGARDING THE SERVICES PROVIDED HEREUNDER SHALL BE DEEMED A WARRANTY FOR ANY PURPOSE OR GIVE RISE TO ANY LIABILITY OF FLG WHATSOEVER. IN NO EVENT SHALL FLG BE LIABLE FOR ANY INCIDENTAL, INDIRECT, EXEMPLARY, SPECIAL, PUNITIVE OR CONSEQUENTIAL DAMAGES, UNDER ANY CIRCUMSTANCES, INCLUDING, BUT NOT LIMITED TO: LOST PROFITS; REVENUE OR SAVINGS; WAIVER BY CLIENT, WHETHER INADVERTENT OR INTENTIONAL, OF CLIENT’S ATTORNEY-CLIENT PRIVILEGE THROUGH CLIENT’S DISCLOSURE OF LEGALLY PRIVILEGED INFORMATION TO FLG; OR THE LOSS, THEFT, TRANSMISSION OR USE, AUTHORIZED OR OTHERWISE, OF ANY DATA, EVEN IF CLIENT OR FLG HAVE BEEN ADVISED OF, KNEW, OR SHOULD HAVE KNOWN, OF THE POSSIBILITY THEREOF. NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, FLG’S AGGREGATE CUMULATIVE LIABILITY HEREUNDER, WHETHER IN CONTRACT, TORT, NEGLIGENCE, MISREPRESENTATION, STRICT LIABILITY OR OTHERWISE, SHALL NOT EXCEED AN AMOUNT EQUAL TO THE LAST TWO (2) MONTHS OF FEES PAYABLE BY CLIENT UNDER PARAGRAPH 2(A) OF THIS AGREEMENT. CLIENT ACKNOWLEDGES THAT THE COMPENSATION PAID BY IT UNDER THIS AGREEMENT REFLECTS THE ALLOCATION OF RISK SET FORTH IN THIS AGREEMENT AND THAT FLG WOULD NOT ENTER INTO THIS AGREEMENT WITHOUT THESE LIMITATIONS ON ITS LIABILITY. THIS PARAGRAPH SHALL NOT APPLY TO EITHER PARTY WITH RESPECT TO A BREACH OF ITS CONFIDENTIALITY OBLIGATIONS.
A. As a condition for recovery of any amount by Client against FLG, Client shall give FLG written notice of the alleged basis for liability within ninety (90) days of discovering the circumstances giving rise thereto, in order that FLG will have the opportunity to investigate in a timely manner and, where possible, correct or rectify the alleged basis for liability; provided that the failure of Client to give such notice will only affect the rights of Client to the extent that FLG is actually prejudiced by such failure. Notwithstanding anything herein to the contrary, Client must assert any claim against FLG by the sooner of: (i) ninety (90) days after discovery; (ii) ninety (90) days after the termination of this Agreement; (iii) ninety (90) days after the last date on which the Services were performed; or, (iv) sixty (60) days after completion of a financial or accounting audit for the period(s) to which a claim pertains.
