Indemnification Limitation and Exclusion of Liability Sample Clauses

Open Split View

Download

Share

Cite

Indemnification Limitation and Exclusion of Liability 

Sample 1Sample 2

Save

Copy

Related to Indemnification Limitation and Exclusion of Liability

• LIMITATION AND EXCLUSION OF LIABILITY 1. 6. 1. Traction Software Limited does not exclude its liability (if any) to you: 1. 6. 1. 1. for personal injury or death resulting from Traction Software Limited’s negligence; 2. 6. 1. 2. for any matter for which it would be illegal for Traction Software Limited to exclude or to attempt to exclude its liability; or 3. 6. 1. 3. for fraud. 2. 6. 2. Traction Software Limited makes no express warranties with respect to the Software and Traction Software Limited hereby excludes (to the fullest extent permissible in law), all conditions, warranties (including without limitation any warranty that the Software will meet your requirements or that its operation will be uninterrupted or error free) and stipulations, express (other than those set out in this License) or implied, statutory, customary or otherwise which, but for such exclusion, would or might subsist in favour of you. Except as set out in this License you assume the entire risk as to the quality and performance of the Software. 3. 6. 3. Subject to clause 6. 1 Traction Software Limited will be under no liability to you whatsoever (whether in contract, tort (including negligence), breach of statutory duty, restitution or otherwise) for any injury, death, damage or direct, indirect or consequential loss (all three of which terms include, without limitation, pure economic loss, loss of profits, loss of business, loss of data, loss of savings, depletion of goodwill and like loss) howsoever caused arising out of or in connection with: 1. 6. 3. 1. the Software, or the manufacture or sale or supply, or failure or delay in supply, of the Software by Traction Software Limited or on the part of Traction Software Limited’s employees, agents or sub-contractors; 2. 6. 3. 2. any breach by Traction Software Limited of any of the express or implied terms of this License; 3. 6. 3. 3. any use made of the Software; or 4. 6. 3. 4. any statement made or not made, or advice given or not given, by or on behalf of Traction Software Limited. 4. 6. 4. Subject to clause 6. 1 and without prejudice to clauses 6. 2 and 6. 3 , Traction Software Limited’s aggregate liability under this License(whether in contract, tort (including negligence), breach of statutory duty, restitution or otherwise) for any injury, death, damage or direct or consequential loss (all three of which terms include without limitation of profits, loss of business, depletion of goodwill and like loss) howsoever caused (other than for death or personal injury caused by Traction Software Limited’s negligence) will be limited to the higher of the price paid by you to use the Software or USD $1 00. 5. 6. 5. You acknowledge that the above provisions of this clause 6 are reasonable given the charges made (if any) for the Software and you will accept such risk and/or insure accordingly. 6. 6. 6. Any rights that you have as a consumer are not affected by this clause 6.

