Factory Made Jumpers Sample Clauses

Factory Made Jumpers. Contractor shall use factory made jumpers for all new installations of the applicable AT&T equipment in accordance with AT&T RF Cabling Standard ATT ▇▇▇-▇▇▇-▇▇▇, *****. *****. If handmade or field-made jumpers are rejected by AT&T, then Contractor shall replace any handmade jumper with a factory made jumper at Contractor’s expense. In addition, for each handmade jumper used to install AT&T equipment, Contractor shall credit AT&T in the amount of ***** ($*****). The Parties acknowledge and agree that the credits are paid in recognition of the diminished value of the Services resulting from Contractor’s failure to meet the agreed upon level of performance. Such credits are part of the compensation arrangement between the Parties, not a penalty or liquidated damages. Furthermore, the credits will not limit AT&T’s right to recover, in accordance with this Agreement, damages incurred by AT&T. THE COMPANY HAS REQUESTED AN ORDER FROM THE SECURITIES AND EXCHANGE COMMISSION (THE “COMMISSION”) GRANTING CONFIDENTIAL TREATMENT TO SELECTED PORTIONS. ACCORDINGLY, THE CONFIDENTIAL PORTIONS HAVE BEEN OMITTED FROM THIS EXHIBIT, AND HAVE BEEN FILED SEPARATELY WITH THE COMMISSION. OMITTED PORTIONS ARE INDICATED IN THIS EXHIBIT WITH “*****”. c. MS*****/***** i. If Contractor fails to Actualize MS*****/***** by the “Planned MS*****/***** Date” (the Delivery Date for the purposes of this Section), as it may be amended by AT&T, for the Project as listed in CASPR, then AT&T will recover, as liquidated damages and not as a penalty, ***** ($*****) for each day starting with the Delivery Date and ending with the day when Contractor completes the delayed Delivery or AT&T terminates the applicable Order, whichever occurs first. The amount of AT&T’s potential recovery under this Section is so limited that it will not exceed ***** (*****%) of the total price of the affected Order. ii. Contractor shall not be responsible for any delays caused by AT&T or the third party base transceiver station (BTS) equipment vendor and the “Delivery Date” for purposes of the application of liquidated damages shall be extended one day for each day of delay caused by either AT&T or the third party BTS equipment vendor’s performance.
View Source
Factory Made Jumpers. Contractor shall use factory made jumpers for all new installations of the applicable AT&T equipment in accordance with AT&T RF Cabling Standard ATT ▇▇▇-▇▇▇-▇▇▇, *****. *****. If handmade or field-made jumpers are rejected by AT&T, then Contractor shall replace any handmade jumper with a factory made jumper at Contractor’s expense. In addition, for each handmade jumper used to install AT&T equipment, Contractor shall credit AT&T in the amount of ***** ($*****). The Parties acknowledge and agree that the credits are paid in recognition of the diminished value of the Services resulting from Contractor’s failure to meet the agreed upon level of performance. Such credits are part of the compensation arrangement between the Parties, not a penalty or liquidated damages. Furthermore, the credits will not limit AT&T’s right to recover, in accordance with this Agreement, damages incurred by AT&T. THE COMPANY HAS REQUESTED AN ORDER FROM THE SECURITIES AND EXCHANGE COMMISSION (THE “COMMISSION”) GRANTING CONFIDENTIAL TREATMENT TO SELECTED PORTIONS. ACCORDINGLY, THE CONFIDENTIAL PORTIONS HAVE BEEN OMITTED FROM THIS EXHIBIT, AND HAVE BEEN FILED SEPARATELY WITH THE COMMISSION. OMITTED PORTIONS ARE INDICATED IN THIS EXHIBIT WITH “*****”.
View Source

Related to Factory Made Jumpers

  • Orlando, FL; Ft Lauderdale, FL; Charlotte-Gastonia-Rock Hill, NC; Greensboro-Winston Salem-High Point, NC; Nashville, TN; and New Orleans, LA, and BellSouth has provided non- discriminatory cost based access to the Enhanced Extended Link (EEL) throughout Density Zone 1 as determined by NECA Tariff No. 4 as in effect on January 1, 1999.

  • Chief Executive Office; Jurisdiction of Organization Seller shall not move its chief executive office from the address referred to in Section 13(a)(17) or change its jurisdiction of organization from the jurisdiction referred to in Section 13(a)(17) unless it shall have provided Buyer 30 days’ prior written notice of such change.

