Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
16.2 To the furthest extent permitted by California law, Developer shall also defend Indemnitees, at its own expense, including but not limited to attorneys’ fees and costs, against all Claims caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Facilities Lease by Developer, its Subcontractors, vendors, or suppliers. However, without impacting Developer’s obligation to provide an immediate and ongoing defense of Indemnitees, Developer’s defense obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent caused by the sole negligence, active negligence, or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. The District shall have the right to accept or reject any legal representation that Xxxxxxxxx proposes to defend the Indemnitees. If any Indemnitee provides its own defense due to failure to timely respond to tender of defense, rejection of tender of defense, or conflict of interest of proposed counsel, Developer shall reimburse such Indemnitee for any expenditures. Developer’s defense obligation shall not be construed to negate, abridge, or otherwise reduce any right or obligation of defense that would otherwise exist as to any Indemnitee or other person described herein. Developer’s defense obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any provision of law, any failure or alleged failure to timely and properly fulfill all of its obligations under the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developer’s obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. Developer shall give prompt notice to the District in the event of any Claim(s).
16.3 Without limitation of the provisions herein, if Xxxxxxxxx’s obligation to indemnify and hold harmless the Indemnitees or its obligation to defend Indemnitees as provided herein shall be determined to be void or unenforceable, in whole or in part, it is the intention of the Parties that these circumstances shall not otherwise affect the validity or enforceability of Developer’s agreement to indemnify, defend, and hold harmless the rest of the Indemnitees, as provided herein. Further, Developer shall be and remain fully liable on its agreements and obligations herein to the fullest extent permitted by law.
Indemnification and Remedies 10.1. The Shareholders and the holders of Vested Options (“Indemnifying Parties”) agree severally and not jointly to protect, defend, indemnify, and hold the Purchaser, the Company and their Affiliates, together with the directors, employees and advisors of the foregoing (the “Indemnified Parties”), harmless against and in respect of any and all loss, liability, deficiency, damage, decrease in value (excluding reduction in Tax losses or loss of NOLs), any damages paid to third parties, cost, expense, fines, interest or actions in respect thereof (including reasonable legal fees and expenses) but excluding consequential (except that a claim by a third party shall not be deemed consequential), incidental, multiple of revenue or earnings (but not including loss of value), loss of profits, punitive or exemplary damages (all of the foregoing, “Damages”), as and when incurred, occasioned by: (i) any non-fulfillment, non-performance, violation or breach of this Agreement or any Transaction Document by the Company; or (ii) any inaccuracy, breach or falsity of any of the representations and warranties of the Company contained in Section 5 above or any certificate or other instrument furnished or to be furnished by the Company hereunder; (iii) any Claim by a third party (regardless of whether the claimant is ultimately successful) which, if true, would constitute any of the above; and (iv) disregarding any disclosure in a disclosure schedule, any Pre-Closing Taxes and (disregarding any disclosure in a disclosure schedule) any breach or falsity contained in Sections 5.7, 6.8, 8.2.19, 8.11 or 8.12, any Tax liability of the Company in connection with any payment made or deemed made by the Company at or prior to the Closing in connection with the Transaction or any Tax liability in connection with any payment pursuant to this Agreement made without sufficient withholding under applicable law provided however, that the Shareholders shall not be jointly liable for a Claim in connection to Tax withholding against a breaching Shareholder for submission of incorrect or false information (in which case, such breaching Shareholder shall be severally liable as set forth in Section 10.2); (v) disregarding any disclosure in a disclosure schedule), any Transaction Costs, (vi) disregarding any disclosure in a disclosure schedule), any liability pursuant to indemnification undertakings granted by the Company to directors and/or officers thereof in connection with the period prior to the Closing Date; (vii) disregarding any disclosure in a disclosure schedule), the matters set out in Schedule 10.1 attached hereto; (viii) disregarding any disclosure in a disclosure schedule), any Claim by a Shareholder, or former shareholder (or holder of Company Options, including indemnity for Damages of such holder in respect of the rate of taxes paid by such holder in excess of the 102 benefit (25% plus excess tax, if applicable) in cases where the ITA disqualifies the grant under a trustee capital gains route, or any other equity securities) of the Company, or any other Person, seeking to assert, or based upon: (a) ownership or rights to ownership of any shares or other equity securities of the Company; (b) any rights of a Shareholder or other equity holder (other than the rights of the Shareholders to receive the payments set out in this Agreement, as and to the extent set forth herein), including any option, preemptive rights or rights to notice or to vote; (c) any Claim that his, her or its shares or other equity securities of the Company were wrongfully repurchased, cancelled, terminated or transferred by the Company or any Person; or (d) any Claim regarding any errors or failures in the allocation or calculation of the applicable Purchase Price payable to such Person or its pro rata share of the Escrow Amount, as set forth in the Waterfall (items (iv) to (viii), together the “Special Indemnities”).