• Indemnification Limitation of Liability This Section 10 shall survive the termination of this Agreement. a. The Participant hereby agrees to indemnify and hold harmless the Distributor, Trust, Funds, Transfer Agent and their respective subsidiaries, Affiliated Persons, directors, officers, employees and agents, and each person, if any, who controls such persons within the meaning of Section 15 of the 1933 Act (each a “Participant-Indemnified Party”) from and against any loss, liability, cost and expense (including reasonable attorneys’ fees, collectively “Losses”) incurred by such Participant-Indemnified Party as a result of (i) any breach by the Participant of any provision of this Agreement; (ii) any failure on the part of the Participant to perform any of its obligations set forth in this Agreement; (iii) any failure by the Participant to comply with applicable Law; (iv) representations by any Distributor-Indemnified Party or any Participant Client about the Shares or any Participant-Indemnified Party (including the Trust and/or Fund(s)) that is not included in the Trust’s then-current Prospectus; (v) any untrue statement or alleged untrue statement of a material fact contained in any Section 8.b Materials or any alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading to the extent that such statement or omission relates to the Shares or any Participant-Indemnified Party unless, in either case, such representation, statement or omission was included by the Participant at the written direction of the Trust or the Distributor or taken verbatim (in context and without omission) from the Prospectus or marketing material approved by the Distributor and the Trust; and (vi) actions of such Participant-Indemnified Party in reliance upon any instructions issued to the Trust, the Distributor or the Transfer Agent reasonably believed by any of them to be genuine and to have been given by the Participant or an Authorized Person. The foregoing shall not apply to any Losses incurred by any Participant-Indemnified Party arising out of any Participant-Indemnified Party’s own fraud, bad faith, willful misconduct, gross negligence or reckless disregard of its duties hereunder. b. The Distributor hereby agrees to indemnify and hold harmless the Participant, its respective subsidiaries, Affiliated Persons, directors, officers, employees and agents, and each person, if any, who controls such persons within the meaning of Section 15 of the 1933 Act (each a “Distributor-Indemnified Party”) from and against any Losses incurred by such Distributor-Indemnified Party as a result of (i) any breach by the Distributor of any provision of this Agreement; (ii) any failure on the part of the Distributor to perform any of its obligations set forth in this Agreement; (iii) any failure by the Distributor to comply with applicable Law; (iv) any untrue statement or alleged untrue statement of a material fact contained in the Prospectus or any alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading, other than any statement made or omitted in reliance upon information provided to the Distributor, the Trust or any other person on behalf of the Trust or the Fund by a Distributor-Indemnified Party in writing and (v) actions of such Distributor-Indemnified Party in reliance upon any instructions reasonably believed by the Participant to be genuine and to have been given by the Distributor. The foregoing shall not apply to any Losses incurred by any Distributor-Indemnified Party arising out of any Distributor-Indemnified Party’s own fraud, bad faith, willful misconduct, gross negligence or reckless disregard of its duties hereunder. c. Notwithstanding anything to the contrary in this Agreement, the Distributor, the Transfer Agent and the Fund will not indemnify the Participant for any violations of the U.S. federal or state securities laws (or other applicable Law) committed by the Participant through its failure to deliver a Prospectus in connection with the offer or sale of Shares and for any oral or written representation or warranty by Participant that is not contained in the Prospectus. d. Notwithstanding anything to the contrary in this Agreement, none of the Participant, Distributor, Trust or Transfer Agent shall be liable to each other for any Losses under this Agreement arising out of (i) mistakes or errors in data provided in connection with Orders, except for data provided by the other or (ii) mistakes or errors by or out of interruptions or delays of communications with a service provider to the Trust. e. Each of the Participant, Distributor and Transfer Agent undertakes to perform such duties and only such duties as are expressly set forth herein, or expressly incorporated herein by reference, and no implied covenants or obligations shall be read into this Agreement. f. In the absence of fraud, bad faith, gross negligence, willful misconduct, or reckless disregard on its part, neither the Distributor nor the Transfer Agent, whether acting directly or through agents or attorneys, shall be liable for any action taken or omitted, or for any error of judgment made, in the performance of their duties hereunder. g. In no event shall any Party be liable for special, indirect or consequential loss or damage of any kind whatsoever (including but not limited to lost profits), even if advised of the likelihood of such loss or damage and regardless of the form of action. In no event shall any Party be liable under this Agreement to another Party for the acts or omissions of the CNS Clearing Process, DTC, NSCC, the Custodian or any securities depository, clearing corporation, exchange or communications service. h. None of the Distributor, the Transfer Agent or the Trust shall be liable for any failure or delay in the performance of its obligations or those of its agents under this Agreement arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including without limitation: acts of God; earthquakes; extreme weather events, including blizzards, hurricanes, tornados thunder storms, fires and floods; wars; civil or military disturbances; blackouts; terrorism; breakdowns in communications systems; riots; loss or malfunction of utilities or computer or internet services; labor disputes; acts of any civil, military or governmental authority. i. Neither the Transfer Agent nor the Distributor shall be required to advance, expend or risk its own funds or otherwise incur or become exposed to financial liability in the performance of its duties hereunder.

