Failure of Allottee to take Possession of Apartment Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the Apartment from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement and the Promoter shall give possession of the Apartment to the Allottee. In case the Allottee fails to take possession within the time provided in para 7.1 such Allottee shall continue to be liable to pay interest on due payments and maintenance charges as specified in para 7.2.
Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.
Site to be free from Encumbrances Subject to the provisions of Clause 8.2, the Site shall be made available by the Authority to the Contractor pursuant hereto free from all Encumbrances and occupations and without the Contractor being required to make any payment to the Authority because of any costs, compensation, expenses and charges for the acquisition and use of such Site for the duration of the Project Completion Schedule. For the avoidance of doubt, it is agreed that the existing rights of way, easements, privileges, liberties and appurtenances to the Site shall not be deemed to be Encumbrances. It is further agreed that, unless otherwise specified in this Agreement, the Contractor accepts and undertakes to bear any and all risks arising out of the inadequacy or physical condition of the Site.
Action by Owners with Respect to Bankruptcy The Owner Trustee shall not have the power to commence a voluntary proceeding in bankruptcy relating to the Trust without the unanimous prior approval of all Owners and the delivery to the Owner Trustee by each such Owner of a certificate certifying that such Owner reasonably believes that the Trust is insolvent.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Investigation by Purchaser (a) Each Buyer Party acknowledges that it and its representatives have been permitted reasonable access to the Books and Records, facilities, equipment, Tax Returns, Contracts, insurance policies (or summaries thereof) and other Properties of the Acquired Companies, and that it and its representatives have had a reasonable opportunity to meet with the officers and employees of the Acquired Companies to discuss the Business. Each of the Buyer Parties further acknowledges that, except as set forth in this Agreement or any of the Ancillary Agreements, the Schedules and the certificates to be delivered at the Closing, (i) none of Seller, the Acquired Companies or any other Person has made any representation or warranty, expressed or implied, as to the Acquired Companies or the accuracy or completeness of any information regarding the Acquired Companies furnished or made available to the Buyer Parties and their respective representatives, (ii) neither Buyer Party has relied on any representation or warranty from Seller, the Acquired Companies or any other Person in determining to enter into this Agreement, and (iii) neither Seller nor any other Person shall have or be subject to any liability to the Buyer Parties or any other Person resulting from the distribution to the Buyer Parties or any other Person, or the Buyer Parties’ or any other Person’s use of, any information, documents or material made available to the Buyers Parties’ or any other Person in any “data rooms,” management presentations or in any other form in expectation of the Transactions. (b) As of the date of this Agreement, the Buyer Parties and their respective Affiliates do not have any actual knowledge that the representations and warranties of Seller made in this Agreement qualified as to materiality are not true and correct, or that those not so qualified are not true and correct in any material respect. The Buyer Parties do not have any actual knowledge of any material errors in, or omissions from, any Schedule.
No Physical Presence of Quorum and Participation by Audio or Video; Disaster Declaration The ability of the Board to meet in person with a quorum physically present at its meeting location may be affected by the Governor or the Director of the Ill. Dept. of Public Health issuing a disaster declaration related to a public health emergency. The Board President or, if the office is vacant or the President is absent or unable to perform the office’s duties, the Vice President determines that an in- person meeting or a meeting conducted under the Quorum and Participation by Audio or Video Means subhead above, is not practical or prudent because of the disaster declaration; if neither the President nor Vice President are present or able to perform this determination, the Superintendent shall serve as the duly authorized designee for purposes of making this determination. The individual who makes this determination for the Board shall put it in writing, include it on the Board’s published notice and agenda for the audio or video meeting and in the meeting minutes, and ensure that the Board meets every OMA requirement for the Board to meet by video or audio conference without the physical presence of a quorum.
POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
Possession by the Allottee After obtaining the occupancy certificate* and handing over physical possession of the [Apartment/Plot] to the Allottees, it shall be the responsibility of the Promoter to hand over the necessary documents and plans, including common areas, to the association of Allottees or the competent authority, as the case may be, as per the local laws. [Provided that, in the absence of any local law, the promoter shall handover the necessary documents and plans, including common areas, to the association of allottees or the competent authority, as the case may be, within thirty days after obtaining the completion certificate].
Succession by Xxxxxx, Etc Any corporation or other entity into which the Trustee may be merged or converted or with which it may be consolidated, or any corporation or other entity resulting from any merger, conversion or consolidation to which the Trustee shall be a party, or any corporation or other entity succeeding to all or substantially all of the corporate trust business of the Trustee (including the administration of this Indenture), shall be the successor to the Trustee hereunder without the execution or filing of any paper or any further act on the part of any of the parties hereto; provided that in the case of any corporation or other entity succeeding to all or substantially all of the corporate trust business of the Trustee such corporation or other entity shall be eligible under the provisions of Section 7.08. In case at the time such successor to the Trustee shall succeed to the trusts created by this Indenture, any of the Notes shall have been authenticated but not delivered, any such successor to the Trustee may adopt the certificate of authentication of any predecessor trustee or authenticating agent appointed by such predecessor trustee, and deliver such Notes so authenticated; and in case at that time any of the Notes shall not have been authenticated, any successor to the Trustee or an authenticating agent appointed by such successor trustee may authenticate such Notes either in the name of any predecessor trustee hereunder or in the name of the successor trustee; and in all such cases such certificates shall have the full force which it is anywhere in the Notes or in this Indenture provided that the certificate of the Trustee shall have; provided, however, that the right to adopt the certificate of authentication of any predecessor trustee or to authenticate Notes in the name of any predecessor trustee shall apply only to its successor or successors by merger, conversion or consolidation.
