Common use of Final Working Drawings Clause in Contracts

Final Working Drawings. Tenant and the Architect shall complete the architectural drawings for the Expansion Space, and the Architect shall compile a fully coordinated set of architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. Tenant The Architect and the Architect Engineers shall complete prepare the architectural and engineering drawings for the Expansion SpacePremises based on the Final Space Plan, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings (collectively, the “Final Working Drawings”) in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectivelythe “Permits”). Tenant shall cooperate with the Architect and the Engineers and provide to the Architect and Engineers such information as they may request in order to prepare and complete such Final Working Drawings and obtain Tenant’s approval thereof on or before the date set forth in Schedule 2. On or before said date, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval Drawings approved by Tenant shall be delivered by the Architect to Landlord to Tenant no later than five (5) business days after Landlord's receipt of for review, and Landlord shall approve or disapprove such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meetin Landlord’s reasonable judgment, within five (5) days Business Days after Landlord's delivery thereof by the Architect. If Landlord disapproves such Final Working Drawings or any portion thereof, Landlord shall specify in writing the reasons for such disapproval, and the Architect, in consultation with Tenant, shall, within five (5) Business Days after receipt of Landlord’s disapproval, revise such Final Working Drawings and resubmit them to agree upon revisions to Landlord for Landlord’s review and approval or disapproval within five (5) Business Days after delivery thereof by the Architect, This process shall be made to repeated, if necessary, until the Final Working Drawings to meet the reasonable satisfaction of have been approved by Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. Tenant On or before the date set forth in Schedule 1, Tenant, the Architect and the Architect Engineers shall complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit four (4) hard copies signed by Tenant of the same Final Working Drawings to Landlord for Landlord's approval ’s approval, and concurrently with Tenant’s delivery of such hard copies, Tenant shall send to Landlord via electronic mail one (1) .pdf electronic copy of such Final Working Drawings; provided, however, Landlord shall only disapprove of the Final Working Drawings to the extent the same are not consistent with, or reasonable disapprovala logical evolution of, which approval or reasonable disapproval the Final Space Plan. Landlord shall be delivered by Landlord to advise Tenant no later than within five (5) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion all of the Final Working Drawings, either (i) approve the parties Final Working Drawings, (ii) approve the Final Working Drawings subject to specified conditions, which conditions must be stated in a reasonably clear and complete manner, or (iii) disapprove and return the Construction Drawings to Tenant with requested revisions. If Landlord disapproves the Final Working Drawings, Tenant shall meet, promptly cause the Final Working Drawings to be revised within five (5) business days after Landlord's disapprovalin order to correct any deficiencies or other matters Landlord may reasonably require, to agree upon revisions to be made to and immediately thereafter Architect shall promptly re-submit the Final Working Drawings Space Plan to meet Landlord for its approval based upon the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon criteria set forth in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than this Section 3.3, within five (5) business days after Landlord's receipt of Landlord receives such revised resubmitted Final Working Drawings. If Landlord Such procedure shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review be repeated until the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedare approved.

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion Space, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the "“Final Working Drawings") ”), and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval ’s approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord to shall advise Tenant no later than within five (5) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawings for the Expansion Space if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, the parties Tenant shall meet, within five promptly (5i) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than to Landlord. The sequence of submitting and reviewing the Final Working Drawings shall continue within the time periods provided herein until the Final Working Drawings are approved. If Landlord fails to respond to any Final Working Drawings submitted for review and approval within five (5) business days after Landlord's receipt of such revised Final Working Drawings. If ’s receipt, Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedbe deemed to have granted its approval.

Final Working Drawings. Tenant Lessee shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the whenever Architect shall compile has compiled a fully coordinated set of architectural architectural, structural, mechanical, electrical or plumbing working drawings with complete specifications in a form which is complete to allow subcontractors be used to bid on obtain permits for the work and to obtain all applicable permits specified in such drawings (collectivelyin each case, the "a “Final Working Drawings") and ”), Lessee shall submit to Lessor for Lessor’s approval, four (4) copies signed by Lessee of such Final Working Drawings. The Final Working Drawings shall substantially reflect the intent of the Design Drawings approved by Lessor. Lessor shall advise Lessee within ten (10) business days after Lessor’s receipt of any Final Working Drawings for the Premises if the same is reasonably unsatisfactory or incomplete in any respect. If Lessor makes any objections to Landlord for Landlord's approval or reasonable disapprovalthe Final Working Drawings, which approval or reasonable disapproval and provided such objections are reasonable, Lessee shall revise the Final Working Drawings and cause such objections to be delivered by Landlord to Tenant no later than remedied in the revised Final Working Drawings. Within five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of Lessor receives the revised Final Working Drawings, the parties Lessor shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord This procedure shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review be repeated until the Final Working Drawings again is finally approved by Lessor and written approval has been delivered to and received by Lessee. Lessor’s failure to advise timely shall be deemed approval. In addition, if the Final Working Drawings are modified, amended or supplemented in accordance any way after Lessor’s approval thereof, or if Lessee prepares a separate set of Final Working Drawings in order to receive applicable permits with respect to any element of the Lessee Improvements, this procedure set forth above shall be repeated until Landlord's reasonable such amended or additional Final Working Drawings are finally approved by Lessor and written approval is obtainedhas been delivered to and received by Lessee.

