INDEMNITY FOR INFRINGEMENT CLAIMS EXCEPT TO THE EXTENT ARISING FROM MATERIALS PROVIDED TO CONTRACTOR BY UNIVERSITY, WHICH MATERIALS ARE UTILIZED BY CONTRACTOR IN THEIR UNALTERED FORM AND WITHOUT LIMITING THE GENERALITY OF THE INDEMNIFICATION CLAUSE REFERENCED IN THE HOLD HARMELSS SECTION BELOW, CONTRACTOR EXPRESSLY AGREES TO INDEMNIFY AND HOLD HARMLESS UNIVERSITY AND ITS DIRECTORS, OFFICERS, EMPLOYEES, AND AGENTS FROM AND AGAINST ANY AND ALL CLAIMS, SUITS, ACTIONS, LOSSES, LIABILITIES, COSTS, EXPENSES, AND DAMAGES ARISING OUT OF OR RELATED TO ANY CLAIMS THAT THE DELIVERABLES INFRINGE ANY PATENT, COPYRIGHT, TRADE SECRET, TRADEMARK, TRADE DRESS, MASK WORK, UTILITY DESIGN, OR OTHER PROPRIETARY RIGHT OF ANY THIRD PARTY. The indemnity under this Section will not apply to the extent such alleged or actual infringement arises as a result of (i) modifications of such work made by University which were not approved by Contractor, or (ii) Contractor’s compliance with any of University’s designs, specifications or instructions. In the event that a court of competent jurisdiction determines in a final, non-appealable order that the work is infringing in a manner for which Contractor is obligated to indemnify University pursuant to this Section, Contractor will, at its option, either (1) procure for University the right to continue using such infringing work; (2) replace the infringing work with a non-infringing item of like form, fit or function; or (3) modify the work so that it no longer infringes.
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”):
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Procedure for Indemnification After receipt by an indemnified party under Section 11.1, Section 11.2, Section 11.3 or Section 11.4 of notice of the commencement of any action, such indemnified party shall, if a claim in respect thereof is to be made against an indemnifying party under such Section, give written notice to the indemnifying party of the commencement thereof. The failure to promptly notify the indemnifying party shall not relieve it of any liability that it may have to any indemnified party with respect to such action; provided that, to the extent that any such failure to provide prompt notice is responsible for an increase in the indemnity obligations of the indemnifying party, the indemnifying party shall not be responsible for any such increase. In case any such action shall be brought against an indemnified party and it shall give written notice to the indemnifying party of the commencement thereof, the indemnifying party shall be entitled to participate therein and, to the extent that it may wish, to assume the defense thereof with counsel reasonably satisfactory to such indemnified party. If the indemnifying party elects to assume the defense of such action, the indemnified party shall have the right to employ separate counsel at its own expense and to participate in the defense thereof. If the indemnifying party elects not to assume (or fails to assume) the defense of such action, the indemnified party shall be entitled to assume the defense of such action with counsel of its own choice, at the expense of the indemnifying party. If the action is asserted against both the indemnifying party and the indemnified party and (i) there is a conflict of interests which renders it inappropriate for the same counsel to represent both the indemnifying party and the indemnified party or (ii) such action could reasonably be expected to result in the imposition of criminal liability, the indemnifying party shall be responsible for paying for separate counsel for the indemnified party; provided, however, that if there is more than one indemnified party and it is practical for all such parties to be represented by common counsel, the indemnifying party shall not be responsible for paying for more than one separate firm of attorneys to represent the indemnified parties, regardless of the number of indemnified parties. If the indemnifying party elects to assume the defense of such action, (a) no compromise or settlement thereof may be effected by the indemnifying party without the indemnified party’s written consent (which shall not be unreasonably withheld) unless the sole relief provided is monetary damages that are paid in full by the indemnifying party and (b) the indemnifying party shall have no liability with respect to any compromise or settlement thereof effected without its written consent (which shall not be unreasonably withheld) unless the indemnifying party has failed to defend such indemnified party against such action. If this Section 11.5 conflicts with the contest provisions in Section 8.7 with respect to any contest or claim relating to taxes, Section 8.7 shall govern.
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.
INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Survival Indemnification All representations, warranties and covenants contained in this Agreement and the indemnification contained herein shall survive (a) the acceptance of this Agreement by the Company, (b) changes in the transactions, documents and instruments described herein which are not material or which are to the benefit of Subscriber, and (c) the death or disability of Subscriber. Subscriber acknowledges the meaning and legal consequences of the representations, warranties and covenants in Article II hereof and that the Company has relied upon such representations, warranties and covenants in determining Subscriber's qualification and suitability to purchase the Securities. Subscriber hereby agrees to indemnify, defend and hold harmless the Company, its officers, directors, employees, agents and controlling persons, from and against any and all losses, claims, damages, liabilities, expenses (including attorneys' fees and disbursements), judgments or amounts paid in settlement of actions arising out of or resulting from the untruth of any representation of Subscriber herein or the breach of any warranty or covenant herein by Subscriber. Notwithstanding the foregoing, however, no representation, warranty, covenant or acknowledgment made herein by Subscriber shall in any manner be deemed to constitute a waiver of any rights granted to it under the Securities Act or state securities laws.
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
