Extra Duties The Trustee shall be entitled to refuse to approve any Substituted Obligor if, pursuant to the law of the jurisdiction of incorporation of the Substituted Obligor, the assumption by the Substituted Obligor of its obligations hereunder imposes responsibilities on the Trustee over and above those which have been assumed under this Trust Deed.
Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.
Proper Instructions and Special Instructions “Proper Instructions,” which may also be standing instructions, as such term is used throughout this Agreement shall mean instructions received by the Custodian from a Fund, a Fund’s duly authorized investment manager or investment adviser, or a person or entity duly authorized by either of them. Such instructions may be in writing signed by the authorized person or persons or may be in a tested communication or in a communication utilizing access codes effected between electro-mechanical or electronic devices or may be by such other means and utilizing such intermediary systems and utilities as may be agreed from time to time by the Custodian and the person(s) or entity giving such instruction, provided that the Fund has followed any security procedures agreed to from time to time by the applicable Fund and the Custodian including, but not limited to, the security procedures selected by the Fund via the form of Funds Transfer Addendum hereto, the terms of which are hereby agreed to. Oral instructions will be considered Proper Instructions if the Custodian reasonably believes them to have been given by a person authorized to provide such instructions with respect to the transaction involved; the Fund shall cause all oral instructions to be confirmed in writing. For purposes of this Section, Proper Instructions shall include instructions received by the Custodian pursuant to any multi-party agreement which requires a segregated asset account in accordance with Section 2.9 hereof.
Administrative Services Agreement The Administrative Services Agreement has been duly authorized, executed and delivered by the Company and is a valid and binding agreement of the Company, enforceable against the Company in accordance with its terms except as the enforceability thereof may be limited by bankruptcy, insolvency, or similar laws affecting creditors’ rights generally from time to time in effect and by equitable principles of general applicability.
No Reliance on Administrative Agent’s Customer Identification Program Each Lender acknowledges and agrees that neither such Lender, nor any of its Affiliates, participants or assignees, may rely on the Administrative Agent to carry out such Lender’s, Affiliate’s, participant’s or assignee’s customer identification program, or other obligations required or imposed under or pursuant to the USA Patriot Act or the regulations thereunder, including the regulations contained in 31 CFR 103.121 (as hereafter amended or replaced, the “CIP Regulations”), or any other Anti-Terrorism Law, including any programs involving any of the following items relating to or in connection with any of the Loan Parties, their Affiliates or their agents, the Loan Documents or the transactions hereunder or contemplated hereby: (i) any identity verification procedures, (ii) any recordkeeping, (iii) comparisons with government lists, (iv) customer notices or (v) other procedures required under the CIP Regulations or such other Laws.
Instructions to Custodian The Sub-Adviser shall have authority to issue to each Fund’s custodian such instructions as it may consider appropriate in connection with the settlement of any transaction relating to a Fund that it has initiated. The Adviser shall ensure that each Fund’s custodian is obliged to comply with any instructions of the Sub-Adviser given in accordance with this Agreement. The Sub-Adviser will not be responsible for supervising a Fund’s custodian.
Instructions to Obligors The Collection Account is the only account to which Obligors have been instructed by the Borrower, or the Servicer on the Borrower’s behalf, to send Principal Collections and Interest Collections on the Collateral Portfolio. The Borrower has not granted any Person other than the Collateral Agent, on behalf of the Secured Parties, an interest in the Collection Account.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Delegated Identity Theft Prevention Duties Terms in quotation marks in this Section shall have the meaning such terms are assigned in the Identity Theft Red Flag Rules under 16 CFR §681.2 issued by the Federal Trade Commission in November 2007, and replaced by 17 CFR Part 248 issued by the Securities and Exchange Commission on April 10, 2013 (in each case pursuant to the Fair and Accurate Credit Transactions Act of 2003 (the “FACT Act”)), as may be amended from time to time, and the implementing regulations (collectively, the “Rules”). In general, the term “Delegated Identity Theft Prevention Duties” encompasses the functions necessary to fulfill obligations that are imposed upon the Trust and the Fund by the Rules and that relate to information maintained or transactions processed by the Transfer Agent (collectively, the “Identity Theft Prevention Obligations”). Notwithstanding anything to the contrary herein or elsewhere, the Delegated Identity Theft Prevention Duties shall not include any identity theft prevention function related to an obligation of the Trust that is performed by any entity that is neither directly nor indirectly owned by FMR LLC (an “Unaffiliated Intermediary”) pursuant to a provision of a Selling Dealer Agreement, Bank Agency Agreement, or any other agreement between Fidelity Distributors Company LLC or any other entity directly or indirectly owned by FMR LLC and the Unaffiliated Intermediary. Where applicable, the Trust has appointed FIIOC to implement its written IDTPP, which is reasonably designed to comply with the Rules. The IDTPP includes the Delegated Identity Theft Prevention Duties and reflects the Fund’s practices for detecting, preventing and mitigating identity theft for covered accounts. Where applicable the Fund shall exercise appropriate oversight of FIIOC’s IDTPP activities through the Fund’s Program Officer (as that is defined in the IDTPP) or his/her delegates.
Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.