Final Working Drawings. Following Landlord’s approval of the Space Plans, Tenant shall cause Tenant’s Architect and the Architect shall Engineers to prepare and submit for Landlord’s approval complete the architectural drawings for the Expansion Spaceand detailed construction plans and specifications, and the Architect shall compile including a fully coordinated set of architectural architectural, structural, mechanical, fire protection, electrical and plumbing working drawings for the Tenant Improvement Work, in a form which is sufficiently complete to allow permit subcontractors to bid on the work and to work, obtain all applicable permits required Permits (collectively, as hereinafter defined) and commence construction (the "“Final Working Drawings"”). Tenant shall furnish Landlord with four (4) and copies signed by Tenant of such Final Working Drawings. Landlord shall submit approve or disapprove of the same Final Working Drawings by giving written notice to Tenant within ten (10) business days after receipt thereof. Landlord for Landlord's shall not unreasonably withhold or delay its approval or reasonable disapprovalof the Final Working Drawings, which approval or reasonable disapproval provided that, without limiting the generality of the foregoing, Landlord shall be delivered by entitled to withhold its consent to the Final Working Drawings for any of the reasons specified in clauses (a) through (e) of Section 2.2 above, or if in Landlord’s good faith judgment, the Final Working Drawings are inconsistent with, or do not conform to, the Space Plans. If Landlord disapproves the Final Working Drawings, Landlord shall return the Final Working Drawings to Tenant no later than with a statement of Landlord’s reasons for disapproval and/or specifying any required corrections or revisions. Landlord shall approve or disapprove of any such revisions to the Final Working Drawings within five (5) business days after Landlord's receipt of such Final Working Drawingsrevisions. If This procedure shall be repeated until Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to approves the Final Working Drawings to meet (as so approved, the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final “Approved Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained”).

Final Working Drawings. After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings with complete specifications in a form which is complete to allow subcontractors to bid on all of the work and to obtain all applicable permits (collectively, the "Final Working DrawingsFINAL WORKING DRAWINGS") and shall submit the same to Landlord for Landlord's approval approval, on or reasonable disapprovalbefore May 30, which approval or reasonable disapproval 2002, four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall be delivered by Landlord to advise Tenant no later than five within ten (510) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet for the reasonable satisfaction of LandlordPremises if the same is unsatisfactory or incomplete in any respect. The Architect If Tenant is so advised, Tenant shall then immediately revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove in connection therewith and submit the revised Final Working Drawings to Landlord no later than five ten (510) business days after Landlord delivers its advice. Landlord's receipt of such revised Final Working Drawings. If Landlord failure to advise timely shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedbe deemed approval.

Final Working Drawings. After the approval and final correction of the Final Space Plan, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the cause Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical, plumbing, and life safety working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and Tenant shall submit the same to Landlord for Landlord's approval or ’s reasonable disapproval, which approval or reasonable disapproval approval. Tenant shall be delivered supply Landlord with two (2) copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord shall advise Tenant, with reasonable specificity, within ten (10) Business Days after Landlord’s receipt of the Final Working Drawings for the Premises if Landlord reasonably disapproves determines that the same are unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such review and any disapproval of any portion Landlord in connection therewith. Landlord shall limit its disapproval to areas of the Final Working Drawings that have a Design Problem. In addition to the foregoing, at the time that Landlord provides its approval of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove also advise Tenant of which components of the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Tenant Improvements that Landlord shall again reasonably disapprove require removal at the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again expiration or earlier termination of this Lease in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedParagraph 9.g. of this Lease.

Final Working Drawings. Following Landlord's approval of the Space Plans, Tenant shall cause Tenant's Architect and the Architect shall Engineers to prepare and submit for Landlord's approval complete the architectural drawings for the Expansion Spaceand detailed construction plans and specifications, and the Architect shall compile including a fully coordinated set of architectural architectural, structural, mechanical, fire protection, electrical and plumbing working drawings for the Tenant Improvement Work, in a form which is sufficiently complete to allow permit subcontractors to bid on the work and to work, obtain all applicable permits required Permits (collectively, as hereinafter defined) and commence construction (the "Final Working Drawings"). Tenant shall furnish Landlord with four (4) and copies signed by Tenant of such Final Working Drawings. Landlord shall submit approve or disapprove of the same Final Working Drawings by giving written notice to Tenant within ten (10) business days after receipt thereof. Landlord shall not unreasonably withhold or delay its approval of the Final Working Drawings, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Final Working Drawings for any of the reasons specified in Section 2.2 above, or if in Landlord's approval good faith judgment, the Final Working Drawings are inconsistent with, or reasonable disapprovaldo not conform to, which approval or reasonable disapproval the Space Plans. If Landlord disapproves the Final Working Drawings, Landlord shall be delivered by Landlord return the Final Working Drawings to Tenant no later than with a statement of Landlord's reasons for disapproval and/or specifying any required corrections or revisions. Landlord shall approve or disapprove of any such revisions to the Final Working Drawings within five (5) business days after Landlord's receipt of such Final Working Drawingsrevisions. If This procedure shall be repeated until Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to approves the Final Working Drawings to meet (as so approved, the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final "Approved Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained").

Final Working Drawings. After the Final Space Plan has been approved by Landlord, Tenant shall supply the Architects and Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the Final Working Drawings (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings with complete specifications in a form which is complete to allow subcontractors to bid on all of the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord for Landlord's ’s approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered four (4) copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of The Final Working Drawings shall comply with the Final Working Drawings, Space Plan and the parties specifications. Landlord shall meet, advise Tenant within five ten (510) business days after Landlord's disapproval, to agree upon revisions to be made to ’s receipt if the Final Working Drawings to meet the reasonable satisfaction of Landlordare unsatisfactory or incomplete in any respect. The Architect If Tenant is so advised, Tenant shall then immediately revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove in connection therewith and submit the revised Final Working Drawings to Landlord no later than five ten (510) business days after Landlord delivers its advice. Landlord's receipt of such revised Final Working Drawings. If Landlord ’s failure to advise timely shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedbe deemed approval.

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the "“Final Working Drawings") ”), and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval ’s approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord to shall advise Tenant no later than within five (5) business days after Landlord's Xxxxxxxx’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, the parties Tenant shall meet, within five promptly (5i) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than to Landlord. The sequence of submitting and reviewing the Final Working Drawings shall continue within the time periods provided herein until the Final Working Drawings are approved. If Landlord fails to respond to any Final Working Drawings submitted for review and approval within five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Xxxxxxxx’s receipt, Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedbe deemed to have granted its approval.