10.2. In addition, each Shareholder, severally and not jointly, agrees to protect, defend, indemnify, and hold the Indemnified Parties, harmless against and in respect of any Damages, as and when incurred, occasioned by: (i) any non-fulfillment, non-performance, violation or breach of this Agreement or any Transaction Document by such Shareholder; or (ii) any inaccuracy, breach or falsity of any of the representations and warranties of such Shareholder contained in Section 6 above or any certificate or other instrument furnished or to be furnished by such Shareholder hereunder; and (iii) any Claim by a third party (regardless of whether the claimant is ultimately successful) which, if true, would constitute the above.
10.3. Promptly, but not later than thirty (30) days after (i) receipt by the Purchaser (or any of its directors, employees or advisors) of notice of the commencement of any Claim, proceeding, or investigation (“Third Party Claim”); or (ii) the Purchaser (or any of its directors, employees or advisors) becoming aware of any breach of this Agreement or falsity of representation or other event or circumstance, in each case, in respect of which indemnity may be sought as provided above, shall notify the Shareholder Representative on behalf of the Indemnifying Party of the Claim, proceeding or investigation and, when known, the facts constituting the basis of such Claim, proceeding or investigation, in reasonable detail, provided that any failure to provide such notice to the Shareholder Representative within such period will not relieve the Indemnifying Parties of any obligation or liability, except and only to the extent that the Shareholder Representative demonstrates that the Indemnifying Parties have been materially prejudiced by such failure to provide such notice to the Shareholder Representative within such period. In the event of any such claim for indemnification hereunder resulting from or in connection with any Third Party Claim, the notice to the Shareholder Representative shall specify, if known, the amount of damages asserted by such third party. In the event of any Third Party Claim, the Purchaser shall assume the defense or prosecution of such Third Party Claim and any litigation resulting therefrom (a “Third Party Defense”). Upon the Purchaser’s assumption of the Third Party Defense (i) the Purchaser shall inform the Shareholder Representative of such Third Party Defense (as set forth herein); (ii) the Shareholder Representative may retain separate counsel, at the expense of the Shareholders; (iii) the Purchaser will not consent to the entry of any judgment or enter into any settlement with respect to the Third Party Claim without the prior written consent of the Shareholder Representative which shall not be unreasonably withheld, conditioned or delayed; (iv) the Purchaser shall conduct the Third Party Defense actively and diligently in consultation with the Shareholder Representative and provide copies of all correspondence and related documentation in connection with the Third Party Defense to the Indemnifying Party; and (v) the Indemnifying Party will provide reasonable cooperation in the Third Party Defense to protect the interests of the Indemnified Party. If the Purchaser elects not to assume the Third Party Defense it shall notify the Shareholder Representative of its decision not to assume such defense, and the Shareholder Representative shall have the right to assume the Third Party Defense with counsel of its choice at the expense of the applicable Indemnifying Parties; provided, however, that the Purchaser shall have the right, at its expense, to participate in such Third Party Defense but the Shareholder Representative shall control the investigation and defense thereof in consultation with the Purchaser; provided, however, that any settlement or compromise by the Shareholder Representative shall be subject to the consent of the Purchaser not to be unreasonably withheld, delayed or conditioned. The Shareholder Representative shall conduct the Third Party Defense actively and diligently, and the Purchaser will provide reasonable cooperation in the Third Party Defense. The Parties will in any event co-operate with each other in dealing with any Claim other than in the event of a conflict of interest, and, other than in the event of a conflict of interest, will allow their respective representatives and advisers reasonable access to all books and records which might be useful for such purpose during normal business hours and at the place where they are normally kept, with full right to make copies thereof or take extracts therefrom. Such books and records shall be subject to a duty of confidentiality except for disclosure necessary for resolving such Claim or otherwise required by applicable law. The Indemnifying Party shall not be authorized to settle or compromise any Claim without the written consent of the Indemnified Party, which shall not be unreasonably withheld.