• Indemnification and Limitation of Liability (a) In the absence of willful misfeasance, bad faith, gross negligence or reckless disregard of obligations or duties hereunder on the part of FSSC and its trustees, officers, employees, agents and representatives, the Funds agree to indemnify FSSC and its trustees, officers, employees, agents and representatives against any and all claims, demands, liabilities and reasonable expenses (including attorneys’ fees), related to or otherwise connected with (i) any breach by the Funds of any provision of this Agreement; or (ii) any action by a Fund’s Shareholder against FSSC. (b) FSSC shall not be liable for any error of judgment or mistake of law or for any loss suffered by any Fund in connection with the matters to which this Agreement relates, except a loss resulting from willful misfeasance, bad faith or gross negligence on its part in the performance of its duties or from reckless disregard by it of its obligations and duties under this Agreement. In no event shall FSSC be liable for indirect or consequential damages. (c) Any person, even though also an officer, trustee, partner, employee or agent of FSSC, who may be or become an officer, employee or agent of any Fund or a member of a Fund's Board, shall be deemed, when rendering services to such Fund or acting on any business of such Fund (other than services or business in connection with the duties of FSSC hereunder) to be rendering such services to or acting solely for such Fund and not as an officer, trustee, partner, employee or agent or one under the control or direction of FSSC even though paid by FSSC. (d) FSSC is expressly put on notice of the limitation of liability as set forth in the Declaration of Trust of each Fund that is a Massachusetts business trust and agrees that the obligations assumed by each such Fund pursuant to this Agreement shall be limited in any case to such Fund and its assets and that FSSC shall not seek satisfaction of any such obligations from the Shareholders of such Fund, the Trustees, Officers, Employees or Agents of such Fund, or any of them. (e) The provisions of this Section shall survive the termination of this Agreement.

• Limitation of Liability and Indemnification State Street shall be held to a standard of reasonable care in carrying out its duties under this Agreement. State Street shall be responsible for the performance of only such duties as are set forth in this Agreement and, except as otherwise provided under Section XVI, shall have no responsibility for the actions or activities of any other party, including other service providers. State Street shall have no liability for any error of judgment or mistake of law or for any loss or damage resulting from the performance or nonperformance of its duties hereunder unless caused by or resulting from the negligence, reckless misconduct, willful malfeasance or lack of good faith of State Street, its officers or employees and, in such event, such liability will be subject to the limitations set forth in Section XIII herein. STATE STREET SHALL NOT BE LIABLE FOR ANY SPECIAL, INDIRECT, INCIDENTAL, OR CONSEQUENTIAL DAMAGES OF ANY KIND WHATSOEVER (INCLUDING, WITHOUT LIMITATION, ATTORNEYS’ FEES) IN ANY WAY DUE TO THE TRUST’S USE OF THE SERVICES DESCRIBED HEREIN OR THE PERFORMANCE OF OR FAILURE TO PERFORM STATE STREET’S OBLIGATIONS UNDER THIS AGREEMENT. This disclaimer applies without limitation to claims regardless of the form of action, whether in contract (including negligence), strict liability, or otherwise and regardless of whether such damages are foreseeable. The Trust, or, if applicable, the relevant Portfolio, will indemnify and hold harmless State Street and its stockholders, directors, officers, employees, agents, and representatives (collectively, the “Trust Indemnified Persons”) for, and will pay to the Trust Indemnified Persons the amount of, any actual and direct damages, whether or not involving a third-party claim (collectively, the “Damages”), arising from or in connection with (i) any act or omission by State Street (or any of its affiliates) pursuant to this Agreement which does not constitute negligence, reckless misconduct, willful malfeasance or lack of good faith in fulfilling the terms and obligations of this Agreement, (ii) any act or omission by the Trust (or any of its affiliates) which constitutes a breach of any representation, warranty, term, or obligation contained in this Agreement, or (iii) any act or omission by the Trust (or any of its affiliates) which constitutes negligence, reckless misconduct, willful malfeasance, or lack of good faith in fulfilling the terms and obligations of this Agreement. The remedies provided in this paragraph are not exclusive of or limit any other remedies that may be available to State Street or any other Trust Indemnified Person. State Street will indemnify and hold harmless the Trust, and its respective shareholders, trustees, directors, officers, agents, and representatives (collectively, the “State Street Indemnified Persons”) for, and will pay to the State Street Indemnified Persons the amount of, any Damages, arising from or in connection with (i) any act or omission by State Street (or any of its affiliates) which constitutes a breach of any representation, warranty, term, or obligation contained in this Agreement or (ii) any act or omission by State Street (or any of its affiliates) which constitutes negligence, reckless misconduct, willful malfeasance, or lack of good faith in fulfilling the terms and obligations of this Agreement; provided, however, that State Street shall not be required to provide indemnification for damages arising from errors caused by inaccurate prices received from independent pricing services and reasonably relied upon by State Street. In the event that State Street is required to provide indemnification under this Section XII, its liability shall be limited as described under Section XIII below. The remedies provided in this paragraph are not exclusive of or limit any other remedies that may be available to the Trust or any other State Street Indemnified Person. The indemnification and limitation of liability contained herein shall survive the termination of this Agreement.

