Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Instructions of the Company The Company shall have the right, by one or more instruments in writing executed and delivered to the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, to direct the time, method and place of conducting any proceeding for the realization of any right or remedy available to the Collateral Agent, or of exercising any power conferred on the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, or to direct the taking or refraining from taking of any action authorized by this Agreement; provided, however, that (i) such direction shall not conflict with the provisions of any law or of this Agreement and (ii) the Collateral Agent, the Custodial Agent and the Securities Intermediary shall be adequately indemnified as provided herein. Nothing in this Section 8.2 shall impair the right of the Collateral Agent in its discretion to take any action or omit to take any action which it deems proper and which is not inconsistent with such direction.
Obligations of the Adviser (a) The Adviser shall provide (or cause the Fund’s Custodian (as defined in Section 5 hereof, the Fund’s accountant and the Fund’s distributor) to provide) timely information to the Sub-Adviser regarding such matters as the composition of the Sub-Advised Assets, cash requirements and cash available for investment in the Sub-Advised Assets, and all other information as may be reasonably necessary for the Sub-Adviser to perform its responsibilities hereunder. (b) The Adviser has furnished the Sub-Adviser with a copy of the prospectus and statement of additional information of the Fund and it agrees during the continuance of this Agreement to furnish the Sub-Adviser copies of any revisions or supplements thereto at, or, if practicable, before the time the revisions or supplements become effective. The Adviser agrees to furnish the Sub-Adviser with copies of any financial statements or reports made by the Fund to its shareholders, and any further materials or information that the Sub-Adviser may reasonably request to enable it to perform its functions under this Agreement.
Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Access to the Authority and the Authority’s Engineer (i) The Right of Way given to the Contractor hereunder shall always be subject to the right of access of the Authority and the Authority’s Engineer and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement. (ii) The Contractor shall ensure, subject to all relevant safety procedures, that the Authority has un-restricted access to the Site during any emergency situation, as decided by the Authority’s Engineer.
Representations of the Adviser 4.1. The Adviser has all requisite power and authority to enter into and perform its obligations under this Agreement, and has taken all necessary corporate action to authorize its execution, delivery and performance of this Agreement. 4.2. The Adviser is registered as an investment adviser under the Advisers Act. None of the Adviser, its affiliates, or any officer, manager, partner or employee of the Adviser or its affiliates is subject to any event set forth in Section 9 of the 1940 Act that would disqualify the Adviser from acting as an investment adviser to an investment company under the 1940 Act. The Adviser will promptly notify the Sub-Adviser upon the Adviser’s discovery of an occurrence of any event that would disqualify the Adviser from serving as an investment adviser of an investment company pursuant to Section 9(a) of the 1940 Act or otherwise. The Adviser agrees to comply with the requirements of the 1940 Act, the Advisers Act, the 1933 Act, the Securities Exchange Act of 1934, as amended, the Commodity Exchange Act and the rules and regulations thereunder, as applicable, as well all other applicable federal and state laws, rules, regulations and case law that relate to the Adviser’s services described hereunder and the to the conduct of its business as a registered investment adviser and to maintain all licenses and registrations necessary to perform its duties hereunder in good order. The Adviser shall maintain compliance procedures that it reasonably believes are adequate to ensure its compliance with the foregoing. 4.3. The Adviser has the authority under the Investment Advisory Agreement to appoint the Sub-Adviser. 4.4. The Adviser further represents and warrants that it has received a copy of the Sub-Adviser’s current Form ADV. 4.5. The Adviser has provided the Sub-Adviser with each Fund’s most current prospectus and statement of additional information contained in the Trust’s registration statement and the Investment Policies, as in effect from time to time. The Adviser shall promptly furnish to the Sub-Adviser copies of all material amendments or supplements to the foregoing documents. 4.6. The Adviser or its delegate will provide timely information to the Sub-Adviser regarding such matters as inflows to and outflows from each Fund and the cash requirements of, and cash available for investment in, the Fund. 4.7. The Adviser or its delegate will timely provide the Sub-Adviser with copies of monthly accounting statements for each Fund, and such other information as may be reasonably necessary or appropriate in order for the Sub-Adviser to perform its responsibilities hereunder.
Rights and discretions of the Agent (a) The Agent may rely on: (i) any representation, notice or document believed by it to be genuine, correct and appropriately authorised; and (ii) any statement made by a director, authorised signatory or employee of any person regarding any matters which may reasonably be assumed to be within his knowledge or within his power to verify. (b) The Agent may assume (unless it has received notice to the contrary in its capacity as agent for the Lenders) that: (i) no Default has occurred (unless it has actual knowledge of a Default arising under Clause 22.1 (Non-payment)); (ii) any right, power, authority or discretion vested in any Party or the Majority Lenders has not been exercised; and (iii) any notice or request made by the Parent (other than a Utilisation Request) is made on behalf of and with the consent and knowledge of all the Obligors. (c) The Agent may engage, pay for and rely on the advice or services of any lawyers, accountants, surveyors or other experts. (d) The Agent may act in relation to the Finance Documents through its personnel and agents. (e) The Agent may disclose to any other Party any information it reasonably believes it has received as agent under this Agreement. (f) Notwithstanding any other provision of any Finance Document to the contrary, neither the Agent nor the Arrangers are obliged to do or omit to do anything if it would or might in its reasonable opinion constitute a breach of any law or regulation or a breach of a fiduciary duty or duty of confidentiality. (g) Without prejudice to the generality of paragraph (f) above, the Agent may disclose the identity of a Defaulting Lender to the other Finance Parties and the Parent and shall disclose the same upon the written request of the Parent or the Majority Lenders. (h) The Agent may not disclose to any Finance Party any details of the rate notified to the Agent by any Lender or the identity of any such Lender for the purpose of paragraph (a)(ii) of Clause 10.2 (Market Disruption).
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Limitations of Authority A. Neither Party has authority for or on behalf of the other except as provided in this XXX. No other authority, power, partnership, use of rights is granted or implied. B. This XXX represents the entire XXX by and between the Parties and supersedes all previous letters, understanding or oral agreements between the College and the School District. Any representations, promises, or guarantees made but not stated in the body of this XXX are null and void and of no effect. C. Neither Party may make, revise, alter, or otherwise diverge from the terms, conditions or policies which are subject to this XXX without a written amendment to this XXX. Changes to this XXX are subject to the approval of the College Legal Department. D. Neither Party may incur any debt, obligation expense, or liability or any kind against the other without the other's express written approval.
REPRESENTATIONS OF THE ADVISOR (a) The Advisor shall use its best judgment and efforts in rendering the advice and services to the Fund as contemplated by this Agreement. (b) The Advisor shall maintain all licenses and registrations necessary to perform its duties hereunder in good order. (c) The Advisor shall conduct its operations at all times in conformance with the Advisers Act, the Investment Company Act, and any other applicable state and/or self-regulatory organization regulations. (d) The Advisor shall maintain errors and omissions insurance in an amount at least equal to that disclosed to the Board of Trustees in connection with their approval of this Agreement.