10.4. Notwithstanding anything to the contrary in this Agreement (including Section 10.3), following the Closing Date, the Purchaser will have the right, in the Purchaser’s sole and absolute discretion, to conduct and control, through counsel of the Purchaser’s choosing, the defense of any Tax Contest; provided, however, that to the extent that any Tax Contest could reasonably give rise to an indemnification claim by the Purchaser under this Section 10, the Purchaser will (i) provide notice of such Tax Contest to the Shareholder Representative within thirty (30) days after receiving the first written notice of the commencement of such Tax Contest or from the relevant Governmental Authority, provided that any failure to provide such notice to the Shareholder Representative within such period will not relieve the Shareholders of any obligation or liability, except to the extent that the Shareholders have been materially prejudiced by such failure to provide such notice to the Shareholder Representative within such period, (ii) provide to the Shareholder Representative all information reasonably requested by the Shareholder Representative regarding such Tax Contest, (iii) permit the Shareholder Representative to evaluate and comment on such Tax Contest, and (iv) reasonably and in good faith consider any such comments of the Shareholder Representative. The Purchaser may settle, adjust, or compromise any Tax Contest, in the Purchaser’s sole and absolute discretion, without the consent of the Shareholder Representative. However, without the prior written consent of the Shareholder Representative – which consent (i) will not be unreasonably withheld, delayed, or conditioned and (ii) will be deemed to have been given unless the Shareholder Representative objects in writing within thirty (30) days after receipt of a written request for such consent from the Purchaser – no settlement, adjustment, or compromise of any Tax Contest will be determinative of the existence of a claim for indemnification under this Section 10 or the amount of indemnifiable amounts relating to such claim. In the event that the Shareholder Representative consents in writing to (or is deemed to have consented to) any settlement, adjustment, or compromise of any Tax Contest, neither the Shareholder Representative nor any Shareholder will have any power or authority to object under any provision of this Section 10 to the amount of any claim by the Purchaser for indemnification under this Section 10 with respect to such settlement, adjustment, or compromise.
10.5. Other than with respect to a specific Shareholder for such Shareholder’s Shareholder Fraud Event, the remedies provided in this Section 10 shall be the sole and exclusive remedy of the Purchaser, or any of their Affiliates for any Claims or Damages resulting from the Transaction, except that each Party shall be entitled to injunctive relief to enjoin the breach or threatened breach of any provisions of this Agreement and the specific performance by the other of its obligations hereunder.
10.6. The representation and warranties of the Company and the Shareholders (read together with the disclosure schedules) and the rights of the Purchaser (and its directors, employees and advisors) to indemnification under this Section 10 shall not be affected by any examination made for or on behalf of the Purchaser or the knowledge of any of the Purchaser’s officers, directors, employees or agents. It is understood and agreed that if the Company suffers, incurs or otherwise becomes subject to any Damages as a result of or in connection with any inaccuracy in or breach of any representation, warranty, covenant or obligation (read together with the disclosure schedules) herein, then (without limiting any of the rights of the Purchaser as an Indemnified Party but without double counting and without providing for diminution in value) the Purchaser shall also be deemed, by virtue of its ownership of the shares of the Company, to have incurred Damages as a result of and in connection with such inaccuracy or breach.
Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement or (b) that use of the Licensed Marks by Licensee in accordance with the terms and conditions of this Agreement infringes or otherwise violates a third party’s Trademarks. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless the INFI Indemnitees from and against any and all losses, damages, fees, expenses, settlement amounts or costs (including reasonable legal expense, attorneys’ fees and witness fees) (“Losses”) relating to or in connection with a Third Party claim to the extent arising out of (a) the research, development, manufacture or commercialization of the IPI-145 Compound or the IPI-145 Product by Licensee, any Licensee Affiliate, any Sublicensee, INFI (to the extent properly acting in accordance with Licensee’s express direction) or any of their respective employees, consultants, contractors, subcontractors or agents after the Effective Date, including any actual or alleged death, personal bodily injury or damage to real or tangible personal property, or other product liability claimed to result from the IPI-145 Product Researched, Developed, Manufactured or Commercialized by or on behalf of Licensee or any of its Affiliates or any Sublicensee, (b) any breach by Licensee of any of its representations, warranties, covenants or obligations under this Agreement, or (c) any negligent act or omission or willful misconduct of Licensee, any of its Affiliates or any Sublicensee, or any of their respective employees, consultants, contractors, subcontractors or agents, in performing Licensee’s obligations or exercising Licensee’s rights under this Agreement; except that the foregoing indemnity shall not apply with respect to any INFI Indemnitee to the extent that any such Losses (x) are caused by the gross negligence or willful misconduct of any INFI Indemnitee, or (y) are otherwise subject to an obligation by INFI to indemnify the Licensee Indemnitees under Section 10.2.
