Common use of Final Working Drawings Clause in Contracts

Final Working Drawings. Based on the Final Space Plan, Landlord shall cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant for Tenant’s approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings or such revisions.

Final Working Drawings. Based on the Final Space Plan, Landlord shall cause the Architect and the Engineers to complete the architectural and engineering drawings for the PremisesThird Expansion Space, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant for Tenant’s approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Third Expansion Space Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three seven (37) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant; provided, however, that Tenant may only disapprove the Final Working Drawings to the extent the same are not (subject to changes reasonably required by Landlord) in substantial conformance with the Final Space Plan (“Working Drawing Design Problem”). Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapprovaldisapproval pertaining to any Working Drawing Design Problem) within said five seven (57) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings or such revisions.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Remaining Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Remaining Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow subcontractors all of Tenant's Agents to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings , which shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned, or delayed. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Remaining Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly cause the Final Working Drawings to be revised in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non standard equipment and specifications, including, without limitation, BTU calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which that is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow subcontractors all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval. The Final Working Drawings , which shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned, or delayed. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. TenantLandlord’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly cause the Final Working Drawings to be revised in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the subject Phase of the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the subject Phase of the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Tenant shall supply Landlord with four (4) hard copies signed by Tenant of the Final Working Drawings, and concurrently with Tenant's delivery of such hard copies, Tenant shall send to Landlord via electronic mail one (1) .pdf electronic copy of such Final Working Drawings. Landlord shall advise Tenant within ten (10) business days after Landlord's receipt of the Final Working Drawings for the subject Phase of the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall incorporate modifications to immediately revise the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be Working Drawings in accordance with the Specificationssuch review and any disapproval of Landlord in connection therewith. If Landlord fails to notify Tenant of Landlord's approval or disapproval of any such Final Working Drawings within such ten (10) business day period, Tenant shall approve or reasonably disapprove have the right to provide Landlord with a second written request for approval (a "Working Drawing Second Request") that specifically identifies the Final Working Drawings and contains the following statement in bold and capital letters: "THIS IS A SECOND REQUEST FOR APPROVAL PURSUANT TO THE PROVISIONS OF SECTION 3.3 OF THE WORK LETTER ATTACHED TO THE LEASE. IF LANDLORD FAILS TO RESPOND WITHIN FIVE (5) BUSINESS DAYS AFTER RECEIPT OF THIS NOTICE, THEN LANDLORD SHALL BE DEEMED TO HAVE APPROVED THE FINAL WORKING DRAWINGS." If Landlord fails to respond to such Working Drawing Second Request within five (5) business days after receipt by Landlord, the Final Working Drawings in question shall be deemed approved by Landlord. Subject to Landlord's obligation to perform the Code Work, if the Final Working Drawings or any revisions amendment thereof or supplement thereto within three shall require alterations in the Base Building (3as contrasted with the Improvements), and if Landlord in its sole and exclusive discretion agrees to any such alterations, and notifies Tenant of the need and cost for such alterations, then Tenant may elect to either: (i) business days after Landlord delivers value engineer the Final Working Drawings so as to reduce or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove eliminate such cost, or (ii) pay the Final Working Drawings or any revisions thereto by written cost of such required changes in advance upon receipt of notice to Landlord (which notice thereof, and in either case Tenant shall specify pay all direct architectural and/or engineering fees in detail the reasonable reasons for Tenant’s disapproval) within said connection with such Base Building changes, plus five percent (5%) business day period of such direct costs for Landlord's servicing and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings or such revisionsoverhead.

Final Working Drawings. Based on Tenant shall supply the Architects and Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, HVAC requirements, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the Final Space Plan, Landlord Working Drawings (as defined below) in the manner as set forth below. Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, Tenant’s Work and Architect shall compile a fully fully-coordinated set of architectural, structuralstructural (if required), mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval. The Final Working Drawings , which approval shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned or delayed. Tenant shall approve or reasonably disapprove supply Landlord with two (2) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Working Drawings for Tenant’s Work if the same is unsatisfactory or incomplete in any revisions thereto within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenantrespect. TenantLandlord’s failure to reasonably disapprove respond within the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenantshall be deemed as Landlord’s continued failure to disapprove approval. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings within two (2) business days after receipt in accordance with such review and any disapproval of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings or such revisionsLandlord in connection therewith.