• Exclusion and Limitation of Liability 10.1 SUPPLIER DOES NOT EXCLUDE OR LIMIT ITS LIABILITY (IF ANY) TO BUYER FOR ANY MATTER FOR WHICH IT WOULD BE ILLEGAL FOR SUPPLIER TO EXCLUDE OR LIMIT OR TO ATTEMPT TO EXCLUDE OR LIMIT ITS LIABILITY. 10.2 OTHER THAN ANY LIABILITY OF SUPPLIER ARISING UNDER CLAUSE 10.1, WHICH SHALL NOT BE LIMITED, AND WITHOUT PREJUDICE TO THE OTHER PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY), SUPPLIER'S AGGREGATE LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) UNDER EACH CONTRACT WILL BE LIMITED TO AN AMOUNT EQUAL TO THE GREATER OF 115% OF THE AMOUNT PAID BY BUYER TO SUPPLIER UNDER THAT CONTRACT OR $10,000.00. 10.3 EXCEPT AS PROVIDED IN CLAUSE 10.1, SUPPLIER WILL BE UNDER NO LIABILITY AS DEFINED IN PART D (DEFINITIONS AND INTERPRETATION) TO BUYER WHATSOEVER IN RESPECT OF 10.3.1 ANY CLAIM ARISING OUT OF AN EVENTWHICH IS CAUSED, OR CONTRIBUTED TO, BY THE GOODS AND SUCH EVENT OCCURS AFTER THE COMMENCEMENT OF THE LAUNCH PROCEDURE OF THE VEHICLE CARRYING SUCH GOODS INTO SPACE; 10.3.2 PURE ECONOMIC LOSS, LOSS OF PROFITS, LOSS OF BUSINESS, LOSS OF REVENUE, LOSS OF CONTRACTS, LOSS OF GOODWILL, LOSS OF ANTICIPATED EARNINGS OR SAVINGS (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR 10.3.3 LOSS OF USE OR VALUE OR DAMAGE OF ANY DATA OR EQUIPMENT (INCLUDING SOFTWARE), WASTED MANAGEMENT, OPERATION OR OTHER TIME (WHETHER DIRECT, INDIRECT, INCIDENTAL OR CONSEQUENTIAL) OR 10.3.4 ANY SPECIAL, INDIRECT, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL LOSS, IN EACH CASE HOWSOEVER CAUSED ARISING OUT OF OR IN CONNECTION WITH: 10.3.5 ANY OF THE WORKS, OR THE MANUFACTURE OR SALE OR SUPPLY, OR FAILURE OR DELAY IN SUPPLY, OF THE WORKS BY SUPPLIER OR ON THE PART OF SUPPLIER’S EMPLOYEES, AGENTS OR SUBCONTRACTORS; 10.3.6 ANY BREACH BY SUPPLIER OF ANY OF THE EXPRESS OR IMPLIED TERMS OF THE CONTRACT; 10.3.7 ANY USE MADE OR RESALE BY BUYER OF ANY OF THE WORKS, OR OF ANY PRODUCT INCORPORATING ANY OF THE WORKS; OR 10.3.8 ANY STATEMENT MADE OR NOT MADE, OR ADVICE GIVEN OR NOT GIVEN, BY OR ON BEHALF OF SUPPLIER. 10.4 EXCEPT AS EXPRESSLY SET OUT IN THE CONTRACT, SUPPLIER HEREBY EXCLUDES TO THE FULLEST EXTENT PERMISSIBLE IN LAW, ALL CONDITIONS, WARRANTIES AND STIPULATIONS, EXPRESS (OTHER THAN THOSE SET OUT IN THE CONTRACT) OR IMPLIED, STATUTORY, CUSTOMARY OR OTHERWISE WHICH, BUT FOR SUCH EXCLUSION, WOULD OR MIGHT SUBSIST IN FAVOR OF BUYER, INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. 10.5 EACH OF SUPPLIER’S EMPLOYEES, AGENTS AND SUBCONTRACTORS MAY RELY UPON AND ENFORCE THE EXCLUSIONS AND RESTRICTIONS OF LIABILITY IN THE CONTRACT IN THAT PERSON’S OWN NAME AND FOR THAT PERSON’S OWN BENEFIT, AS IF THE WORDS “ITS EMPLOYEES, AGENTS AND SUBCONTRACTORS” FOLLOWED THE WORD SUPPLIER WHEREVER IT APPEARS IN THOSE CLAUSES SAVE FOR EACH REFERENCE IN CLAUSE10.3.5. 10.6 BUYER ACKNOWLEDGES THAT THE ABOVE PROVISIONS OF THIS CLAUSE 10 (EXCLUSION AND LIMITATION OF LIABILITY) ARE REASONABLE AND REFLECTED IN THE PRICE WHICH WOULD BE HIGHER WITHOUT THOSE PROVISIONS, AND BUYER WILL ACCEPT SUCH RISK AND/OR INSURE ACCORDINGLY. 10.7 BUYER IS SOLELY RESPONSIBLE AND LIABLE FOR THE PROPER LEGAL DISPOSAL OF ALL MATERIALS PURCHASED FROM SUPPLIER AT THE END-OF- LIFE CYCLE OF SUCH MATERIALS.