Final Working Drawings. Tenant Based on the Final Space Plan, Landlord shall cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord Tenant for Landlord's approval or reasonable disapprovalTenant’s approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, which approval or reasonable disapproval the actual specifications and finish work shall be delivered by Landlord to in accordance with the Specifications. Tenant no later than shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to delivers the Final Working Drawings or any revisions thereto to meet the reasonable satisfaction of Landlord. The Architect shall then revise Tenant; provided, however, that Tenant may only disapprove the Final Working Drawings to the form agreed upon extent the same are not (subject to changes reasonably required by Landlord) in such meetingsubstantial conformance with the Final Space Plan (“Working Drawing Design Problem”). Landlord shall then approve or Tenant’s failure to reasonably disapprove the revised Final Working Drawings no later than or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval pertaining to any Working Drawing Design Problem) within said five (5) business days after Landlord's receipt day period shall be deemed to constitute Tenant’s approval of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedor such revisions.

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the "“Final Working Drawings") ”), and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval ’s approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord shall reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, advise Tenant within five (5) days Business Days after Landlord's disapproval, to agree upon revisions to be made to ’s receipt of the Final Working Drawings to meet for the reasonable satisfaction of LandlordPremises if the same is unsatisfactory or incomplete in any respect and the manner in which the Final Working Drawings is unsatisfactory or incomplete. The Architect If Tenant is so advised, Tenant shall then promptly (i) revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than to Landlord. In the event Landlord fails to respond within such five (5) business days Business Day period, Tenant shall send a reminder notice to Landlord and Landlord’s failure to respond to the reminder notice within two (2) Business Days after receipt thereof shall be deemed approval by Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. Tenant and Following Landlord’s approval of the Space Plans, Tenant’s Architect shall prepare and submit for Landlord’s approval complete the architectural drawings for the Expansion Spaceand detailed construction plans and specifications, and the Architect shall compile including a fully coordinated set of architectural architectural, structural, mechanical, fire protection, electrical and plumbing working drawings for the Tenant Improvement Work, in a form which is sufficiently complete to allow permit subcontractors to bid on the work and to work, obtain all applicable permits required Permits (collectively, as hereinafter defined) and commence construction (the "“Final Working Drawings"”). Landlord shall approve or disapprove of the Final Working Drawings by giving written notice to Tenant within ten (10) and business days after receipt thereof. Landlord shall submit not unreasonably withhold or condition its approval of the same to Final Working Drawings, provided that, without limiting the generality of the foregoing, Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered by entitled to withhold its consent to the Final Working Drawings for any of the reasons specified in Section 3.2 above, or if in Landlord’s good faith judgment, the Final Working Drawings are inconsistent with, or do not conform to, the Space Plans. If Landlord disapproves the Final Working Drawings, Landlord shall return the Final Working Drawings to Tenant no later than with a statement of Landlord’s reasons for disapproval and/or specifying any required corrections or revisions. Landlord shall approve or disapprove of any such revisions to the Final Working Drawings necessitated by Landlord’s comments or initiated by Tenant within five (5) business days after Landlord's receipt of such Final Working Drawingsrevisions. If This procedure shall be repeated until Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to approves the Final Working Drawings to meet (as so approved, the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final “Approved Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained”).

Final Working Drawings. Tenant After the Final Space Plan has been approved by Lessor, Lessee shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Lessor and Lessee, Lessee shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings with complete specifications in a form which is complete to allow subcontractors to bid on all of the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord Lessor for Landlord's approval or reasonable disapprovalLessor’s approval, which approval or reasonable disapproval shall be delivered four (4) copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt Lessee of such Final Working Drawings. Lessor shall advise Lessee within seven (7) business days after Lessor’s receipt of the Final Working Drawings for the New Premises and Existing Premises, as applicable, if the same is reasonably unsatisfactory or incomplete in any respect. If Landlord reasonably disapproves Lessee is so advised, Lessee shall immediately revise the Final Working Drawings in accordance with such review and any disapproval of Lessor in connection therewith and submit the revised Final Working Drawings to Lessor no later than seven (7) business days after Lessor delivers its advice. If Lessor makes any portion of objections to the Final Working Drawings, the parties and provided such objections are reasonable, Lessee shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings and cause such objections to be remedied in the form agreed upon in such meetingrevised Final Working Drawings. Landlord Within two (2) business days after Lessor receives the revised Final Working Drawings, Lessor shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord This procedure shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review be repeated until the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable is finally approved by Lessor and written approval is obtainedhas been delivered to and received by Lessee. Lessor’s failure to advise timely shall be deemed approval. Lessor acknowledges that Lessee plans to utilize design-build MEPFS sub contractors.

Final Working Drawings. Tenant Tenant, the Architect and the Architect Engineers shall complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval or reasonable disapprovalas set forth below. Following Landlord's approval of the applicable Final Space Plan, Tenant, the Architect and the Engineers shall complete the Final Working Drawings for the applicable phase of the Tenant Improvements in a form which approval or reasonable disapproval is sufficient to allow contractors to bid on the work and to obtain all applicable permits and shall be delivered by submit the same to Landlord to Tenant no later than for Landlord's approval. Landlord shall, within five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion all of the Final Working Drawings, either (i) approve the parties Final Working Drawings, (ii) approve the Final Working Drawings subject to specified conditions, or (iii) disapprove and return the Construction Drawings to Tenant with requested revisions; provided, however, Landlord shall meetonly disapprove such Final Working Drawings to the extent of a Design Problem. If Landlord disapproves the Final Working Drawings, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to Tenant may resubmit the Final Working Drawings to meet Landlord at any time, and Landlord shall approve or disapprove the reasonable satisfaction of Landlordresubmitted Final Working Drawings, based upon the criteria set forth in this Section 3.3, within three (3) business days after Landlord receives such resubmitted Final Working Drawings. The Architect Such procedure shall then revise be repeated until the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedare approved.