Final Working Drawings. Based on the Final Space Plan, Landlord shall cause the Architect and the Engineers to complete the architectural and engineering drawings for the PremisesExpansion Space, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant for Tenant’s 's approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Expansion Space Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant; provided, however, that Tenant may only disapprove the Final Working Drawings to the extent the same are not (subject to changes reasonably required by Landlord) in substantial conformance with the Final Space Plan ("Working Drawing Design Problem"). Tenant’s 's failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval's disapproval pertaining to any Working Drawing Design Problem) within said five ten (510) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s 's approval of the Final Working Drawings or such revisions.

Final Working Drawings. Based on Tenant shall supply the Architects and Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, HVAC requirements, electrical requirements and special electrical receptacle requirements for the Reduced Premises, to enable the Engineers and the Architect to complete the Final Space Plan, Landlord Working Drawings (as defined below) in the manner as set forth below. Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, Tenant’s Work and Architect shall compile a fully fully-coordinated set of architectural, structuralstructural (if required), mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval. The Final Working Drawings , which approval shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned or delayed. Tenant shall approve or reasonably disapprove the supply Landlord with two (2) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant, in writing, within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord’s receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings if the same are unsatisfactory or incomplete in any respect (and specify in such revisionswritten notice the unsatisfactory items). Landlord’s failure to respond within the said 5-business day period shall be deemed as Landlord’s disapproval. If Tenant is so advised, Tenant shall promptly review the Final Working Drawings in accordance with such review and any disapproval of Landlord in connection therewith and submit revised Final Working Drawings for Landlord’s approval in accordance with the terms hereof.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Btu calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”"FINAL WORKING DRAWINGS") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow subcontractors all of Tenant's Agents to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings , which shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned, or delayed. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect with reasonable specificity. If Tenant is so advised, Tenant shall promptly cause the Final Working Drawings to be revised in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow subcontractors all of Tenant's Agents to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings , which shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned, or delayed. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Xxxxxxxx's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly cause the Final Working Drawings to be revised in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval. The Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings Drawings. Landlord shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements advise Tenant in writing within five (5) business days after Landlord’s receipt of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any revisions thereto within three (3) business days after Landlord delivers respect, specifying with reasonable specificity the reasons for Landlord’s objection and/or the changes needed to eliminate Landlord’s objection. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such review and correct any deficiencies or any revisions thereto other matters Landlord may reasonably require. In the event that Landlord fails to Tenant. Tenant’s failure respond to reasonably disapprove Tenant regarding the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail within the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove set forth above, then the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings or such revisionshave been approved by Landlord.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord and Tenant, Landlord Tenant shall promptly cause the Architect and the Engineers Contractor to complete the architectural and engineering drawings for the PremisesExpansion Space, and cause the Architect shall to compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the “"Final Working Drawings”) "), and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings , which shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specificationsunreasonably withheld. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Expansion Space if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith, and (ii) deliver such revised Final Working Drawings to Landlord. Landlord and Tenant shall continue such process until Landlord has reasonably approved the Final Working Drawings.

Final Working Drawings. Based on After the Construction Drawings have been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, BTU calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Space PlanWorking Drawings” (as defined below) in the manner as set forth below. Upon the approval of the Construction Drawings by Landlord and Tenant, Landlord Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which that is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for Tenant’s Landlords’ approval. The Final Working Drawings , which approval shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned or delayed. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. TenantLandlord’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisions.review and any disapproval of Landlord in connection therewith. Halozyme, Inc. First Amendment to Standard Industrial Net Lease Page 4 of 8

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval. The Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings Drawings. Landlord shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the advise Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord’s receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect as reasonably detem1ined by Landlord. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on the Final Space Plan, Landlord shall cause enlist Engineers and Architect to assist Tenant in evaluating requirements for Tenant’s standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to ensure all Tenant’s requirements for operation are to completely represented in the “Final Working Drawings” (as that term is defined in below). On or before the date set forth in Section 5 below, Architect and the Engineers to shall complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant for Tenant’s reasonable approval. The Landlord may also submit the same to the appropriate municipal authorities for all applicable building permits. Landlord shall supply Tenant with two (2) full size sets and (2) half size sets signed by the Architect of such Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the SpecificationsDrawings. Tenant shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto advise Landlord within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and days after Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Landlord is so advised, Landlord shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Tenant in connection therewith.