INDEMNIFICATION AND ATTORNEYS' FEES (a) The Bank shall indemnify, hold harmless and defend the Executive against reasonable costs, including legal fees, incurred by him in connection with his consultation with legal counsel or arising out of any action, suit or proceeding in which he may be involved, as a result of his efforts, in good faith, to defend or enforce the terms of this Agreement. The Bank agrees to pay all such costs as they are incurred by the Executive, to the full extent permitted by law, and without regard to whether the Bank believes that it has a defense to any action, suit or proceeding by the Executive or that it is not obligated for any payments under this Agreement.
(b) In the event any dispute or controversy arising under or in connection with the Executive's termination is resolved in favor of the Executive, whether by judgment, arbitration or settlement, the Executive shall be entitled to the payment of all back-pay, including salary, bonuses and any other cash compensation, fringe benefits and any compensation and benefits due the Executive under this Agreement.
(c) The Bank shall indemnify, hold harmless and defend the Executive for any act taken or not taken, or any omission or failure to act, by him in good faith while performing services for the Bank or the Company to the same extent and upon the same terms and conditions as other similarly situated officers and directors of the Bank or the Company. If and to the extent that the Bank or the Company, maintains, at any time during the Employment Period, an insurance policy covering the other officers and directors of the Bank or the Company against lawsuits, the Bank or the Company shall use its best efforts to cause the Executive to be covered under such policy upon the same terms and conditions as other similarly situated officers and directors.
Indemnification by Xxxxx Xxxxx agrees to indemnify and hold harmless each of the Fund and the Manager, each of their directors, trustees, members, each of their officers who signed the Registration Statement, and each person, if any, who controls the Fund or the Manager within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act, and each affiliate of the Fund or the Manager within the meaning of Rule 405 under the Securities Act, against any and all loss, liability, claim, damage and expense described in the indemnity contained in subsection (a) of this Section 10, as incurred, but only with respect to (i) any failure by Xxxxx to comply with the prospectus delivery requirements applicable to Placement Shares and (ii) any untrue statements or omissions, or alleged untrue statements or omissions, made in the Registration Statement (or any amendment thereto), any sales material, or any Prospectus (or any amendment or supplement thereto) in reliance upon and in conformity with written information furnished to the Fund or the Manager by Xxxxx expressly for use in the Registration Statement (or any amendment thereto), any sales material, or any Prospectus (or any amendment or supplement thereto). The Fund and the Manager acknowledge that Xxxxx has not furnished any information to the Fund for inclusion in the Prospectus.
Indemnification and Survival Without limitation on any other obligations of the Guarantor or remedies of the Agent and the Lenders under this Guaranty, the Guarantor shall, to the fullest extent permitted by law, indemnify, defend and save and hold harmless the Agent and the Lenders from and against, and shall pay on demand, any and all damages, losses, liabilities and expenses (including reasonable attorneys’ fees and expenses and the allocated cost and disbursements of internal legal counsel) that may be suffered or incurred by the Agent and the Lenders in connection with or as a result of any failure of any Guaranteed Obligations to be the legal, valid and binding obligations of the Borrower enforceable against the Borrower in accordance with their terms. The obligations of the Guarantor under this paragraph shall survive the payment in full of the Guaranteed Obligations and termination of this Guaranty.
Indemnification by Xxxxxx Xxxxxx agrees to indemnify and hold ------------------------- harmless RTI, each of RTI's directors and officers, and each person, if any, who controls RTI within the meaning of the Securities Act or the Exchange Act, from and against any losses, claims, damages or liabilities (or actions or proceedings in respect thereof) to which they may become subject (under the Securities Act or otherwise) insofar as such losses, claims, damages or liabilities (or actions or proceedings in respect thereof) arise out of, or are based upon:
(a) either an untrue statement made in or the omission of a material fact from such Registration Statement in reliance upon and in conformity with written information furnished to RTI by or on behalf of Abbott specifically for use in preparation of the Registration Statement,
(b) the failure of Abbott to comply with the covenants or agreements contained in Section 2.6 hereof, or
(c) any untrue statement or omission in any prospectus that is corrected in any subsequent prospectus that was delivered to Abbott prior to the pertinent sale or sales by Abbott, and Abbott will, as incurred, reimburse RTI and such persons for any legal or other expenses reasonably incurred in investigating, defending, or preparing to defend any such action, proceeding, or claim; provided, however, that in no event shall Xxxxxx'x cumulative aggregate liability under this Section 3.2, or under Section 3.4, or under Sections 3.2 and 3.4 together, exceed the net amount received by Abbott from the sale of the Shares to which such loss relates minus the amount of any damages which Abbott has otherwise been required to pay by reason of such untrue or allegedly untrue statement or omission or alleged omission. RTI - Reg. Rights Agmt May 2, 2000 -9-
Indemnification by Xxxxxxx Each Lender shall severally indemnify the Administrative Agent, within ten (10) days after demand therefor, for (i) any Indemnified Taxes attributable to such Lender (but only to the extent that any Loan Party has not already indemnified the Administrative Agent for such Indemnified Taxes and without limiting the obligation of the Loan Parties to do so), (ii) any Taxes attributable to such Xxxxxx’s failure to comply with the provisions of Section 10.6 relating to the maintenance of a Participant Register and (iii) any Excluded Taxes attributable to such Lender, in each case, that are payable or paid by the Administrative Agent in connection with any Loan Document, and any reasonable expenses arising therefrom or with respect thereto, whether or not such Taxes were correctly or legally imposed or asserted by the relevant Governmental Authority. A certificate as to the amount of such payment or liability delivered to any Lender by the Administrative Agent shall be conclusive absent manifest error. Each Lender hereby authorizes the Administrative Agent to set off and apply any and all amounts at any time owing to such Lender under any Loan Document or otherwise payable by the Administrative Agent to the Lender from any other source against any amount due to the Administrative Agent under this Section 2.20(e).