Final Working Drawings. Following Landlord's approval of the Space Plans, Tenant shall cause Tenant's Architect and the Architect shall Engineers to prepare and submit for Landlord's approval complete the architectural drawings for the Expansion Spaceand detailed construction plans and specifications, and the Architect shall compile including a fully coordinated set of architectural architectural, structural, mechanical, fire protection, electrical and plumbing working drawings for the Tenant Improvement Work, in a form which is sufficiently complete to allow permit subcontractors to bid on the work and to work, obtain all applicable permits required Permits (collectively, as hereinafter defined) and commence construction (the "Final Working Drawings"). Tenant shall furnish Landlord with four (4) and copies signed by Tenant of such Final Working Drawings. Landlord shall submit approve or disapprove of the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered Final Working Drawings by Landlord giving written notice to Tenant no later than within five (5) business days after Landlord's receipt of such Final Working Drawingsthereof. If Landlord reasonably disapproves of any portion shall not unreasonably withhold, condition or delay its approval of the Final Working Drawings, provided that, without limiting the parties generality of the foregoing, Landlord shall meet, within five (5) days after Landlord's disapproval, be entitled to agree upon revisions to be made withhold its consent to the Final Working Drawings to meet if in Landlord's good faith judgment, the reasonable satisfaction of LandlordFinal Working Drawings are inconsistent with, or do not conform to, the Space Plans. The Architect If Landlord disapproves the Final Working Drawings, Landlord shall then revise return the Final Working Drawings to the form agreed upon in such meetingTenant with a statement of Landlord's reasons for disapproval and/or specifying any required corrections or revisions. Landlord shall then approve or reasonably disapprove of any such revisions to the revised Final Working Drawings no later than within five (5) business days after Landlord's receipt of such revised Final Working Drawingsrevisions. If This procedure shall be repeated until Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review approves the Final Working Drawings again in accordance with (as so approved, the procedure set forth above until Landlord's reasonable approval is obtained"Approved Working Drawings").

Final Working Drawings. Tenant After the Final Space Plan has been approved by Lessor, which approval shall not be unreasonably withheld, Lessee shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Lessor and Lessee, Lessee shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings with complete specifications in a form which is complete to allow subcontractors to bid on all of the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord Lessor for Landlord's approval or reasonable disapprovalLessor’s approval, which approval or reasonable disapproval shall not be delivered unreasonably withheld, four (4) copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt Lessee of such Final Working Drawings. If Landlord reasonably disapproves of any portion Lessor shall advise Lessee within ten (10) business days after Lessor’s receipt of the Final Working DrawingsDrawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Lessee is so advised, the parties Lessee shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then immediately revise the Final Working Drawings to the form agreed upon in accordance with such meeting. Landlord shall then approve or reasonably disapprove review and any disapproval of Lessor in connection therewith and submit the revised Final Working Drawings to Lessor no later than five ten (510) business days after Landlord's receipt of such revised Final Working DrawingsLessor delivers its advice. If Landlord Lessor’s failure to advise timely shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedbe deemed approval.

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the "“Final Working Drawings") ”), and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval ’s approval. Tenant shall be delivered supply Landlord with two (2) copies signed by Tenant of such Final Working Drawings. Landlord to shall advise Tenant no later than within five (5) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, the parties Tenant shall meet, within five promptly (5i) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than five (5) to Landlord. Unless Landlord provides comments or changes within 5 business days after Landlord's ’s receipt of such revised the Final Working Drawings. If Landlord shall again reasonably disapprove the Drawings or any revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedas last submitted shall be deemed approved.

Final Working Drawings. Tenant On or before the date set forth in Schedule 1, Tenant, the Architect and the Architect Engineers shall complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord for Landlord's approval or reasonable disapproval’s approval. Landlord shall, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than within five (5) business days after Landlord's ’s receipt of such the Final Working Drawings. If Landlord reasonably disapproves of any portion of Drawings either (i) approve the Final Working Drawings, (ii) approve the parties Final Working Drawings subject to specified conditions to be satisfied by Tenant prior to submitting the Approved Working Drawings for permits as set forth in Section 3.4, below, if the Final Working Drawings do not comply with the Final Space Plan or contain a design problem, or (iii) disapprove and return the Final Working Drawings to Tenant with detailed requested revisions if the Final Working Drawings do not comply with the Final Space Plan or contain a design problem. If Landlord disapproves the Final Working Drawings, Tenant shall meet, resubmit the Final Working Drawings to Landlord within five (5) days after Landlord's disapprovalbusiness days, to agree upon revisions to be made to and Landlord shall approve or disapprove of the resubmitted Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than within five (5) business days after Landlord's receipt of Lxxxxxxx receives such revised resubmitted Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord for Landlord's approval or reasonable disapproval’s approval, which approval shall not be unreasonably withheld or reasonable disapproval delayed. Tenant shall be delivered supply Landlord with four (4) copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion shall advise Tenant within ten (10) business days after Xxxxxxxx’s receipt of the Final Working DrawingsDrawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, the parties Tenant shall meetwithin ten (10) business days, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedsuch review and any disapproval of Landlord in connection therewith.

Final Working Drawings. After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant, the Architect and the Engineers shall promptly complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval or reasonable disapprovalapproval. Landlord shall, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than within five (5) business days after Landlord's receipt of such the Final Working Drawings (i) approve the Final Working Drawings or (ii) disapprove the Final Working Drawings for a Design Problem (as defined in Section 3.2 above) and return the same to Tenant with requested revisions. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties Tenant shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to resubmit the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.within five

Final Working Drawings. Tenant and the Architect shall complete the architectural drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working DrawingsFINAL WORKING DRAWINGS") and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the "“Final Working Drawings") ”), and shall submit the same to 37849147v5 Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval ’s approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall have the right to have its building architect and engineers review the Final Working Drawings. Landlord shall advise Tenant no later than within five (5) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawings for the Premises if, in Landlord’s reasonable determination, the parties same is unsatisfactory or incomplete in any respect. Landlord shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to not disapprove the Final Working Drawings to meet if the reasonable satisfaction of Landlordsame are consistent with the Construction Drawings. The Architect If Tenant is so advised, Tenant shall then promptly (i) revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any reasonable disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than five (5) business days after to Landlord's receipt of such revised Final Working Drawings. If Landlord The foregoing process shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review be repeated until the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedare approved.