• Additional Indemnification; Limitation of Liability A. Subject to Section 2(A), USBFS CANNOT AND DOES NOT GUARANTEE AVAILABILITY OF THE ELECTRONIC SERVICES. Accordingly, USBFS’s sole liability to the Trust or any third party (including End Users) for any claims, notwithstanding the form of such claims (e.g., contract, negligence, or otherwise), arising out of the delay of or interruption in the Electronic Services to be provided by USBFS hereunder shall be to use its best reasonable efforts to commence or resume the Electronic Services as promptly as is reasonably possible. B. USBFS shall, at its sole cost and expense, defend, indemnify, and hold harmless the Trust and its trustees, officers and employees from and against any and all claims, demands, losses, expenses and liabilities of any and every nature (including reasonable attorneys’ fees) arising out of or relating to (a) any infringement, or claim of infringement, of any United States patent, trademark, copyright, trade secret, or other proprietary rights based on the use or potential use of the Electronic Services and (b) the provision of the Trust Files (as defined below) or Confidential Information (as defined below) to a person other than a person to whom such information may be properly disclosed hereunder. C. If an injunction is issued against the Trust’s use of the Electronic Services by reason of infringement of a patent, copyright, trademark, or other proprietary rights of a third party, USBFS shall, at its own option and expense, either (i) procure for the Trust the right to continue to use the Electronic Services on substantially the same terms and conditions as specified hereunder, or (ii) after notification to the Trust, replace or modify the Electronic Services so that they become non-infringing, provided that, in the Trust’s judgment, such replacement or modification does not materially and adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust. If in the Trust’s judgment, such replacement or modification does materially adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust, the Trust may terminate all rights and responsibilities under this Exhibit C immediately on written notice to USBFS. D. Because the ability of USBFS to deliver Electronic Services is dependent upon the Internet and equipment, software, systems, data and services provided by various telecommunications carriers, equipment manufacturers, firewall providers and encryption system developers and other vendors and third parties, USBFS shall not be liable for delays or failures to perform its obligations hereunder to the extent that such delays or failures are attributable to circumstances beyond its reasonable control which interfere with the delivery of the Electronic Services by means of the Internet or any of the equipment, software and services which support the Internet provided by such third parties. USBFS shall also not be liable for the actions or omissions of any third party wrongdoers (i.e., hackers not employed by USBFS or its affiliates) or of any third parties involved in the Electronic Services and shall not be liable for the selection of any such third party, unless USBFS selected the third party in bad faith or in a grossly negligent manner. E. USBFS shall not be responsible for the accuracy of input material from End Users nor the resultant output derived from inaccurate input. The accuracy of input and output shall be judged as received at USBFS’s data center as determined by the records maintained by USBFS. F. Notwithstanding anything to the contrary contained herein, USBFS shall not be obligated to ensure or verify the accuracy or actual receipt, or the transmission, of any data or information contained in any transaction via the Electronic Services or the consummation of any inquiry or transaction request not actually reviewed by USBFS.

