FINAL MEASUREMENTS Sample Clauses

FINAL MEASUREMENTS. Final measurements, on unit price contracts, shall be made by the Owner, and the Contractor shall at his own expense provide help and other assistance as may be required for making same.
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
FINAL MEASUREMENTS. Following Substantial Completion of the Interior Improvements and prior to the Closing Date, SELLER will cause the Architect - Shell Improvements to certify the Rentable Square Feet within the Building to confirm compliance with the restriction in subsection 3.2.2 above. If BUYER disputes such certification, BUYER shall notify SELLER in writing within ten (10) days of BUYER's receipt of such certification. In such event, SELLER and BUYER shall submit any such dispute for decision by Arbitration. Notwithstanding the submission of such dispute to Arbitration, BUYER and SELLER shall proceed with the Close of Escrow based on the determination of the Architect-Shell Improvements and any adjustment resulting from a different determination in an Arbitration shall be made within thirty (30) days from the receipt of the Arbitration award. In addition, SELLER shall cause the Architects to deliver as-built plans of the Improvements to SELLER and BUYER no later than sixty (60) days following the issuance of the Certificate of Substantial Completion.
Sample 1

Related to FINAL MEASUREMENTS

  • Measurement Should the State terminate this contract as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to the Engineer. In determining the value of the work performed by the Engineer prior to termination, the State shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should the State terminate this contract under paragraph (4) or (5) above, the Engineer shall not incur costs during the thirty-day notice period in excess of the amount incurred during the preceding thirty days.

  • Performance Measures The System Agency will monitor the Grantee’s performance of the requirements in Attachment A and compliance with the Contract’s terms and conditions.

  • Performance Measure Grantee will adhere to the performance measures requirements documented in Attachment A-5.

  • Performance Targets Threshold, target and maximum performance levels for each performance measure of the performance period are contained in Appendix B.

  • Targets a) Seller’s supplier diversity spending target for Work supporting the construction of the Project prior to the Commercial Operation Date is ____ percent (___%) as measured relative to Seller’s total expenditures on construction of the Project prior to the Commercial Operation Date, and;

  • Performance Excused 11.5.1 The Affected Party, to the extent rendered unable to perform its obligations or part of the obligation thereof under the PPA as a consequence of the Force Majeure Event, shall be excused from performance of the obligations, provided that the period shall not exceed 180 (one hundred and eighty) Days from the date of issuance of the FM Notice. The Parties may mutually agree to extend the period for which performance is excused due to a Force Majeure Event.

  • Performance Objectives 4.1 The Performance Plan (Annexure A) sets out-

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!