Final Working Drawings. Tenant Landlord, the Architect and the Architect Engineers shall ---------------------- complete the architectural and engineering drawings for the Expansion SpaceImprovements, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord Tenant for LandlordTenant's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Tenant to Landlord to Tenant no later than five (5) business days after LandlordTenant's receipt of such Final Working Drawings. If Landlord Tenant reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after LandlordTenant's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of LandlordTenant. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord Tenant shall then approve or reasonably disapprove the revised Final Working Drawings no later than five two (52) business days after LandlordTenant's receipt of such revised Final Working Drawings. If Landlord Tenant shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until LandlordTenant's reasonable approval is obtained. The Final Working Drawings, as approved by Tenant, may be referred to herein as the "Approved Working Drawings."

Final Working Drawings. After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord for Landlord's approval or reasonable disapproval’s approval, which approval shall not be unreasonably withheld, conditioned or reasonable disapproval delayed; provided that Landlord and Tenant hereby agree that it shall be delivered by deemed reasonable for Landlord to withhold its approval of the Final Working Drawings if a Design Problem exists or the Final Working Drawings are not substantially consistent with the Final Space Plan. Tenant no later than shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawings for the Premises if the same is unsatisfactory or incomplete in any respect, then the parties shall meet, within five (5) days after Landlord's disapproval, promptly meet and confer and negotiate in good faith to agree upon revisions to be made to reach an agreement on the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. Following Landlord's approval of the Space ---------------------- Plans, Tenant shall cause Tenant's Architect and the Architect shall Engineers to prepare and submit for Landlord's approval complete the architectural drawings for the Expansion Spaceand detailed construction plans and specifications, and the Architect shall compile including a fully coordinated set of architectural architectural, structural, mechanical, fire protection, electrical and plumbing working drawings for the Tenant Improvement Work, in a form which is sufficiently complete to allow permit subcontractors to bid on the work and to work, obtain all applicable permits required Permits (collectively, as hereinafter defined) and commence construction (the "Final Working Drawings"). Tenant shall furnish Landlord with four (4) and copies signed by Tenant of such Final Working Drawings. Landlord shall submit approve or disapprove of the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered Final Working Drawings by Landlord giving written notice to Tenant no later than within five (5) business days after Landlord's receipt of such Final Working Drawingsthereof. If Landlord reasonably disapproves of any portion shall not unreasonably withhold or delay its approval of the Final Working Drawings, provided that, without limiting the parties generality of the foregoing, Landlord shall meet, within five (5) days after Landlord's disapproval, be entitled to agree upon revisions to be made withhold its consent to the Final Working Drawings to meet for any of the reasonable satisfaction of reasons specified in Section 2.2 above, or if in Landlord's good faith judgment, the Final Working Drawings are inconsistent with, or do not conform to, the Space Plans. The Architect If Landlord disapproves the Final Working Drawings, Landlord shall then revise return the Final Working Drawings to the form agreed upon in such meetingTenant with a statement of Landlord's reasons for disapproval and/or specifying any required corrections or revisions. Landlord shall then approve or reasonably disapprove of any such revisions to the revised Final Working Drawings no later than within five (5) business days after Landlord's receipt of such revised Final Working Drawingsrevisions. If This procedure shall be repeated until Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review approves the Final Working Drawings again in accordance with (as so approved, the procedure set forth above until Landlord's reasonable approval is obtained"Approved Working Drawings").

Final Working Drawings. Tenant After Landlord approves the Final Space Plan, Tenant, the Architect and the Architect Engineers shall complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working DrawingsFINAL WORKING DRAWINGS ") and shall submit the same to Landlord for Landlord's approval or reasonable disapprovalapproval. However, which approval or reasonable disapproval if Tenant reasonably determines that the Engineers are not reasonably responsive to Tenant's requirements, Tenant may so notify Landlord in writing and if Landlord does not cause such Engineers to be so responsive within one (1) business day after receipt of Tenant's notice, then the thirty (30) day period set forth above shall be delivered by extended for each day after the expiration of said one (1) business day cure period that completion of the Final Working Drawings are so delayed as a result of the failure of the Engineers to be reasonably responsive. Landlord to shall advise Tenant no later than within five (5) business days after Landlord's receipt of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect and Landlord's failure to give Tenant written notice of any such objection within said five (5) business-day period shall be deemed approval by Landlord of the Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to notifies Tenant that the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect are deficient in any respect, Tenant shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than within five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will thereafter revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedsuch review and any disapproval of Landlord in connection therewith.

Final Working Drawings. Tenant Based on the approved Preliminary Plans, Landlord shall cause Landlord's architect and the Architect shall engineer to complete the architectural and engineering drawings for the Expansion SpaceVertical Exhaust, and cause the Architect shall architect to compile a fully coordinated set of architectural architectural, structural and mechanical working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Tenant for Tenant's approval, not to be unreasonably withheld. The Final Working Drawings shall incorporate modifications to the Preliminary Plans as necessary to comply with the structural and system requirements of the Building as well as changes required by applicable laws. Except for changes required by applicable laws, any material Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval modification to the Final Workings Drawings shall be delivered by Landlord subject to Tenant's reasonable approval, not to be unreasonably withheld. Tenant no later than shall approve or reasonably disapprove the Final Working Drawings within five (5) business days after Landlord's receipt of such Landlord delivers the same to Tenant or within three (3) business days after Landlord delivers any Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawing revisions thereto to Tenant; provided, the parties shall meethowever, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise that Tenant may only disapprove the Final Working Drawings to the form agreed upon extent the same are not in substantial conformance with the Preliminary Plans. Failure of Tenant to respond to Landlord before the expiration of any such meeting. Landlord time periods set forth above shall then approve or reasonably disapprove be deemed Tenant's approval of the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised The Final Working Drawings, once approved (or deemed approved) by Tenant, may be referred to herein as the parties will revise and review the Final "Approved Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedDrawings."

