Investment Description Each Fund will invest and reinvest its assets in accordance with the investment objective(s), policies and limitations specified in the prospectus (the “Prospectus”) relating to such Fund filed with the Securities and Exchange Commission (the “SEC”) as part of the Fund’s Registration Statement on Form N-1A, as it may be periodically amended or supplemented and in accordance with exemptive orders and no-action letters issued to the Trust by the SEC and its staff.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Escrow Analysis If applicable, with respect to each Mortgage Loan, the Seller has within the last twelve months (unless such Mortgage was originated within such twelve month period) analyzed the required Escrow Payments for each Mortgage and adjusted the amount of such payments so that, assuming all required payments are timely made, any deficiency will be eliminated on or before the first anniversary of such analysis, or any overage will be refunded to the Mortgagor, in accordance with RESPA and any other applicable law;
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Contract Closeout The Provider Agency shall comply with all requirements of Policy Circular P7.01, Contract Closeout, including the timely submittal of the Final Report of Expenditures and any other financial or programmatic reports required by the Department. All required documentation is due within 120 Days of Contract Expiration, Non-renewal or Termination.
Auction Schedule The Auction Agent shall conduct Auctions in accordance with the schedule set forth below. Such schedule may be changed by the Auction Agent with the consent of the Company, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to each Broker-Dealer. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Company and the Broker-Dealers of the Reference Rate and the Maximum Applicable Rate as set forth in Section 2.2(e)(i) hereof.
Project Closeout a. Participate in final inspection to prepare punch lists for project contractor to correct and/or to complete listed items. Verify that items on punch lists have been completed successfully assist COUNTY Project Manager or designee to determine completion date and coordinate project close out.
a. Coordinate the preparation, acceptance and distribution of project closeout documents in accordance with COUNTY Project Manager or designee procedures to clients.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof.
6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement.
6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement.
6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER.
6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing.
6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8.
6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Capital Projects (a) The selection of all design professionals and contractors for capital projects shall be made by Lessor and Lessor shall provide at its expense all materials and services for capital projects.
(b) Lessee shall cooperate with Lessor with respect to capital projects. Notwithstanding anything in the foregoing which may be construed to the contrary, Lessee shall have no obligation to perform any such capital projects unless Lessee agrees to perform and be responsible for same in accordance with a written agreement therefor between Lessor and Lessee.