Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
Litigation Matters If the FDIC Party and the Assuming Institution do not agree to submit the Dispute Item to arbitration, the Dispute Item may be resolved by litigation in accordance with Federal or state law, as provided in Section 13.10 of the Purchase and Assumption Agreement. Any litigation shall be filed in a United States District Court in the proper district.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Notice of Litigation, Right to Prosecute, Etc No Fund shall be liable for indemnification under this Section 5.03 unless a Person shall have promptly notified such Fund in writing of the commencement of any litigation or proceeding brought against such Person in respect of which indemnity may be sought under this Section 5.03. With respect to claims in such litigation or proceedings for which indemnity by a Fund may be sought and subject to applicable law and the ruling of any court of competent jurisdiction, such Fund shall be entitled to participate in any such litigation or proceeding and, after written notice from such Fund to any Person, such Fund may assume the defense of such litigation or proceeding with counsel of its choice at its own expense in respect of that portion of the litigation for which such Fund may be subject to an indemnification obligation; provided however, a Person shall be entitled to participate in (but not control) at its own cost and expense, the defense of any such litigation or proceeding if such Fund has not acknowledged in writing its obligation to indemnify the Person with respect to such litigation or proceeding. If such Fund is not permitted to participate or control such litigation or proceeding under applicable law or by a ruling of a court of competent jurisdiction, such Person shall reasonably prosecute such litigation or proceeding. A Person shall not consent to the entry of any judgment or enter into any settlement in any such litigation or proceeding without providing each applicable Fund with adequate notice of any such settlement or judgment, and without each such Fund's prior written consent. All Persons shall submit written evidence to each applicable Fund with respect to any cost or expense for which they are seeking indemnification in such form and detail as such Fund may reasonably request.
Class, Collective and Representative Action Waiver THE PARTIES AGREE THAT COVERED CLAIMS WILL, AT EITHER PARTY’S ELECTION, ONLY BE ARBITRATED ON AN INDIVIDUAL BASIS AND THAT EACH WAIVES THE RIGHT TO PARTICIPATE IN OR RECEIVE COMPENSATION FROM ANY CLASS, COLLECTIVE OR REPRESENTATIVE PROCEEDING. NO PARTY MAY BRING A CLAIM ON BEHALF OF OTHER INDIVIDUALS; ANY ARBITRATOR HEARING A COVERED CLAIM MAY NOT COMBINE MORE THAN ONE INDIVIDUAL’S CLAIM OR CLAIMS INTO A SINGLE CASE OR TO ARBITRATE ANY FORM OF A CLASS, COLLECTIVE OR REPRESENTATIVE PROCEEDING. SHOULD ANY PORTION OF THE FOREGOING WAIVER BE FOUND INVALID, THE REMAINING PORTION THAT IS VALID WILL BE ENFORCED TO THE FULLEST EXTENT ALLOWED BY APPLICABLE LAW.
Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).
Initial Claim Generally, the determination of whether a Claim is an Urgent Care Claim will be made by an individual acting on behalf of XxXxx, applying the judgment of a prudent layperson possessing an average knowledge of health and medicine. However, if a Physician with knowledge of the Member’s Condition determines that the Claim is an Urgent Care Claim, it will be deemed urgent. Urgent Care Claims may be made orally or in writing. AvMed will notify the Claimant of the benefit determination as soon as possible, taking into account the medical exigencies, but no later than 72 hours after receipt of the Urgent Care Claim.
1) If the Claimant fails to provide sufficient information to determine whether or to what extent benefits are covered or payable under this Contract, AvMed will notify the Claimant, no later than 24 hours after receipt of the Claim, of the specific information necessary to complete the Claim. The Claimant will be afforded no less than 48 hours, to provide the specified information.
2) AvMed will notify the Claimant of the benefit determination no later than 48 hours after the earlier of: XxXxx’s receipt of the specified information, or the end of the period afforded the Claimant to provide the specified information. If the Claimant fails to supply the specified information within the 48-hour period, the Claim will be denied.
3) AvMed may notify the Claimant of the benefit determination orally or in writing. If the notification is provided orally, a written or electronic notification will also be provided to the Claimant no later than three days after the oral notification.
Tax Claims Notwithstanding any other provision of this Agreement, the control of any claim, assertion, event or proceeding in respect of Taxes of the Company (including, but not limited to, any such claim in respect of a breach of the representations and warranties in Section 3.22 hereof or any breach or violation of or failure to fully perform any covenant, agreement, undertaking or obligation in Article VI) shall be governed exclusively by Article VI hereof.
Litigation; Claims Any rights (including indemnification) and claims and recoveries under litigation of Seller against third parties arising out of or relating to events prior to the Closing Date;
Selection of Representatives a) Each central party and the Crown shall select its own representatives to the Committee.