Final Working Drawings. Tenant Based on the Final Space Plan, Landlord shall cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord Tenant for LandlordTenant's approval or reasonable disapprovalapproval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, which approval or reasonable disapproval the actual specifications and finish work shall be delivered by Landlord to in accordance with the Specifications. Tenant no later than shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to delivers the Final Working Drawings or any revisions thereto to meet the reasonable satisfaction of Landlord. The Architect shall then revise Tenant; provided, however, that Tenant may only disapprove the Final Working Drawings to the form agreed upon extent the same are not (subject to changes reasonably required by Landlord) in such meetingsubstantial conformance with the Final Space Plan ("Working Drawing Design Problem"). Landlord shall then approve or Tenant's failure to reasonably disapprove the revised Final Working Drawings no later than or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant's disapproval pertaining to any Working Drawing Design Problem) within said five (5) business days after Landlordday period shall be deemed to constitute Tenant's receipt approval of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedor such revisions.

Final Working Drawings. Tenant On or before January 31, 2013, Tenant, the Architect and the Architect Engineers (if any) shall complete the architectural and engineering drawings for the Expansion Space, and Premises based on the Architect shall compile a fully coordinated set of Final Space Plan. The final architectural working drawings shall be in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and ). Tenant shall submit four (4) hard copies signed by Tenant of the same Final Working Drawings to Landlord for Landlord's approval approval, and concurrently with Tenant's delivery of such hard copies, Tenant shall send to Landlord via electronic mail one (1) .pdf electronic copy of such Final Working Drawings. Landlord shall approve or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Landlord reasonably disapprove (with a detailed breakdown of the changes requested in order to Tenant no later than obtain Landlord's approval) the Final Working Drawings within five (5) business days after delivery of the same to Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meetTenant shall, within five three (53) business days after from its receipt of Landlord's disapproval, cause the Architect and/or Engineers to agree upon revise such drawings and will resubmit the Final Working Drawings, as revised, to the Landlord for its approval; provided that Landlord's approval right will be limited to those items disapproved on the previous Final Working Drawings or any changes made by Tenant to such prior Final Working Drawings. Such procedure will be repeated (except that the time to consent to any revisions will be shortened to be made to three (3) business days) until the Final Working Drawings to meet the reasonable satisfaction of are approved by Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. Tenant On or before the date set forth in Schedule 1, Tenant, the Architect and the Architect Engineers shall complete the architectural and engineering drawings for the Expansion Space, and the Architect shall compile a fully coordinated set of final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working DrawingsFINAL WORKING DRAWINGS") and shall submit the same to Landlord for Landlord's approval or reasonable disapprovalapproval. However, which approval or reasonable disapproval if Tenant reasonably determines that the Engineers are not reasonably responsive to Tenant's requirements, Tenant may so notify Landlord in writing and if Landlord does not cause such Engineers to be so responsive within one (1) business day after receipt of Tenant's notice, then the time period set forth in Schedule 1 shall be delivered by extended for each day after the expiration of said one (1) business day cure period that completion of the Final Working Drawings are so delayed as a result of the failure of the Engineers to be reasonably responsive. Landlord to shall advise Tenant no later than within five (5) business days after Landlord's receipt of the Final Working Drawings for the Expansion Space if the same is unsatisfactory or incomplete in any respect and Landlord's failure to give Tenant written notice of any such objection within said five (5) business-day period shall be deemed approval by Landlord of the Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to notifies Tenant that the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect are deficient in any respect, Tenant shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than within five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will thereafter revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedsuch review and any disapproval of Landlord in connection therewith.

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements and which shall include a list of all specifications to be used in connection with the Tenant Improvements, which shall in all events be consistent with the character of the Buildings as first-class office and R&D buildings (collectively, the "Final Working Drawings") ), and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord to shall advise Tenant no later than within five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet for the reasonable satisfaction of LandlordPremises if the same is unsatisfactory or incomplete in any respect. The Architect If Tenant is so advised, Tenant shall then promptly (i) revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than five (5) business days after to Landlord for Landlord's receipt of such revised Final Working Drawings. If Landlord approval, and the foregoing procedure shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review be repeated until the Final Working Drawings again in accordance with are approved by Landlord (which approved Final Working Drawings shall be referred to herein as the procedure set forth above until Landlord's reasonable approval is obtained"Approved Working Drawings").

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Suite 1100 Expansion Space, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Suite 1100 Tenant Improvements (collectively, the "“Final Working Drawings") ”), and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval ’s approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord to shall advise Tenant no later than within five (5) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawings for the Suite 1100 Expansion Space if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, the parties Tenant shall meet, within five promptly (5i) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than to Landlord. The sequence of submitting and reviewing the Final Working Drawings shall continue within the time periods provided herein until the Final Working Drawings are approved. If Landlord fails to respond to any Final Working Drawings submitted for review and approval within five (5) business days after Landlord's ’s receipt and if such failure continues for one (1) additional business day after receipt of such revised Final Working Drawings. If Tenant’s second request for approval, Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedbe deemed to have granted its approval.

Final Working Drawings. Tenant Tenant, the Architect and the Architect Engineers ---------------------- shall complete the architectural architectural, engineering, structural, mechanical, electrical and plumbing drawings for the Expansion Space, and the Architect shall compile a fully coordinated set of architectural working drawings Premises in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval approval. The Final Working Drawings may be submitted in one or reasonable disapprovalmore stages at one or more times, which approval or reasonable disapproval provided that Tenant shall be delivered ultimately supply Landlord with four (4) completed copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of shall, within three (3) business days after Landlord receives the Final Working Drawings, either (a) approve the parties shall meetFinal Working Drawings, within five (5b) days after Landlord's disapproval, approve the Final Working Drawings subject to agree upon revisions specified conditions to be made satisfied by Tenant prior to submitting the Approved Working Drawings for permits as set forth in Section 2.4, below, or (c) disapprove the Final Working Drawings and return them to Tenant with requested revisions; provided, however, that Landlord shall only be entitled to conditionally approve pursuant to item (b) above or disapprove pursuant to item (c) above the Final Working Drawings if they materially deviate from the Construction Drawings, or for any of the following reasons: (i) an adverse effect on the structural integrity of the Building; (ii) non-compliance with applicable laws; (iii) an adverse effect on the systems and equipment of the Building; or (iv) an adverse effect on the exterior appearance of the Building (individually or collectively, a "Design Problem"). If Landlord disapproves the Final Working Drawings, Tenant may resubmit the Final Working Drawings to meet Landlord at any time, and Landlord shall approve or disapprove of the reasonable satisfaction of Landlord. The Architect shall then revise the resubmitted Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five within two (52) business days after Landlord's receipt of Landlord receives such revised resubmitted Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. Tenant Promptly after the Final Space Plan is approved by Landlord in accordance with Section 3.2, the Architect and the Architect Engineers (with reasonable input by Landlord) shall complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord Tenant for Landlord's Tenant’s approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Tenant to Landlord no later than five (5) days after Tenant’s receipt of such Final Working Drawings. Once Tenant has approved the Final Working Drawings, they shall be delivered to Landlord for Landlord’s reasonable approval, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than five three (53) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five three (53) business days after Landlord's ’s disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five three (53) business days after Landlord's ’s receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's ’s reasonable approval is obtained.