• Limitation of Liability of Sub-Adviser and Indemnification Sub-Adviser shall not be liable for any costs or liabilities arising from any error of judgment or mistake of law or any loss suffered by the Fund or the Trust in connection with the matters to which this Contract relates except a loss resulting from willful misfeasance, bad faith or gross negligence on the part of Sub-Adviser in the performance by Sub-Adviser of its duties or from reckless disregard by Sub-Adviser of its obligations and duties under this Contract. Any person, even though also an officer, partner, employee, or agent of Sub-Adviser, who may be or become a Trustee, officer, employee or agent of the Trust, shall be deemed, when rendering services to a Fund or the Trust or acting with respect to any business of a Fund or the Trust to be rendering such service to or acting solely for the Fund or the Trust and not as an officer, partner, employee, or agent or one under the control or direction of Sub-Adviser even though paid by it.

• Limitation of Liability No provision hereof, in the absence of any affirmative action by the Holder to exercise this Warrant to purchase Warrant Shares, and no enumeration herein of the rights or privileges of the Holder, shall give rise to any liability of the Holder for the purchase price of any Common Stock or as a stockholder of the Company, whether such liability is asserted by the Company or by creditors of the Company.

• Limitation of Liability; Indemnification (a) Funds Management shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust in connection with the performance of its obligations and duties under this Agreement, except a loss resulting from Funds Management’s willful misfeasance, bad faith, or negligence in the performance of its obligations and duties or that of its agents or sub-administrators, or by reason of its or their reckless disregard thereof. Any person, even though also an officer, director, employee or agent of Funds Management, shall be deemed, when rendering services to the Trust or acting on any business of the Trust (other than services or business in connection with Funds Management’s duties as Administrator hereunder), to be acting solely for the Trust and not as an officer, director, employee, or agent or one under the control or discretion of Funds Management even though paid by it. (b) The Trust, on behalf of each Fund, will indemnify Funds Management against and hold it harmless from any and all losses, claims, damages, liabilities, or expenses (including reasonable counsel fees and expenses) resulting from any claim, demand, action, or suit relating to the particular Fund and not resulting from willful misfeasance, bad faith, or negligence of Funds Management or its agents or sub-administrators in the performance of their obligations and duties hereunder, or by reason of its or their reckless disregard thereof. Funds Management will not confess any claim or settle or make any compromise in any instance in which the Trust will be asked to provide indemnification, except with the Trust’s prior written consent. Any amounts payable by the Trust under this Subparagraph shall be satisfied only against the assets of the Fund involved in the claim, demand, action, or suit and not against the assets of any other Fund. (c) Funds Management will indemnify the Trust against and hold it harmless from any and all losses, claims, damages, liabilities, or expenses (including reasonable counsel fees and expenses) resulting from any claim, demand, action, or suit against the Trust or any Fund that resulted from a failure of Funds Management or its agents to act in accordance with the standard of care set forth in Subparagraph (a) above; provided that such loss, claim, damage, liability or expense did not result primarily from willful misfeasance, bad faith, or negligence of the Trust or its agents (other than Funds Management or agents of Funds Management) in the performance of their obligations and duties, or by reason of its or their reckless disregard thereof. The Trust will not confess any claim or settle or make any compromise in any instance in which Funds Management will be asked to provide indemnification, except with Funds Management’s prior written consent.

