Indemnification and Litigation Cooperation Sample Clauses

Open Split View

Download

Share

Cite

Indemnification and Litigation Cooperation 

Sample 1Sample 2

Save

Copy

Related to Indemnification and Litigation Cooperation

• Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.

• Indemnification and Liability A. Neither the Contractor, OSC, nor the State shall be liable for any delay or failure in performance beyond its control resulting from acts of war, hostility or sabotage; act of God; electrical, internet or telecommunications outage that is not caused by the obligated party; or government restrictions, or other force majeure. The parties shall use reasonable efforts to eliminate or minimize the effect of such force majeure events upon performance of their respective duties under this Agreement. If such event continues for more than 90 days, either party may terminate all or any agreed upon portion of the Agreement immediately upon written notice. This section does not excuse either party’s obligation to take reasonable steps to follow its normal disaster recovery procedures, or OSC’s obligation to pay for Services provided by the Contractor which have been approved by OSC.

• INDEMNIFICATION AND RECOVERY H-GAC’s liability under this Agreement, whether for breach of contract, warranty, negligence, strict liability, in tort or otherwise, is limited to its order processing charge. In no event will H-GAC be liable for any loss of use, loss of time, inconvenience, commercial loss, lost profits or savings or other incidental, special or consequential damages to the full extent such use may be disclaimed by law. Contractor agrees, to the extent permitted by law, to defend and hold harmless H-GAC, its board members, officers, agents, officials, employees and indemnities from any and all claims, costs, expenses (including reasonable attorney fees), actions, causes of action, judgements, and liens arising as a result of Contractor’s negligent act or omission under this Agreement. Contractor shall notifiy H-GAC of the threat of lawsuit or of any actual suit filed against Contractor relating to this Agreement.

• Indemnification and Save Harmless Provision The Association agrees to indemnify and hold the Board harmless against any liability which may arise by reason of any action taken by the Board in complying with the provisions of this Article.

• Indemnification and General Liability Section 10.4 Required Post-Expiration Coverage.

• Indemnification Process 20.2.1 As used in this Section 20, “Indemnified Person” means a person whom an Indemnifying Party is obligated to indemnify, defend and/or hold harmless under Section 20.1.

• Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.

• Indemnification and Limitation of Liability (a) To the fullest extent that limitations on the liability of Trustees and officers are permitted by the DSTA, the officers and Trustees shall not be responsible or liable in any event for any act or omission of: any agent or employee of the Trust; any Investment Adviser or Principal Underwriter of the Trust; or with respect to each Trustee and officer, the act or omission of any other Trustee or officer, respectively. The Trust, out of the Trust Property, shall indemnify and hold harmless each and every officer and Trustee from and against any and all claims and demands whatsoever arising out of or related to such officer’s or Trustee’s performance of his or her duties as an officer or Trustee of the Trust. This limitation on liability applies to events occurring at the time a Person serves as a Trustee or officer of the Trust whether or not such Person is a Trustee or officer at the time of any proceeding in which liability is asserted. Nothing herein contained shall indemnify, hold harmless or protect any officer or Trustee from or against any liability to the Trust or any Shareholder to which such Person would otherwise be subject by reason of willful misfeasance, bad faith, gross negligence or reckless disregard of the duties involved in the conduct of such Person’s office.

• Indemnification - General The Company shall indemnify, and advance Expenses (as hereinafter defined) to, Indemnitee (a) as provided in this Agreement and (b) to the fullest extent permitted by applicable law in effect on the date hereof and as amended from time to time. The rights of Indemnitee provided under the preceding sentence shall include, but shall not be limited to, the rights set forth in the other Sections of this Agreement.

• Indemnification Procedure Any person obligated to provide indemnification under this Article VIII ("Indemnifying Party" for the purpose of this Section 8.3) will not be liable under the indemnification provisions of this Article VIII with respect to any claim made against a party entitled to indemnification under this Article VIII ("Indemnified Party" for the purpose of this Section 8.3) unless such Indemnified Party will have notified the Indemnifying Party in writing within a reasonable time after the summons or other first legal process giving information of the nature of the claim will have been served upon such Indemnified Party (or after such party will have received notice of such service on any designated agent), but failure to notify the Indemnifying Party of any such claim will not relieve the Indemnifying Party from any liability which it may have to the Indemnified Party against whom such action is brought otherwise than on account of the indemnification provision of this Article VIII, except to the extent that the failure to notify results in the failure of actual notice to the Indemnifying Party and such Indemnifying Party is damaged solely as a result of failure to give such notice. In case any such action is brought against the Indemnified Party, the Indemnifying Party will be entitled to participate, at its own expense, in the defense thereof. The Indemnifying Party also will be entitled to assume the defense thereof, with counsel satisfactory to the party named in the action. After notice from the Indemnifying Party to the Indemnified Party of the Indemnifying Party's election to assume the defense thereof, the Indemnified Party will bear the fees and expenses of any additional counsel retained by it, and the Indemnifying Party will not be liable to such party under this Agreement for any legal or other expenses subsequently incurred by such party independently in connection with the defense thereof other than reasonable costs of investigation, unless: (a) the Indemnifying Party and the Indemnified Party will have mutually agreed to the retention of such counsel; or (b) the named parties to any such proceeding (including any impleaded parties) include both the Indemnifying Party and the Indemnified Party and representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them. The Indemnifying Party will not be liable for any settlement of any proceeding effected without its written consent but if settled with such consent or if there is a final judgment for the plaintiff, the Indemnifying Party agrees to indemnify the Indemnified Party from and against any loss or liability by reason of such settlement or judgment. A successor by law of the parties to this Agreement will be entitled to the benefits of the indemnification contained in this Article VIII. The indemnification provisions contained in this Article VIII will survive any termination of this Agreement.