Final Working Drawings. Tenant and the Architect shall complete the architectural drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. , If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. Tenant Within twenty (20) business days following Landxxxx'x xpproval of the Final Space Plan, Tenant, Architect, the MPE Subcontractors and the Architect Engineer shall complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set C-3 47 of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the " FINAL WORKING DRAWINGS"Final Working Drawings") ), and shall submit the same to Landlord for Landlord's approval approval. Landlord shall diligently review the Final Working Drawings and shall either approve or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than five disapprove the Final Working Drawings within three (53) business days after Landlord's following receipt of such Final Working Drawings. If thereof, and if Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five two (52) business days after Landlord's disapprovalLandxxxx'x xisapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of LandlordLandlord and Tenant. The Architect shall then then, within two (2) business days after such meeting, revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, and in the parties will revise and review case of disapproval, the foregoing process shall be repeated until the Final Working Drawings again in accordance with the procedure set forth above until are approved by Landlord's reasonable approval is obtained.

Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and cause the Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a 37849147v5 form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the "“Final Working Drawings") ”), and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which approval or reasonable disapproval ’s approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall have the right to have its building architect and engineers review the Final Working Drawings. Landlord shall advise Tenant no later than within five (5) business days after Landlord's ’s receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working DrawingsDrawings for the Premises if, in Landlord’s reasonable determination, the parties same is unsatisfactory or incomplete in any respect. Landlord shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to not disapprove the Final Working Drawings to meet if the reasonable satisfaction of Landlordsame are consistent with the Construction Drawings. The Architect If Tenant is so advised, Tenant shall then promptly (i) revise the Final Working Drawings to the form agreed upon in accordance with such meeting. review and any reasonable disapproval of Landlord shall then approve or reasonably disapprove the in connection therewith, and (ii) deliver such revised Final Working Drawings no later than five (5) business days after to Landlord's receipt of such revised Final Working Drawings. If Landlord The foregoing process shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review be repeated until the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedare approved.

Final Working Drawings. Tenant Tenant, the Architect and the Architect Engineer shall complete the architectural and engineering drawings for the Expansion Space, and the Architect shall compile a fully coordinated set of architectural working drawings Premises in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings"“FINAL WORKING DRAWINGS”) and shall submit the same to Landlord for Landlord's approval ’s approval. The Final Working Drawings may be submitted in one or reasonable disapprovalmore stages at one or more times, which approval or reasonable disapproval provided that Tenant shall be delivered ultimately supply Landlord with four (4) completed copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of shall, within ten (10) business days after Landlord receives the Final Working Drawings, either (i) approve the parties shall meetFinal Working Drawings, within five (5ii) days after Landlord's disapproval, approve the Final Working Drawings subject to agree upon revisions specified conditions to be made satisfied by Tenant prior to submitting the Approved Working Drawings for permits as set forth in SECTION 3.4, below, if the Final Working Drawings do not comply with the Final Space Plan or contain a Design Problem, or (iii) disapprove and return the Final Working Drawings to meet Tenant with requested revisions if the reasonable satisfaction of LandlordFinal Working Drawings do not comply with the Final Space Plan or contain a Design Problem. The Architect shall then revise If Landlord disapproves the Final Working Drawings, Tenant may resubmit the Final Working Drawings to the form agreed upon in such meeting. Landlord at any time, and Landlord shall then approve or reasonably disapprove of the revised resubmitted Final Working Drawings no later than five Drawings, based upon the criteria set forth in this SECTION 3.3, within two (52) business days after Landlord's receipt of Landlord receives such revised resubmitted Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained.

Final Working Drawings. After the approval and final correction of the Final Space Plan, Tenant shall promptly cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpaceSpace and the Existing Premises, as applicable, and the cause Architect shall to compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and Tenant shall submit the same to Landlord for Landlord's approval or ’s reasonable disapproval, which approval or reasonable disapproval approval. Tenant shall be delivered supply Landlord with four (4) copies signed by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion shall advise Tenant, with reasonable specificity, within ten (10) business days after Landlord’s receipt of the Final Working DrawingsDrawings for the Expansion Space or the Existing Premises, as applicable, if Landlord reasonably determines that the parties same are unsatisfactory or incomplete in any respect. If Landlord fails to advise Tenant of any such deficiency within said ten (10) business day period, then Landlord shall meet, within five (5) days after Landlord's disapproval, be deemed to agree upon revisions to be made to the have approved such Final Working Drawings to meet the reasonable satisfaction of LandlordDrawings. The Architect If Tenant is so advised, Tenant shall then immediately revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtainedsuch review and any disapproval of Landlord in connection therewith.