Indemnification; Remedies The Company shall indemnify the Purchaser, each affiliate of the Purchaser, and each of the following parties participating in a Securitization Transaction: each Sponsor; each issuing entity; each Person (including, but not limited to, any Master Servicer if applicable) responsible for the preparation, execution or filing of any report required to be filed with the Commission with respect to such Securitization Transaction, or for execution of a certification pursuant to Rule 13a-14(d) or Rule 15d-14(d) under the Exchange Act with respect to such Securitization Transaction; each broker dealer acting as underwriter, placement agent or initial purchaser, each Person who controls any of such parties or the Depositor (within the meaning of Section 15 of the Securities Act and Section 20 of the Exchange Act); and the respective present and former directors, officers, employees, agents and affiliates of each of the foregoing and of the Depositor (each, an “Indemnified Party”), and shall hold each of them harmless from and against any claims, losses, damages, penalties, fines, forfeitures, legal fees and expenses and related costs, judgments, and any other costs, fees and expenses that any of them may sustain arising out of or based upon:
(a) (A) any untrue statement of a material fact contained or alleged to be contained in any information, report, certification, accountants’ letter or other material provided in written or electronic format under this Article II by or on behalf of the Company, or provided under this Article II by or on behalf of any Third-Party Originator (collectively, the “Company Information”), or (B) the omission or alleged omission to state in the Company Information a material fact required to be stated in the Company Information or necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading; provided, by way of clarification, that clause (B) of this paragraph shall be construed solely by reference to the Company Information and not to any other information communicated in connection with a sale or purchase of securities, without regard to whether the Company Information or any portion thereof is presented together with or separately from such other information;
(b) any breach by the Company of its obligations under this Article II, including particularly any failure by the Company or any Third-Party Originator to deliver any information, report, certification, accountants’ letter or other material when and as required under this Article II;
(c) any breach by the Company of a representation or warranty set forth in Section 2.02(a) or in a writing furnished pursuant to Section 2.02(b) and made as of a date prior to the closing date of the related Securitization Transaction, to the extent that such breach is not cured by such closing date, or any breach by the Company of a representation or warranty in a writing furnished pursuant to Section 2.02(b) to the extent made as of a date subsequent to such closing date, or
(d) the negligence, bad faith or willful misconduct of the Company in connection with its performance under this Article II. If the indemnification provided for herein is unavailable or insufficient to hold harmless an Indemnified Party, then the Company agrees that it shall contribute to the amount paid or payable by such Indemnified Party as a result of any claims, losses, damages or liabilities incurred by such Indemnified Party in such proportion as is appropriate to reflect the relative fault of such Indemnified Party on the one hand and the Company on the other. In the case of any failure of performance described in clause (a)(ii) of this Section, the Company shall promptly reimburse the Purchaser, any Depositor, as applicable, and each Person responsible for the preparation, execution or filing of any report required to be filed with the Commission with respect to such Securitization Transaction, or for execution of a certification pursuant to Rule 13a-14(d) or Rule 15d-14(d) under the Exchange Act with respect to such Securitization Transaction, for all costs reasonably incurred by each such party in order to obtain the information, report, certification, accountants’ letter or other material not delivered as required by the Company or any Third-Party Originator.
(e) This indemnification shall survive the termination of the Agreement or the termination of any party to the Agreement.