• Disclaimer and Limitation of Liability PROVIDER DISCLAIMS ALL WARRANTIES, EXPRESS,IMPLIED, STATUTORY OR ARISING FROM A COURSE OF DEALING OR PERFORMANCE OR CUSTOM, WITH RESPECT TO THE SERVICES, EQUIPMENT, AND ANY OTHER PROVIDER PRODUCTS, SERVICES OR EQUIPMENT PROVIDED HEREUNDER, INCLUDING, BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, PERFORMANCE IN A XXXXXXX-LIKE MANNER, COMPLIANCE WITH LAWS, QUALITY, ACCURACY, COMPLETENESS OR CURRENCY OF INFORMATION, SYSTEM INTEGRABILITY, TITLE, QUIET ENJOYMENT AND NON-INFRINGEMENT. PROVIDERDOES NOT REPRESENT, WARRANT OR COVENANT THAT THE PRODUCTS, SERVICES OR EQUIPMENT PROVIDED WILL OPERATE UNINTERRUPTED, ERROR FREE OR WITHOUT DEGRADATION OR LOSS OF DATA, OR BE SECURE. NEITHER PROVIDER NOR ITS SERVICE PROVIDERS WILL BE LIABLE FOR UNAUTHORIZED ACCESS TO OR ALTERATION, THEFT OR DESTRUCTION OF CUSTOMER’S OR A USER’S DATA FILES, PROGRAMS, PROCEDURES OR INFORMATION, INCLUDING, WITHOUT LIMITATION, ANY SUCH DATA IN PROVIDER’S POSSESSION, CUSTODY OR CONTROL, THROUGH ACCIDENT, FRAUDULENT MEANS OR DEVICES, OR ANY OTHER METHOD, REGARDLESS OF WHETHER SUCH DAMAGE OCCURS AS A RESULT OF PROVIDER’S OR ITS SERVICE PROVIDER’S NEGLIGENCE. IN NO EVENT WILL PROVIDER OR ITS AFFILIATE, SERVICE PROVIDER, FACILITY OPERATOR OR CARRIER, OR THEIR RESPECTIVE OWNERS, DIRECTORS, MANAGERS, OFFICERS, EMPLOYEES OR AGENTS (COLLECTIVELY, “PROVIDER PARTIES”) BE LIABLE FOR ANY DIRECT, ACTUAL, INDIRECT, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER DAMAGES, OR FOR ANY COST OF COVER OR LOST PROFITS OF ANY KIND OR NATURE WHATSOEVER, ARISING FROM OR RELATED TO THIS AGREEMENT OR A PROVIDER PARTY’S PERFORMANCE OR NONPERFORMANCE OF OBLIGATIONS HEREUNDER, A FAILURE OF OR A DEFECT IN THE SERVICES, EQUIPMENT OR ANY PRODUCT, A PROVIDER PARTY’S VIOLATION OF A THIRD PARTY’S RIGHT, OR A PROVIDER PARTY’S ACTS OR OMISSIONS. PROVIDER WILL NOT BE LIABLE FOR THE ACTS OR OMISSIONS OF, A FAILURE OF OR A DEFECT IN ANY PRODUCT OR SERVICE PROVIDED BY, OR VIOLATION OF ANY THIRD PARTY’S RIGHTS BY ANY THIRD-PARTY SERVICE PROVIDER, FACILITY OPERATOR OR CARRIER. THE PROVIDER PARTIES’ MAXIMUM TOTAL LIABILITY TO CUSTOMER WILL NOT EXCEED THE AMOUNTS PAID BY CUSTOMER TO PROVIDER IN THE THREE (3) MONTHS PRECEDING THE DATE THE CLAIM ACCRUED. THE PROVIDER PARTIES WILL NOT BE LIABLE IN ANY WAY TO ANY USER.