Final Working Drawings. Tenant Based on the Final Space Plan, Landlord shall cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord Tenant for LandlordTenant's approval or reasonable disapprovalapproval. The Final Working Drawings may incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, which approval or reasonable disapproval the actual specifications and finish work shall be delivered by Landlord to in accordance with the Specifications. Tenant no later than five shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three (53) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to delivers the Final Working Drawings or any revisions thereto to meet the reasonable satisfaction of Landlord. The Architect shall then revise Tenant; provided, however, that Tenant may only disapprove the Final Working Drawings to the form agreed upon extent the same are not (subject to changes reasonably required by Landlord) in such meetingsubstantial conformance with the Final Space Plan ("Working Drawing Design Problem"). Landlord shall then approve or Tenant's failure to reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again or any revisions thereto by written notice to Landlord (which notice shall specify in accordance with detail the procedure set forth above until Landlordreasonable reasons for Tenant's reasonable disapproval pertaining to any Working Drawing Design Problem) within said three (3) business day period shall be deemed to constitute Tenant's approval is obtainedof the Final Working Drawings or such revisions.

Final Working Drawings. Tenant Landlord, the Architect and the Architect Engineers shall ---------------------- complete the architectural and engineering drawings for the Expansion Space, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord Tenant for LandlordTenant's approval or reasonable disapproval, which approval or reasonable disapproval shall be delivered by Tenant to Landlord to Tenant no later than five (5) business days after LandlordTenant's receipt of such Final Working Drawings. If Landlord Tenant reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after LandlordTenant's disapproval, to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of LandlordTenant. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord Tenant shall then approve or reasonably disapprove the revised Final Working Drawings no later than five two (52) business days after LandlordTenant's receipt of such revised Final Working Drawings. If Landlord Tenant shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until LandlordTenant's reasonable approval is obtained. The Final Working Drawings, as approved by Tenant, may be referred to herein as the "Approved Working Drawings."

Final Working Drawings. Tenant and Landlord shall use commercially reasonable efforts to cause the Architect shall to complete the detailed architectural and engineering drawings for the Expansion SpaceTenant Improvements shown on the Final Space Plan, and the Architect shall compile a fully coordinated set of final detailed architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”). Within five (5) and days after Architect’s completion of the Final Working Drawings, Landlord shall submit the same to Landlord Tenant for Landlord's approval or Tenant’s reasonable disapprovalapproval, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than provided within five (5) business days after Landlord's of receipt of such the same; provided, however, that except to the extent Tenant disapproves the Final Working DrawingsDrawings as being inconsistent with the Final Space Plan, such disapproval shall be deemed a Tenant Delay (as hereinafter defined). If Landlord reasonably disapproves Tenant’s disapproval is not delivered within five (5) business days of any portion receipt of the Final Working Drawings, Tenant’s approval shall be deemed to have been given. If Tenant disapproves of the parties Final Working Drawings Tenant shall meetdeliver to Landlord, within such five (5) days after Landlord's disapprovalbusiness day period, specific changes proposed by Tenant. Landlord shall cause the Architect to agree upon revisions to be made to the Final Working Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to incorporate such revisions and submit the form agreed upon same for Tenant’s approval in such meeting. Landlord shall then approve or reasonably disapprove accordance with the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawingsforegoing provisions, and the parties will revise and review shall follow the foregoing procedures for approving the Final Working Drawings again in accordance with until the procedure set forth above until Landlord's reasonable approval is obtainedsame are finally approved by Landlord and Tenant.

Final Working Drawings. Based upon that certain final space plan for all Tenant Improvements in the Premises ("Final Space Plan") attached hereto as Exhibit "C-1", Landlord shall cause the Architect and the Architect shall Engineers to complete and deliver to Tenant for Tenant's reasonable approval four (4) copies of complete fully coordinated architectural and (to the architectural extent required) structural, mechanical, electrical and plumbing working drawings and specifications for the Expansion Space, and Tenant Improvements for the Architect shall compile a fully coordinated set of architectural working drawings Premises in a form which is sufficiently complete to allow all subcontractors to bid on the work shown therein and to obtain all applicable permits Permits therefor, if any (defined below) (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval or reasonable disapproval). Tenant shall, which approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than within five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of Tenant receives the Final Working Drawings, either (i) approve the parties Final Working Drawings, or (ii) reasonably disapprove and return the same to Landlord with Tenant's reasonably requested Changes. If Tenant reasonably disapproves the Final Working Drawings, then Landlord shall meet, within five (5) days after cause Landlord's disapprovalArchitect to make all such reasonable Tenant requested Changes thereto required to satisfy Tenant's reasonably requested Changes and shall resubmit to Tenant such Final Working Drawings, to agree upon revisions with the foregoing procedure to be made to repeated until the Final Working Drawings to meet for the reasonable satisfaction of LandlordPremises are ultimately approved by Tenant (as so approved, the "Approved Working Drawings"). The Architect shall then revise the Final Approved Working Drawings for the Premises and all parts or components thereof are sometimes referred to herein as the form agreed upon in such meeting. Landlord shall then approve or reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working "Construction Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is obtained."

Final Working Drawings. Tenant Based on the Final Space Plan, Landlord shall cause the Architect and the Architect shall Engineers to complete the architectural and engineering drawings for the Expansion SpacePremises, and the Architect shall compile a fully coordinated set of architectural architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "“Final Working Drawings"”) and shall submit the same to Landlord Tenant for Landlord's approval or reasonable disapprovalTenant’s approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, which approval or reasonable disapproval the actual specifications and finish work shall be delivered by Landlord to in accordance with the Specifications. Tenant no later than shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to delivers the Final Working Drawings or any revisions thereto to meet the reasonable satisfaction of Landlord. The Architect shall then revise Tenant; provided, however, that Tenant may only disapprove the Final Working Drawings to the form agreed upon extent the same are not (subject to changes reasonably required by Landlord) in such meetingsubstantial conformance with the Final Space Plan (“Working Drawing Design Problem”). Landlord shall then approve or Tenant’s failure to reasonably disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again or any revisions thereto by written notice to Landlord (which notice shall specify in accordance with detail the procedure set forth above until Landlord's reasonable reasons for Tenant’s disapproval pertaining to any Working Drawing Design Problem) within said five (5)-business day period shall be deemed to constitute Tenant’s approval is obtainedof the Final Working Drawings or such revisions.