Insurance Proceeds under the Construction Contract. Evidence satisfactory to the Facility Agent that the Loss Payable Clause has been or will be endorsed on the Builder’s insurance policy.
Insurance Proceeds under the Construction Contract Sample Clauses
Related to Insurance Proceeds under the Construction Contract
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Use of Insurance Proceeds In case the buildings, improvements or fixtures required to be insured in Section 6.1 or any part thereof shall be destroyed or damaged by fire or such other casualty required to be insured against, then and as often as the same shall happen, all proceeds of such insurance shall be available for and used with all reasonable dispatch by the Lessee in rebuilding, repairing, replacing or otherwise reinstating the buildings, improvements or fixtures so destroyed or damaged in a good and substantial manner according to the plan and elevation thereof, or according to such modified plan as shall be approved under Section 4.1(a), and to pay the rent due the Lessor. If the available insurance proceeds shall be insufficient for rebuilding, repairing, replacing or otherwise reinstating such buildings, improvements or fixtures in the manner provided in this section above, then the Lessee shall provide the balance of all funds required to completely rebuild, repair, replace or otherwise reinstate such buildings, improvements or fixtures. Lessee shall undertake promptly to reinstate the building or buildings, or portions thereof, so destroyed or damaged according to the original plan and elevation thereof, or according to such modified plan as shall be approved by Lessor pursuant to Section 4.1(a). If a casualty under this Section 6.1 shall occur in the last ten (10) years of the Term of this Lease, the Lessee shall have the option of notifying the Lessor that the Lessee does not intend to rebuild the buildings, improvements, or fixtures so destroyed, but rather elects to terminate the Lease as of the date of the casualty, by giving Lessor written notice at least thirty (30) days after the date of the casualty, and then Lessee will, at its own expense, pay all real property taxes and any assessments then outstanding and shall pay over all insurance proceeds to the Lessor, except if requested by Lessor, Lessee shall use the insurance proceeds to promptly remove from the Premises, all buildings, improvements and trade fixtures, and restore the Land then remaining to good, orderly and sanitary condition and even grade, and upon so doing the Lessee shall then surrender any remaining balance of the insurance proceeds (if any), surrender this Lease and Lessee shall be relieved of further performance under this Lease. If the available insurance proceeds shall be insufficient, then Lessee shall provide the balance of all funds required to remove from the Premises, all buildings, improvements and trade fixtures, and restore the Land then remaining to good, orderly and sanitary condition and even grade.
Insurance of Collateral; Condemnation Proceeds (a) Each Loan Party shall maintain insurance with respect to the Collateral, covering casualty, hazard, public liability, theft, malicious mischief, and such other risks, in such amounts, with such endorsements, and with such insurers (rated A or better by A.M. Best Rating Guide) as are reasonably satisfactory to the Agents. All proceeds of Collateral under each policy shall be payable to the Administrative Agent. From time to time upon request, the Loan Parties shall deliver to the Administrative Agent the originals or certified copies of their insurance policies and updated flood plain searches. As soon as practicable and in any event by the last day of each Fiscal Year, the Loan Parties shall deliver to the Agents a report in form and substance reasonably satisfactory to the Agents outlining all material insurance coverage maintained as of the date of such report by the Loan Parties and all material insurance coverage planned to be maintained by the Loan Parties in the immediately succeeding Fiscal Year. Unless the Agents shall agree otherwise, each policy shall include reasonably satisfactory endorsements (i) showing the Administrative Agent as loss payee or additional insured, as appropriate; (ii) requiring 30 days’ prior written notice to the Administrative Agent in the event of cancellation of the policy for any reason whatsoever; and (iii) specifying that the interest of the Administrative Agent shall not be impaired or invalidated by any act or neglect of any Loan Party or the owner of the Property, nor by the occupation of the premises for purposes more hazardous than are permitted by the policy. If any Loan Party fails to provide and pay for such insurance, the Agents may, at their option, but shall not be required to, procure the insurance and charge the Loan Parties therefor. Each Loan Party agrees to deliver to the Agents, promptly as rendered, copies of all reports made to insurance companies. While no Event of Default exists, the Loan Parties may settle, adjust or compromise any insurance claim, as long as the proceeds are delivered to the Administrative Agent. If an Event of Default exists, only the Agents shall be authorized to settle, adjust and compromise such claims. Without limiting the foregoing, the Loan Parties will (a) keep all of their physical property (and the property of their Subsidiaries) insured with casualty or physical hazard insurance on an “all risks” basis, with broad form flood and, to the extent consistent with prudent business practice for the location in which such property is situated, earthquake coverages and electronic data processing coverage, with a full replacement cost endorsement and an “agreed amount” clause in an amount equal to 100% of the full replacement cost of such property, (b) maintain all such workers’ compensation or similar insurance as may be required by Applicable Law and (c) maintain, in amounts and with deductibles equal to those generally maintained by businesses engaged in similar activities in similar geographic areas, general public or civil liability insurance against claims of bodily injury, death or property damage occurring, on, in or about the properties of the Loan Parties and their Subsidiaries; business interruption insurance; and product liability insurance. (b) Any proceeds of insurance (other than proceeds from workers’ compensation or D&O insurance) and any awards arising from condemnation or expropriation of any Collateral shall be paid to the Administrative Agent.