Indemnification by Subcontractors To the fullest extent permitted by law, an Interconnection Party that uses a subcontractor to carry out any of the Interconnection Party’s obligations under this Appendix 2 shall require each of its subcontractors to indemnify, hold harmless and defend each other Interconnection Party, its representatives and assigns from and against any and all claims and/or liability for damage to property, injury to or death of any person, including the employees of any Interconnection Party or of any Affiliate of any Interconnection Party, or any other liability incurred by the other Interconnection Party or any of its Affiliates, including all expenses, legal or otherwise, to the extent caused by any act or omission, negligent or otherwise, by such subcontractor and/or its officers, directors, employees, agents and assigns, that arises out of or is connected with the operation of the facilities of either Interconnected Entity described in this Appendix 2; provided, however, that no Interconnection Party or Affiliate thereof shall be entitled to indemnity under this Section 18.3 in respect of any injury, loss, or damage to the extent that such loss, injury, or damage results from the negligence or willful misconduct of the Interconnection Party or Affiliate seeking indemnity.
Indemnification by Contractor To the fullest extent permitted by law, the CONTRACTOR agrees to indemnify, defend and hold the COUNTY and its departments, elected and appointed officials, employees, agents and volunteers, harmless from and against any and all claims, damages, losses and expenses, including but not limited to court costs, attorney’s fees and alternative dispute resolution costs, for any personal injury, for any bodily injury, sickness, disease or death and for any damage to or destruction of any property (including the loss of use resulting therefrom) which 1) are caused in whole or in part by any action or omission, negligent or otherwise, of the CONTRACTOR, its employees, agents or volunteers or CONTRACTOR’s subcontractors and their employees, agents or volunteers; or 2) are directly or indirectly arising out of, resulting from, or in connection with performance of this Contract; or 3) are based upon the CONTRACTOR’S or its subcontractors’ use of, presence upon or proximity to the property of the COUNTY. This indemnification obligation of the CONTRACTOR shall not apply in the limited circumstance where the claim, damage, loss or expense is caused by the sole negligence of the COUNTY. This indemnification obligation of the CONTRACTOR shall not be limited in any way by the Washington State Industrial Insurance Action RCW Title 51, or by application of any other workmen’s compensation act, disability benefit act or other employee benefit act, and the CONTRACTOR hereby expressly waives any immunity afforded by such acts. The foregoing indemnification obligations of the CONTRACTOR are a material inducement to COUNTY to enter into the Contract, are reflected in the CONTRACTOR’s compensation, and have been mutually negotiated by the parties.
Indemnification by Provider If an action is brought against SAP by a third party arising from (a) any taxes and related costs, interest and penalties paid or payable by SAP, (b) Provider’s representations not authorized by SAP, (c) Provider’s breach of this Agreement, including but not limited to: (i) any breach or violation of applicable export laws or regulations; or (ii) action in excess of Provider’s authority hereunder and arising out of any claims by any Customers or End Users; or (d) Provider’s failure to comply with the terms of the Customer Service Agreement, (e) any agreement between Provider and its distributors, resellers or Customers, (f) a claim that any Provider Confidential Information infringes, misappropriates or violates any patent, copyright or trademark of any third party or Provider's combining (or its authorizing others to combine) the Software with any products not provided by SAP, or (g) a third party’s assertion that Provider acted as SAP's agent or otherwise on its behalf, then Provider shall defend SAP, at Provider's expense, and shall pay any settlement amounts Provider authorizes and all damages, costs and attorneys’ fees finally awarded against SAP in the action. Provider shall indemnify and hold harmless SAP from any damages and costs SAP incurs as a consequence of any infringement of intellectual property rights of third parties caused by any of the circumstances set forth in this Section or the use of the Software not in accordance with this Agreement.
WAIVER OF LIABILITY, ASSUMPTION OF RISK, AND INDEMNITY AGREEMENT I, , IN CONSIDERATION of being permitted to participate in any way in the Rocky Mountain Cycling Club 600km brevet calendared for June 4, 2021 (“Activity”), I hereby acknowledge, agree, attest and represent the following:
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:
Indemnification by Lessee Lessee agrees to indemnify, defend, protect, save and keep harmless Lessor and its Affiliates, and their respective officers, directors, shareholders, unitholders, members, partners, managers, agents, employees, representatives, successors and assigns (collectively, the “Lessor Indemnified Parties”) from and against any and all Claims which may be imposed on, incurred by or asserted against the Lessor Indemnified Parties, in any way and to the extent relating to or arising out of (a) any failure to perform any covenant or agreement made or undertaken by Lessee in this Lease, or (b) the exercise of Lessee’s Parties’ rights under Section 2.2(a); provided, however, Lessee shall not have any obligation to indemnify the Lessor Indemnified Parties for any such Claim under clauses (a) or (b) to the extent resulting from or arising out of the willful misconduct or negligence of any of the Lessor Indemnified Parties. To the extent that the Lessor Indemnified Parties in fact receive full indemnification payments from Lessee under the indemnification provisions of this Section 10.2, Lessee shall be subrogated to the Lessor Indemnified Parties’ rights with respect to the transaction or event requiring or giving rise to such indemnity. NOTWITHSTANDING ANYTHING CONTAINED IN THIS LEASE TO THE CONTRARY, IN NO EVENT SHALL LESSEE BE LIABLE FOR INCIDENTAL, INDIRECT, SPECIAL, PUNITIVE, EXEMPLARY OR CONSEQUENTIAL DAMAGES, LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES IN TORT, CONTRACT OR OTHERWISE UNDER OR ON ACCOUNT OF THIS LEASE, EXCEPT THOSE PAYABLE TO THIRD PARTIES FOR WHICH LESSEE WOULD BE LIABLE UNDER THIS SECTION.
Required Confidentiality Claim Form This is a requirement of the TIPS Contract and is non-negotiable. TIPS provides the required TIPS Confidentiality Claim Form in the "Attachments" section of this solicitation. Vendor must execute this form by either signing and waiving any confidentiality claim, or designating portions of Vendor's proposal confidential. If Vendor considers any portion of Vendor's proposal to be confidential and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s) and orders, Vendor must have identified the claimed confidential materials through proper execution of the Confidentiality Claim Form. If TIPS receives a public information act or similar request, any responsive documentation not deemed confidential by you in this manner will be automatically released. For Vendor documents deemed confidential by you in this manner, TIPS will follow procedures of controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law, including Attorney General determination and opinion. Notwithstanding any other Vendor designation of Vendor's proposal as confidential or proprietary, Vendor’s submission of this proposal constitutes Vendor’s agreement that proper execution of the required TIPS Confidentiality Claim Form is the only way to assert any portion of Vendor's proposal as confidential.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
RELEASE OF LIABILITY, WAIVER OF CLAIMS AND INDEMNITY AGREEMENT In consideration of the Releasees allowing me to participate in wilderness activities I hereby agree as follows:
