Initiation of the Project; Insurance and Payment Bonds Required. Subject to any applicable Land Use Approvals and the terms of the Lease, the Company shall implement, construct, and operate the Project as provided in this Section 4.3.
Initiation of the Project; Insurance and Payment Bonds Required Sample Clauses
Related to Initiation of the Project; Insurance and Payment Bonds Required
Construction Bonds, Insurance and Supervision (i) The Recipient shall require that each of its Contractors furnish a performance and payment bond in an amount at least equal to 100 percent (100%) of its contract price as security for the faithful performance of its contract. (ii) The Recipient shall require that each of its construction contractors and each subcontractor maintain during the life of its contract or subcontract appropriate Workers Compensation Insurance, Public Liability, Property Damage and Vehicle Liability Insurance. (iii) The Recipient shall provide and maintain competent and adequate project management covering the supervision and inspection of the development and construction of the Project and bearing the responsibility of ensuring that construction conforms with the approved surveys, plans, profiles, cross sections and specifications and certifying to the OPWC and the Recipient at the completion of construction that construction is in accordance with the approved surveys, plans, profiles, cross sections and specifications or approved amendments thereto.
Liability Insurance and Funding For the duration of Indemnitee’s service as a director and/or officer of the Company and for a reasonable period of time thereafter, which such period shall be determined by the Company in its sole discretion, the Company shall use commercially reasonable efforts (taking into account the scope and amount of coverage available relative to the cost thereof) to cause to be maintained in effect policies of directors’ and officers’ liability insurance providing coverage for directors and/or officers of the Company, and, if applicable, that is substantially comparable in scope and amount to that provided by the Company’s current policies of directors’ and officers’ liability insurance. Upon reasonable request, the Company shall provide Indemnitee or his or her counsel with a copy of all directors’ and officers’ liability insurance applications, binders, policies, declarations, endorsements and other related materials. In all policies of directors’ and officers’ liability insurance obtained by the Company, Indemnitee shall be named as an insured in such a manner as to provide Indemnitee the same rights and benefits, subject to the same limitations, as are accorded to the Company’s directors and officers most favorably insured by such policy. Notwithstanding the foregoing, (i) the Company may, but shall not be required to, create a trust fund, grant a security interest or use other means, including, without limitation, a letter of credit, to ensure the payment of such amounts as may be necessary to satisfy its obligations to indemnify and advance expenses pursuant to this Agreement and (ii) in renewing or seeking to renew any insurance hereunder, the Company will not be required to expend more than 2.0 times the premium amount of the immediately preceding policy period (equitably adjusted if necessary to reflect differences in policy periods).
Maintenance of the Primary Insurance Policies (a) The Master Servicer shall not take, or permit any Servicer (to the extent such action is prohibited under the applicable Servicing Agreement) to take, any action that would result in noncoverage under any applicable Primary Insurance Policy of any loss which, but for the actions of such Master Servicer or Servicer, would have been covered thereunder. The Master Servicer shall use its best reasonable efforts to cause each Servicer (to the extent required under the related Servicing Agreement) to keep in force and effect (to the extent that the Mortgage Loan requires the Mortgagor to maintain such insurance), primary mortgage insurance applicable to each Mortgage Loan in accordance with the provisions of this Agreement and the related Servicing Agreement, as applicable. The Master Servicer shall not, and shall not permit any Servicer (to the extent required under the related Servicing Agreement) to, cancel or refuse to renew any such Primary Insurance Policy that is in effect at the date of the initial issuance of the Mortgage Note and is required to be kept in force hereunder except in accordance with the provisions of this Agreement and the related Servicing Agreement, as applicable. (b) The Master Servicer agrees to present, or to cause each Servicer (to the extent required under the related Servicing Agreement) to present, on behalf of the Trustee and the Certificateholders, claims to the insurer under any Primary Insurance Policies and, in this regard, to take such reasonable action as shall be necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Pursuant to Sections 3.07 and 3.08, any amounts collected by the Master Servicer or any Servicer under any Primary Mortgage Insurance Policies shall be deposited in the Collection Account, subject to withdrawal pursuant to Sections 3.07 and 3.08.
Subcontractor Insurance In accord with Good Utility Practice, each Interconnected Entity shall require each of its subcontractors to maintain and provide evidence of insurance coverage of types, and in amounts, commensurate with the risks associated with the services provided by the subcontractor. Bonding of contractors or subcontractors shall be at the hiring Interconnected Entity’s discretion, but regardless of bonding, the hiring principal shall be responsible for the performance or non- performance of any contractor or subcontractor it hires.
Subcontractor Insurance Requirements Consultant shall require each of its subcontractors that perform services under this Agreement to maintain insurance coverage that meets all of the requirements of this Section 11.
PROFESSIONAL LIABILITY INSURANCE (ERRORS & OMISSIONS) Professional Liability Insurance for Errors and Omissions coverage in the amount of not less than ($1,000,000). If CONTRACTOR sub-contracts in support of CONTRACTOR’S work provided for in the agreement, Professional Liability Insurance for Errors shall be provided by the sub-contractor in an amount not less than one million dollars ($1,000,000) in aggregate. The insurance coverage provided by the CONTRACTOR shall contain language providing coverage up to one (1) year following completion of the contract in order to provide insurance coverage for the hold harmless provisions herein if the policy is a claims-made policy.
Maintenance of Fire Insurance and Omissions and Fidelity Coverage (a) The Master Servicer shall cause to be maintained for each Mortgage Loan (other than a Cooperative Loan) fire insurance with extended coverage in an amount which is equal to the lesser of the principal balance owing on such Mortgage Loan or 100 percent of the insurable value of the improvements; provided, however, that such coverage may not be less than the minimum amount required to fully compensate for any loss or damage on a replacement cost basis. To the extent it may do so without breaching the related Subservicing Agreement, the Master Servicer shall replace any Subservicer that does not cause such insurance, to the extent it is available, to be maintained. The Master Servicer shall also cause to be maintained on property acquired upon foreclosure, or deed in lieu of foreclosure, of any Mortgage Loan (other than a Cooperative Loan), fire insurance with extended coverage in an amount which is at least equal to the amount necessary to avoid the application of any co-insurance clause contained in the related hazard insurance policy. Pursuant to Section 3.07, any amounts collected by the Master Servicer under any such policies (other than amounts to be applied to the restoration or repair of the related Mortgaged Property or property thus acquired or amounts released to the Mortgagor in accordance with the Master Servicer's normal servicing procedures) shall be deposited in the Custodial Account, subject to withdrawal pursuant to Section 3.10. Any cost incurred by the Master Servicer in maintaining any such insurance shall not, for the purpose of calculating monthly distributions to the Certificateholders, be added to the amount owing under the Mortgage Loan, notwithstanding that the terms of the Mortgage Loan so permit. Such costs shall be recoverable by the Master Servicer out of related late payments by the Mortgagor or out of Insurance Proceeds and Liquidation Proceeds to the extent permitted by Section 3.
Insurance and Bonds Unless otherwise specified in this Contract, Grantee shall acquire and maintain, for the duration of this Contract, insurance coverage necessary to ensure proper fulfillment of this Contract and potential liabilities thereunder with financially sound and reputable insurers licensed by the Texas Department of Insurance, in the type and amount customarily carried within the industry as determined by the System Agency. Grantee shall provide evidence of insurance as required under this Contract, including a schedule of coverage or underwriter’s schedules establishing to the satisfaction of the System Agency the nature and extent of coverage granted by each such policy, upon request by the System Agency. In the event that any policy is determined by the System Agency to be deficient to comply with the terms of this Contract, Grantee shall secure such additional policies or coverage as the System Agency may reasonably request or that are required by law or regulation. If coverage expires during the term of this Contract, Grantee must produce renewal certificates for each type of coverage. In addition, if required by System Agency, Grantee must obtain and have on file a blanket fidelity bond that indemnifies System Agency against the loss or theft of any grant funds, including applicable matching funds. The fidelity bond must cover the entirety of the grant term and any subsequent renewals. The failure of Grantee to comply with these requirements may subject Grantee to remedial or corrective actions detailed in section 10.1, General Indemnity, above. These and all other insurance requirements under the Grant apply to both Grantee and its Subcontractors, if any. Grantee is responsible for ensuring its Subcontractors’ compliance with all requirements.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board of Education agrees to pay the actual tuition costs of courses taken by a teacher at accredited colleges or universities up to three courses per two (2) year fiscal periods from July 1, 2006 to June 30, 2008 and July 1, 2008 to June 30, 2010 respectively, except as follows: 1. No teacher may be reimbursed for courses taken during the first year of teaching in Vineland. 2. Teachers taking courses in the second and third years of employment in Vineland will not receive remuneration until tenure has been secured. The remuneration will then be retroactive and will be paid to the teacher in a lump sum within sixty (60) days after the teacher has secured tenure. 3. All courses must be pre-approved by the Superintendent or his designee subject to the following requirements: (a) A teacher must provide official documentation that he/she has obtained a grade of B or better; (b) Reimbursement shall be paid only for courses directly related to teacher’s teaching field which increase the teacher’s content knowledge and are related to the teacher’s current certification, as determined by the Superintendent or his/her designee in his/her sole discretion; no reimbursement shall be paid for courses leading to a post graduate or professional degree in a field other than education or teaching. Further, effective September 1, 2010, all newly hired teachers shall not be eligible for reimbursement until they are tenured, and they shall not be eligible for retroactive reimbursement upon gaining tenure for courses taken prior to being tenured. (c) The maximum total payments to be made by the Board shall not exceed $130,000.00. Courses shall be applied for no earlier than the following dates: Summer Session - April 1 Fall/Winter Session - June 1 Spring Session - October 1 Courses must, as set forth hereinabove in this sub-article 18.A.3, be pre-approved by the Superintendent or his designee, prior to the teacher commencing the course(s); and (d) Teacher taking courses shall sign a contract requiring them to reimburse the Board for all tuition paid for a course if the teacher shall voluntarily leave the employ of the Board within one (1) full school/academic year of completion of said course, except that reimbursement shall not be required when the teacher shall voluntarily leave the employ of the Board due to a significant, documented life change. 4. Tuition reimbursement costs shall be a sum not to exceed the actual cost of college credits charged in an accredited public State college/University of the State of New Jersey. B. When the Superintendent initiates in-service training courses, workshops, conferences and programs designed to improve the quality of instruction, the cooperation of the Vineland Education Association will be solicited. Notwithstanding the above, the initiation of in-service training courses, workshops, conferences and programs shall be determined solely at the discretion of the Board. C. One professional leave day may be granted to a teacher upon request, according to the following guidelines: 1. The professional day may be for attendance at a workshop, seminar or visit to another school for the expressed purpose of self professional improvement for the job. 2. The request shall arrive in the office of the Superintendent of Schools at least ten (10) working days prior to the date requested and shall be reviewed by the immediate supervisor prior to submission. The Board reserves the right to deny a professional leave day before or immediately following a holiday or on a day which by its nature suggests a hardship for providing a substitute. 3. No more than two teachers from any one elementary school or from any one department in the secondary schools may be granted a professional leave for a given day. 4. The teacher may be required to submit a report to the Superintendent of Schools, Assistant Superintendent, supervisor (s), principal and staff regarding the activity of the professional day. 5. Costs incurred by the teacher for the professional day authorized under this Section shall be the teacher’s responsibility. 6. A maximum of 90 professional leave days may be authorized for the school year which shall be apportioned as follows: elementary, 35; grades seven and eight, 20; and high school, 35. D. If the Board initiates a teacher’s attendance at a professional workshop, seminar or visit, the expenses shall be the responsibility of the Board. Further, this day shall not be subtracted from the 90 professional leave days granted to teachers of the Association. E. The Board agrees to pay the full cost of courses taken by secretaries related to skills and knowledge improvement when such courses are required and approved by the Board. F. The Board and the Association agree that it is important to communicate when developing and implementing current and future learning technologies, including but not limited to distance and on-line learning.