Final Working Drawings. Based on Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space PlanPlan by Landlord and Tenant, Landlord Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the supply Landlord with one (1) electronic copy and, upon Landlord's request, no more than two (2) hard copies of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on the Final Space Preliminary Plan, Landlord Tenant shall cause the Architect and the Engineers Contractor to complete the architectural and engineering drawings for the PremisesTenant Improvements, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical architectural and plumbing working drawings MEP Design-Build Drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval, which shall not be unreasonably withheld. The Final Working Drawings shall incorporate modifications to the Final Space Preliminary Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Preliminary Plan or the Approved Working Drawings for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord’s receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith, and (ii) deliver such revised Final Working Drawings to Landlord. Landlord and Tenant shall continue such process until Landlord has reasonably approved the Final Working Drawings.

Final Working Drawings. Based on (a) As soon as practicable after Tenant’s approval of the Final Approved Space Plan, Landlord Tenant shall cause the Architect preparation and the Engineers to submit for Landlord’s approval complete the architectural and engineering drawings for the Premisesdetailed construction plans and specifications, and Architect shall compile including a fully coordinated set of architectural, structural, mechanical, fire protection, electrical and plumbing working drawings for the Tenant Improvement Work, in a form which is sufficiently complete to allow permit subcontractors to bid on the work and to work, obtain all applicable permits required Permits (collectively, as hereinafter defined) and commence construction (the “Final Working Drawings”) and shall submit the same to Tenant for Tenant’s approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications). Tenant shall furnish Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall approve or reasonably disapprove of the Final Working Drawings or any revisions thereto by giving written notice to Tenant within three ten (310) business days after receipt thereof. (b) Landlord delivers shall not unreasonably withhold or delay its approval of the Final Working Drawings, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Final Working Drawings if in Landlord’s good faith judgment, (i) any one or more of the following situations exist: (A) the proposed Tenant Improvements will adversely affect the exterior appearance of the Project; (B) the proposed Tenant Improvements may impair the structural strength of the Project, adversely affect the roof or any revisions thereto of the Building Systems or materially adversely affect the value of the Project; (C) the proposed Tenant Improvement Work would trigger the necessity under Governmental Requirements or otherwise for work to Tenant. Tenant’s failure to reasonably disapprove be performed outside the Premises; (D) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project; or (ii) the Final Working Drawings are inconsistent with, or any revisions thereto by written notice do not conform to, the Approved Space Plan. (c) If Landlord disapproves the Final Working Drawings, Landlord shall return the Final Working Drawings to Landlord (which notice shall specify in detail the reasonable Tenant with a statement of Landlord’s reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure disapproval and/or specifying any required corrections or revisions. Landlord shall approve or disapprove of any such revisions to disapprove the Final Working Drawings within two five (25) business days after receipt of a second written notice such revisions. This procedure shall be deemed to constitute Tenant’s approval of repeated until Landlord approves the Final Working Drawings (as so approved, the “Approved Working Drawings”). (d) If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in any portion of the Building Systems outside of the Premises, and Landlord approves such revisionschanges or alterations, such changes or alterations shall be made at Tenant’s expense.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within ten (10) business days after Landlord's receipt of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect, provided that Landlord shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably only disapprove the Final Working Drawings or any revisions thereto within three (3) business days after Landlord delivers for reasonable and material reasons, such as if the same do not comply with the Final Working Drawings Space Plan or any revisions thereto contain a Design Problem. Landlord agrees that it shall work with reasonable diligence to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval complete its review of the Final Working Drawings or in fewer than ten (10) business days. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, BTU calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which that is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved as provided in Section 4.1 above, Landlord Tenant shall supply Tenant's architect with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable Tenant's architect to complete the "Working Drawings" (as that term is defined below) in the manner as set forth below. Upon the approval of the Space Plan as provided in Section 4.1 above, Tenant shall promptly cause the Architect and the Engineers Tenant's architect to complete the architectural and engineering drawings for the Premises, and Architect Tenant's architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final "Working Drawings”") and shall submit the same to Landlord. Tenant shall supply Landlord with four (4) copies signed by Tenant's architect of such Working Drawings. Landlord shall advise Tenant in writing within ten (10) days after Landlord's receipt of the Working Drawings for Tenant’s approvalthe Premises if the same is materially inconsistent with other existing Buildings in the Project or incomplete in any respect, in Landlord's reasonable discretion. The Final If Tenant is so advised, Tenant shall immediately revise the Working Drawings to correct the same. If Landlord fails to respond in writing to Tenant within ten (10) days after receiving the Working Drawings, then the Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings or such revisionsapproved by Landlord.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval. The Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings Drawings. Landlord shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the advise Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three ten (310) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. TenantLandlord’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days after receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such revisionsreview and any disapproval of Landlord in connection therewith.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall promptly supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Landlord shall provide Tenant with copies of any documentation containing the foregoing information that is in Landlord's possession or control. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “"Final Working Drawings”") and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings , which approval shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereonbe unreasonably withheld, the actual specifications and finish work shall be in accordance with the Specificationsconditioned or delayed. Tenant shall approve or reasonably disapprove the supply Landlord with two (2) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove the Final Working Drawings within two (2) business days Business Days after Landlord's receipt of a second written notice shall be deemed to constitute Tenant’s approval of the Final Working Drawings for the Premises if the same is unsatisfactory or such revisionsincomplete in any reasonable respect. If Tenant is so advised, Tenant shall promptly revise the Final Working Drawings to correct any deficiencies or other matters Landlord may reasonably require.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow subcontractors all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. The Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings Drawings, Landlord shall incorporate modifications to not unreasonably withhold, condition, or delay its approval of the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the BuildingWorking Drawings. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant Landlord shall approve or reasonably disapprove the Final Working Drawings or any revisions thereto within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove of the Final Working Drawings within two ten (210) business days after Landlord’s receipt of a second written notice thereof. If Landlord reasonably withholds its approval, Landlord shall be deemed to constitute Tenant’s approval of provide Tenant with the Final Working Drawings or such revisionsspecific reasons therefor.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord and Tenant, Landlord Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the PremisesExpansion Space, and cause the Architect shall to compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the “"Final Working Drawings”) "), and shall submit the same to Tenant Landlord for Tenant’s Landlord's approval. The Final Working Drawings , which shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specificationsunreasonably withheld. Tenant shall approve or reasonably disapprove the supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings or any revisions thereto Drawings. Landlord shall advise Tenant within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove days after Landlord's receipt of the Final Working Drawings within two (2) business days after receipt for the Expansion Space if the same is unsatisfactory or incomplete in any reasonable respect, and failure of a second written notice Landlord to so advise during such period shall be deemed to constitute TenantLandlord’s approval of the Final Working Drawings. If Tenant is so advised, Tenant shall promptly (i) revise the Final Working Drawings or in accordance with such revisionsreview and any reasonable disapproval of Landlord in connection therewith, so long as Landlord sets forth with specificity the particular aspects of the Final Working Drawings that are disapproved and describes the code-compliant changes necessary, and (ii) deliver such revised Final Working Drawings to Landlord.

Final Working Drawings. Based on After the Final Space PlanPlan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow subcontractors all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the “‘‘Final Working Drawings”) and shall submit the same to Tenant Landlord for TenantLandlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. The Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings Drawings, Landlord shall incorporate modifications to not unreasonably withhold, condition, or delay its approval of the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the BuildingWorking Drawings. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the Tenant Improvements depicted thereon, the actual specifications and finish work shall be in accordance with the Specifications. Tenant Landlord shall approve or reasonably EXHIBIT A disapprove the Final Working Drawings or any revisions thereto within three (3) business days after Landlord delivers the Final Working Drawings or any revisions thereto to Tenant. Tenant’s failure to reasonably disapprove the Final Working Drawings or any revisions thereto by written notice to Landlord (which notice shall specify in detail the reasonable reasons for Tenant’s disapproval) within said five (5) business day period and Tenant’s continued failure to disapprove of the Final Working Drawings within two ten (210) business days after Landlord’s receipt of a second written notice thereof. If Landlord reasonably withholds its approval, Landlord shall be deemed to constitute Tenant’s approval of provide Tenant with the Final Working Drawings or such revisionsspecific reasons therefor.