  • LOKASI ▇▇▇ KETERANGAN HARTANAH Hartanah tersebut adalah terletak di tingkat 6 Pangsapuri Mesra Ria. Hartanah tersebut adalah pangsapuri kos rendah 3 ▇▇▇▇▇ tidur pertengahan dikenali sebagai ▇▇▇▇▇ Pemaju No. A-06-06, Tingkat No 06, Bangunan No A, Pandan Mesra ▇▇▇ beralamat pos di No. 06-06, Pangsapuri Mesra Ria, ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇. (“Hartanah”) Hartanah ini akan dijual keadaan “sepertimana sedia ada” tertakluk kepada satu harga rizab sebanyak RM150,000.00 (RINGGIT MALAYSIA SATU RATUS ▇▇▇ ▇▇▇▇ PULUH RIBU SAHAJA), mengikut kepada Syarat-syarat Jualan di sini dengan cara Penyerahan Hak dari Pemegang Serahhak ▇▇▇ tertakluk kepada Pembeli memperoleh pengesahan / kebenaran yang diperlukan daripada Pemaju ▇▇▇/atau Pemilik Tanah ▇▇▇/atau Pihak Berkuasa Negeri ▇▇▇/atau badan-badan yang relevan (jika ada). Semua penawar yang ingin membuat tawaran adalah dikehendaki membayar deposit sebanyak 10% daripada harga rizab (“deposit pendahuluan”) secara bank draf atau kasyier order dipalang “AKAUN PENERIMA SAHAJA” atas nama HONG ▇▇▇▇▇ BANK BERHAD / ▇▇▇ ▇▇▇ ▇▇▇▇ & ▇▇▇▇ ▇▇▇ MEE @ ▇▇▇▇ NYUIK THAI atau melalui pemindahan perbankan atas talian yang ditentukan oleh pelelong, sekurang-kurangnya SATU (1) HARI BEKERJA SEBELUM TARIKH LELONGAN ▇▇▇ membayar perbezaan di antara deposit pendahuluan ▇▇▇ jumlah bersamaan 10% daripada harga berjaya tawaran sama ada dengan bank draf atau kasyier order dipalang “AKAUN PENERIMA SAHAJA” atas nama ▇▇▇▇ ▇▇▇▇▇ BANK BERHAD / ▇▇▇ ▇▇▇ ▇▇▇▇ & ▇▇▇▇ ▇▇▇ MEE @ ▇▇▇▇ NYUIK THAI atau melalui pemindahan perbankan atas talian dalam masa TIGA (3) HARI BEKERJA sebaik sahaja ketukan tukul oleh Pelelong dibuat. Deposit ▇▇▇▇ ▇▇▇ jumlah perbezaan secara dikumpul dikenali sebagai “deposit”. Hari Bekerja bermaksud hari (tidak termasuk Sabtu, Ahad ▇▇▇ ▇▇▇▇ Umum) di mana Pihak Pemegang Serahhak dibuka untuk perniagaan di Kuala Lumpur Baki harga belian sepenuhnya hendaklah dibayar dalam tempoh sembilan puluh (90) hari dari tarikh jualan lelongan kepada HONG ▇▇▇▇▇ BANK BERHAD. ▇▇▇▇ rujuk Terma & Syarat Dalam Talian Pelelong di ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ untuk ▇▇▇▇-▇▇▇▇ pembayaran deposit. Untuk butir-butir lanjut, ▇▇▇▇ berhubung dengan Tetuan ▇▇▇ ▇▇▇▇ & Co., Peguamcara bagi Pihak Pemegang Serahhak di ▇-▇, ▇▇▇▇▇ ▇▇▇ ▇/▇, ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇▇▇. (Ref No.: 51303.23, Tel No.: ▇▇-▇▇▇▇▇▇▇▇, Fax No.: ▇▇-▇▇▇▇▇▇▇▇) atau Pelelong yang tersebut di bawah ini:- Suite C-20-3A, Level 20, Block C, Megan Avenue II, / ▇▇▇▇▇ ▇▇▇▇▇ BIN ▇▇▇▇▇▇ ▇▇, ▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇, 50450 Kuala Lumpur. (Pelelong Berlesen) Tel No : ▇▇-▇▇▇▇ ▇▇▇▇ Fax No: ▇▇-▇▇▇▇ ▇▇▇▇ Ruj. Kami: ALIN/HLBB1604/WCC Ruj Bank : ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ Web: ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ E-mail : ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇

  • New Hampshire In the event You do not receive satisfaction under this Agreement, You may contact the New Hampshire Insurance Department, ▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇, (▇▇▇) ▇▇▇-▇▇▇▇. ARBITRATION section of this Agreement is removed.

  • WASHINGTON’S ELECTRONIC BUSINESS SOLUTION (WEBS). Contractor represents and warrants that Contractor is registered in Washington’s Electronic Business Solution (WEBS), Washington’s contract registration system and that, all of Contractor’s information therein is current and accurate and that throughout the term of this Contract, Contractor shall maintain an accurate profile in WEBS.