Particular Methods of Procurement of Consultants’ Services 1. Quality- and Cost-based Selection. Except as otherwise provided in paragraph 2 below, consultants’ services shall be procured under contracts awarded on the basis of Quality and Cost-based Selection.
Other Methods of Procurement of Consultants’ Services The following table specifies the methods of procurement, other than Quality and Cost-based Selection, which may be used for consultants’ services. The Procurement Plan shall specify the circumstances under which such methods may be used. (a) Quality-based Selection (b) Selection under a Fixed Budget
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever. (ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties. (iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority. (iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i). (v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party. (vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway. (vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Virus Management DST shall maintain a malware protection program designed to deter malware infections, detect the presence of malware within DST environment.
Trunk Group Architecture and Traffic Routing 5.2.1 The Parties shall jointly establish Access Toll Connecting Trunks between CLEC and CBT by which they will jointly provide Tandem-transported Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic from and to CLEC's Customers. 5.2.2 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access and non-translated Toll Free traffic (e.g., 800/888) to allow CLEC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier that is connected to the CBT access Tandem. 5.2.3 The Access Toll Connecting Trunks shall be one-way or two-way trunks, as mutually agreed, connecting an End Office Switch that CLEC utilizes to provide Telephone Exchange Service and Switched Exchange Access Service in the given LATA to an access Tandem Switch CBT utilizes to provide Exchange Access in the LATA.
WINDOW CLEANING Tenant shall not clean, nor require, permit, suffer or allow any window in the Premises to be cleaned from the outside in violation of Section 202 of the Labor Law, or any other Requirement, or of the rules of the Board of Standards and Appeals, or of any other board or body having or asserting jurisdiction.
Access Toll Connecting Trunk Group Architecture 9.2.1 If CSTC chooses to subtend a Verizon access Tandem, CSTC’s NPA/NXX must be assigned by CSTC to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG. 9.2.2 CSTC shall establish Access Toll Connecting Trunks pursuant to applicable access Tariffs by which it will provide Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic to and from CSTC’s Customers. 9.2.3 The Access Toll Connecting Trunks shall be two-way trunks. Such trunks shall connect the End Office CSTC utilizes to provide Telephone Exchange Service and Switched Exchange Access to its Customers in a given LATA to the access Tandem(s) Verizon utilizes to provide Exchange Access in such LATA. 9.2.4 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access to allow CSTC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier which is connected to a Verizon access Tandem.
Description of the procurement Under this Lot the supplier will provide the below packs (this list is not exhaustive): o Orthopaedic Day Case o Hip Arthroplasty o Knee Arthroplasty o Shoulder Arthroplasty o Arthroscopy- Knee, Hip, Shoulder, Ankle o Hand Surgery o Foot & Ankle Surgery o ACL (Anterior Cruciate Ligament) o Spine- Lumbar, Cervical TERMS AND CONDITIONS / ACTIVITY BASED INCOME (ABI) The terms and conditions of this Agreement and any resulting call-off contract is appended to the ITT. These terms include provisions requiring the payment by the supplier of an ABI management charge in consideration of the award of this Agreement, the management and administration by HTE of the overall contract structure and associated documentation, as well as the requirement to submit regular management information to HTE. SUBMISSION OF EXPRESSIONS OF INTEREST AND PROCUREMENT INFORMATION This exercise will be conducted on the HTE Bravo portal. Candidates wishing to be considered must register expressions of interest as follows: Register on the HTE portal at xxxxx://xxxxxxxxxxxxxxxxx.xxxxxxxxxxxxx.xx.xx. Login to the portal with username/password. Click the SQs/ITTs Open to All Suppliers link. These are the SQs/ITTs open to any registered supplier. Click on the relevant SQ/ ITT to access the content. Click the Express Interest button at the top of the page. This will move the SQ/ITT into your My SQs/My ITTs page. You can access any attachments by clicking Buyer Attachments in the SQ/ITT Details box. Follow the onscreen instructions to complete the SQ/ITT. Submit your reply using the Submit Response button at the top of the page. If you require any further advice, contact the Bravo e- Tendering Help Desk at xxxx@xxxxxxxxxxxxx.xx.xx. Sid4Gov HTE utilises the sid4gov supplier information database. Candidates should register on sid4gov at xxxxx://xxx0xxx.xxxxxxxxxxxxx.xxx.xx/organisation/register and submit their sid4gov company profile for publication on the database. Candidates already registered on sid4gov must ensure information is up to date. Where access to sid4gov is unavailable, please contact the sid4gov helpdesk at xxx0xxx@xxx.xxx.xxx.xx. Please note that sid4gov does not prepopulate any fields of the SQ on HTE's Bravo portal. Candidates must complete the Qualification & Technical Envelopes of the SQ in Bravo in full.
Procurement of Small Works Works estimated to cost $250,000 equivalent or less per contract, up to an aggregate amount not to exceed $800,000 equivalent, may be procured under lump-sum, fixed-price contracts awarded on the basis of quotations obtained from three (3) qualified domestic contractors in response to a written invitation. The invitation shall include a detailed description of the works, including basic specifications, the required completion date, a basic form of agreement acceptable to the Bank, and relevant drawings, where applicable. The award shall be made to the contractor who offers the lowest price quotation for the required work, and who has the experience and resources to complete the contract successfully. Part D: Review by the Bank of Procurement Decisions
