Initial Programming Information Clause Samples
The Initial Programming Information clause defines the baseline set of data, specifications, or parameters that will guide the commencement of a project or service. Typically, this clause outlines what information must be provided at the outset, such as technical requirements, timelines, or deliverables, and may specify which party is responsible for supplying these details. By clearly establishing the foundational information needed to begin work, this clause helps prevent misunderstandings and delays, ensuring that all parties have a shared understanding of the project's starting point.
Initial Programming Information. Tenant shall deliver to Landlord, in writing, all information necessary in the judgment of Landlord, the Architect and the Engineers for the preparation ofa conceptual space plan for the Premises (for purposes of this Exhibit A, a “Space Plan”), including layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein, the number and sizes of workstations, number and size of kitchen, copy, reception and storage areas (for purposes of this Exhibit A, collectively, the “Initial Programming Information”). The Initial Programming Information shall be consistent with Landlord’s requirements for avoiding aesthetic, engineering or other conflicts with the design and function of the balance of the Building (for purposes of this Exhibit A, collectively, the “Landlord Requirements”) and shall otherwise be subject to Landlord’s reasonable approval. Landlord shall provide Tenant with notice approving or reasonably disapproving the Initial Programming Information within five (5) business days after the later of Landlord’s receipt thereof or the mutual execution and delivery of this Agreement. If Landlord disapproves the Initial Programming Information, Landlord’s notice of disapproval shall describe with reasonable specificity the basis for such disapproval and the changes that would be necessary to resolve Landlord’s objections. If Landlord disapproves the Initial Programming Information, Tenant shall modify the Initial Programming Information and resubmit it for Landlord’s review and approval. Such procedure shall be repeated as necessary until Landlord has approved the Initial Programming Information.
Initial Programming Information. Within five (5) business days following the full execution and delivery of this Lease, Tenant shall furnish to Landlord all information necessary in the judgment of Landlord, the Architect and the Engineers for the preparation of Space Plan layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein, the number and sizes of workstations, number and size of kitchen, laboratory, warehouse, reception and Initial Programming Information disapproving the Initial Programming Information within five (5) business days objections. If Landlord disapproves the Initial Programming Information, Tenant shall modify the Initial necessary until Landlord has approved the Initial Programming Information.