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Insurance and Condemnation Proceeds The Borrower Parties shall promptly notify the Agent and the Lenders of any loss, damage, or destruction to the Collateral whether or not covered by insurance. The Agent is hereby authorized to collect all insurance and condemnation proceeds in respect of Collateral directly and to apply or remit them as follows: (i) With respect to insurance and condemnation proceeds relating to Collateral other than Fixed Assets, after deducting from such proceeds the reasonable expenses, if any, incurred by the Agent in the collection or handling thereof, the Agent shall apply such proceeds, ratably, to the reduction of the Obligations in the order provided for in Section 3.6. (ii) With respect to insurance and condemnation proceeds relating to Collateral consisting of Fixed Assets, the Agent shall permit or require the Borrowers to use such proceeds, or any part thereof, to replace, repair, restore or rebuild the relevant Fixed Assets in a diligent and expeditious manner with materials and workmanship of substantially the same quality as existed before the loss, damage or destruction so long as (1) no Default or Event of Default has occurred and is continuing, (2) the aggregate proceeds do not exceed $1,000,000 and (3) the Borrower first (i) provides the Agent and the Required Lenders with plans and specifications for any such repair or restoration which shall be reasonably satisfactory to the Agent and the Required Lenders and (ii) demonstrates to the reasonable satisfaction of the Agent and the Required Lenders that the funds available to it will be sufficient to complete such project in the manner provided therein. In all other circumstances, the Agent shall apply such insurance and condemnation proceeds, ratably, to the reduction of the Obligations in the order provided for in Section 3.6.
Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default. (b) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by such Grantor thereunder. The Agent shall not have any obligation or liability under any such contract or agreement by reason of or arising out of this Agreement or the receipt by the Agent of any payment relating to any of the Collateral, nor shall the Agent be obligated in any manner to perform any of the obligations of any Grantor under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Agent in respect of the Collateral or as to the sufficiency of any performance by any party under any such contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Agent or to which the Agent may be entitled at any time or times. The Agent’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Sections 9-207 and 9-208 of the UCC or otherwise, shall be to deal with such Collateral in the same manner as the Agent deals with similar property for its own account. (c) Each Grantor shall, to the extent reasonably necessary to preserve and maintain the Intellectual Property Collateral and the interest of the Agent therein, diligently pursue legal or other action to enforce the Intellectual Property Collateral and any licenses thereof.
Application of Insurance Proceeds Grantor shall promptly notify Lender of any loss or damage to the Collateral. Lender may make proof of loss if Grantor fails to do so within fifteen (15) days of the casualty. All proceeds of any insurance on the Collateral, including accrued proceeds thereon, shall be held by Lender as part of the Collateral. If Lender consents to repair or replacement of the damaged or destroyed Collateral, Lender shall, upon satisfactory proof of expenditure, pay or reimburse Grantor from the proceeds for the reasonable cost of repair or restoration. If Lender does not consent to repair or replacement of the Collateral, Lender shall retain a sufficient amount of the proceeds to pay all of the Indebtedness, and shall pay the balance to Grantor. Any proceeds which have not been disbursed within six (6) months after their receipt and which Grantor has not committed to the repair or restoration of the Collateral shall be used to prepay the Indebtedness.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral. (b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies. (c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in (i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Trustee to Retain Possession of Certain Insurance Policies and Documents The Trustee (or the Custodian, as directed by the Trustee), shall retain possession and custody of the originals (to the extent available) of any Primary Mortgage Insurance Policies, or certificate of insurance if applicable, and any certificates of renewal as to the foregoing as may be issued from time to time as contemplated by this Agreement. Until all amounts distributable in respect of the Certificates have been distributed in full and the Master Servicer otherwise has fulfilled its obligations under this Agreement, the Trustee (or its Custodian, if any, as directed by the Trustee) shall also retain possession and custody of each Mortgage File in accordance with and subject to the terms and conditions of this Agreement. The Master Servicer shall promptly deliver or cause to be delivered to the Trustee (or the Custodian, as directed by the Trustee), upon the execution or receipt thereof the originals of any Primary Mortgage Insurance Policies, any certificates of renewal, and such other documents or instruments that constitute portions of the Mortgage File that come into the possession of the Master Servicer from time to time.
Conditions to Obligations of Each Party Under This Agreement The respective obligations of each party to effect the Merger and the other transactions contemplated herein shall be subject to the satisfaction at or prior to the Effective Time of the following conditions, any or all of which may be waived, in whole or in part, to the extent permitted by applicable Law:
