Failure of Allottee to take Possession of Apartment Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the Apartment from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement and the Promoter shall give possession of the Apartment to the Allottee. In case the Allottee fails to take possession within the time provided in para 7.1 such Allottee shall continue to be liable to pay interest on due payments and maintenance charges as specified in para 7.2.
Purchaser's Election to Commence Foreclosure Proceedings (a) In connection with any Mortgage Loan identified in a report under Section 2.01(a)(i)(B), the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure as soon as practicable. Such election must be evidenced by written notice received by the Company by 5:00 p.m., New York City time, on the third Business Day following the delivery of such report under Section 2.01(a)(i).
(b) Within two Business Days of making any Election to Foreclose, the Purchaser shall remit to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to 125% of the current unpaid principal balance of the Mortgage Loan and three months interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit the above amounts relating to the Mortgage Loan within two Business Days of the Election to Foreclose subject to Section 3.01.
(c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Foreclose, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than Commencement of Foreclosure as provided herein). In connection therewith, the Company shall have the same rights to make withdrawals for Monthly Advances and Liquidations Expenses from the Collateral Fund as are provided under Section 2.02(e), and the Company shall make reimbursements thereto to the limited extent provided under such subsection in accordance with its customary procedures. The Company shall not be required to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure if (i) the same is stayed as a result of the mortgagor's bankruptcy or is otherwise barred by applicable law, or to the extent that all legal conditions precedent thereto have not yet been complied with, or (ii) the Company believes there is a breach of representations or warranties by the Company, a Servicer, or a Seller, which may result in a repurchase or substitution of such Mortgage Loan, or (iii) the Company or related Servicer reasonably believes the Mortgaged Property may be contaminated with or affected by hazardous wastes or hazardous substances (and, without limiting the related Servicer's right not to proceed with the Commencement of Foreclosure, the Company supplies the Purchaser with information supporting such belief). Any foreclosure that has been initiated may be discontinued (x) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the Purchaser) or (y) with notice to the Purchaser if the related Servicer has reached the terms of a forbearance agreement unless instructed otherwise by the Purchaser within two Business Days of such notification. Any such instruction shall be based upon a decision that such forbearance agreement is not in conformity with reasonable servicing practices.
(d) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Foreclose and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (c) above, the Company shall calculate the amount, if any, by which the unpaid principal balance of the Mortgage Loan at the time of liquidation (plus all unreimbursed interest and servicing advances and Liquidation Expenses in connection therewith other than those paid from the Collateral Fund) exceeds the actual sales price obtained for the related Mortgaged Property, and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund (after adjustment for all withdrawals and deposits pursuant to subsection (c) in respect of such Mortgage Loan shall be released to the Purchaser.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Documents Records and Funds in Possession of Master Servicer to be Held for the Trustee Notwithstanding any other provisions of this Agreement, the Master Servicer shall transmit to the Trustee as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Master Servicer from time to time and shall account fully to the Trustee for any funds received by the Master Servicer or which otherwise are collected by the Master Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, Distribution Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
Documents, Records and Funds in Possession of Master Servicer To Be Held for Trustee (a) The Master Servicer shall transmit and each Servicer (to the extent required by the related Servicing Agreement) shall transmit to the Trustee or Custodian such documents and instruments coming into the possession of the Master Servicer or such Servicer from time to time as are required by the terms hereof, or in the case of the Servicers, the applicable Servicing Agreement, to be delivered to the Trustee or Custodian. Any funds received by the Master Servicer or by a Servicer in respect of any Mortgage Loan or which otherwise are collected by the Master Servicer or by a Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan shall be held for the benefit of the Trustee and the Certificateholders subject to the Master Servicer's right to retain or withdraw from the Master Servicer Collection Account the Master Servicing Compensation and other amounts provided in this Agreement, and to the right of each Servicer to retain its Servicing Fee and other amounts as provided in the applicable Servicing Agreement. The Master Servicer shall, and (to the extent provided in the applicable Servicing Agreement) shall cause each Servicer to, provide access to information and documentation regarding the Mortgage Loans to the Trustee, its agents and accountants at any time upon reasonable request and during normal business hours, and to Certificateholders that are savings and loan associations, banks or insurance companies, the Office of Thrift Supervision, the FDIC and the supervisory agents and examiners of such Office and Corporation or examiners of any other federal or state banking or insurance regulatory authority if so required by applicable regulations of the Office of Thrift Supervision or other regulatory authority, such access to be afforded without charge but only upon reasonable request in writing and during normal business hours at the offices of the Master Servicer designated by it. In fulfilling such a request the Master Servicer shall not be responsible for determining the sufficiency of such information.
(b) All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer, in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds or Insurance Proceeds, shall be held by the Master Servicer for and on behalf of the Trustee and the Certificateholders and shall be and remain the sole and exclusive property of the Trustee; provided, however, that the Master Servicer and each Servicer shall be entitled to setoff against, and deduct from, any such funds any amounts that are properly due and payable to the Master Servicer or such Servicer under this Agreement or the applicable Servicing Agreement.
Trustee to Retain Possession of Certain Insurance Policies and Documents The Trustee (or the Custodian, as directed by the Trustee), shall retain possession and custody of the originals (to the extent available) of any Primary Mortgage Insurance Policies, or certificate of insurance if applicable, and any certificates of renewal as to the foregoing as may be issued from time to time as contemplated by this Agreement. Until all amounts distributable in respect of the Certificates have been distributed in full and the Master Servicer otherwise has fulfilled its obligations under this Agreement, the Trustee (or its Custodian, if any, as directed by the Trustee) shall also retain possession and custody of each Mortgage File in accordance with and subject to the terms and conditions of this Agreement. The Master Servicer shall promptly deliver or cause to be delivered to the Trustee (or the Custodian, as directed by the Trustee), upon the execution or receipt thereof the originals of any Primary Mortgage Insurance Policies, any certificates of renewal, and such other documents or instruments that constitute portions of the Mortgage File that come into the possession of the Master Servicer from time to time.
Contract for Servicing; Possession of Servicing Files The Seller, by execution and delivery of this Agreement, does hereby contract with the Servicer, subject to the terms of this Agreement, for the servicing of the Mortgage Loans. On or before the Closing Date or Servicing Transfer Date, as applicable, the Seller shall cause to be delivered the Servicing Files with respect to the Mortgage Loans listed on the Mortgage Loan Schedule to the Servicer. Each Servicing File delivered to a Servicer shall be held in trust by such Servicer for the benefit of the Trustee; provided, however, that the Servicer shall have no liability for any Servicing Files (or portions thereof) not delivered by the Seller. The Servicer’s possession of any portion of the Mortgage Loan documents shall be at the will of the Trustee for the sole purpose of facilitating servicing of the related Mortgage Loan pursuant to this Agreement, and such retention and possession by the Servicer shall be in a custodial capacity only. The ownership of each Mortgage Note, Mortgage, and the contents of the Servicing File shall be vested in the Trustee and the ownership of all records and documents with respect to the related Mortgage Loan prepared by or which come into the possession of the Servicer shall immediately vest in the Trustee and shall be retained and maintained, in trust, by the Servicer at the will of the Trustee in such custodial capacity only. The portion of each Servicing File retained by the Servicer pursuant to this Agreement shall be segregated from the other books and records of the Servicer and shall be appropriately marked to clearly reflect the ownership of the related Mortgage Loan by the Trustee. The Servicer shall release from its custody the contents of any Servicing File retained by it only in accordance with this Agreement.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES
