FAITH-BASED ORGANIZATIONS A. Contractor agrees and acknowledges that County may make funds available for programs or services affiliated with religious organizations under the following conditions: (a) the funds are made available on an equal basis as for programs or services affiliated with non-religious organizations; (b) the program funded does not have the substantial effect of supporting religious activities; (c) the funding is indirect, remote, or incidental to the religious purpose of the organization; and (d) the organization complies with the terms and conditions of this Contract.
Excess Obligations Prohibited The Contract is subject to termination or cancellation, without penalty to the System Agency, either in whole or in part, subject to the availability of state funds. System Agency is a state agency whose authority and appropriations are subject to actions of the Texas Legislature. If System Agency becomes subject to a legislative change, revocation of statutory authority, or lack of appropriated funds that would render either System Agency’s or Performing Agency’s delivery or performance under the Contract impossible or unnecessary, the Contract will be terminated or cancelled and be deemed null and void. In the event of a termination or cancellation under this Section, System Agency will not be liable to Performing Agency for any damages that are caused or associated with such termination, or cancellation, and System Agency will not be required to give prior notice.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Recourse to Agencies or Courts of Competent Jurisdiction Notwithstanding Section 11.2, nothing in this Agreement shall restrict the rights of a Party to file a complaint with the FERC under relevant provisions of the Federal Power Act or with the PUCO under relevant provisions of the Legal Authorities. The Parties’ agreement under this Section 11.3 is without prejudice to any Party’s right to contest jurisdiction of the FERC or PUCO to which a complaint is brought.
Additional Indemnity Obligations Consultant shall defend, with counsel of Town’s choosing and at Consultant's own cost, expense and risk, any and all claims, suits, actions or other proceedings of every kind covered by Section 3.5.6.1 that may be brought or instituted against Town or its directors, officials, officers, employees, volunteers and agents. Consultant shall pay and satisfy any judgment, award or decree that may be rendered against Town or its directors, officials, officers, employees, volunteers and agents as part of any such claim, suit, action or other proceeding. Consultant shall also reimburse Town for the cost of any settlement paid by Town or its directors, officials, officers, employees, agents or volunteers as part of any such claim, suit, action or other proceeding. Such reimbursement shall include payment for Town's attorney's fees and costs, including expert witness fees. Consultant shall reimburse Town and its directors, officials, officers, employees, agents, and/or volunteers, for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. Consultant's obligation to indemnify shall not be restricted to insurance proceeds, if any, received by the Town, its directors, officials officers, employees, agents, or volunteers.
Obligation to Indemnify Subject to the provisions of this Section IV.G, Company will indemnify and hold Investor, its Affiliates, managers and advisors, and each of their officers, directors, shareholders, partners, employees, representatives, agents and attorneys, and any person who controls Investor within the meaning of Section 15 of the Act or Section 20 of the Exchange Act (collectively, “Investor Parties” and each a “Investor Party”), harmless from any and all losses, liabilities, obligations, claims, contingencies, damages, reasonable costs and expenses, including all judgments, amounts paid in settlements, court costs and reasonable attorneys’ fees and costs of investigation (collectively, “Losses”) that any Investor Party may suffer or incur as a result of or relating to (a) any breach of any of the representations, warranties, covenants or agreements made by Company in this Agreement or in the other Transaction Documents, (b) any untrue statement or alleged untrue statement of a material fact contained in the Registration Statement, Prospectus, Prospectus Supplement, or any information incorporated by reference therein, or arising out of or based upon any omission or alleged omission to state a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading, or (c) any action by a creditor or stockholder of Company who is not an Affiliate of an Investor Party, challenging the transactions contemplated by the Transaction Documents; provided, however, that Company will not be obligated to indemnify any Investor Party for any Losses finally adjudicated to be caused solely by (i) a false statement of material fact contained within written information provided by such Investor Party expressly for the purpose of including it in the applicable Registration Statement, Prospectus, Prospectus Supplement, or (ii) such Investor Party’s unexcused material breach of an express provision of this Agreement or another Transaction Document.
APPLICANT’S OBLIGATION TO MAINTAIN VIABLE PRESENCE In order to receive and maintain the limitation authorized by Section 2.4 in addition to the other obligations required by this Agreement, the Applicant shall Maintain Viable Presence in the District commencing at the start of the Tax Limitation Period through the Final Termination Date of this Agreement. Notwithstanding anything contained in this Agreement to the contrary, the Applicant shall not be in breach of, and shall not be subject to any liability for failure to Maintain Viable Presence to the extent such failure is caused by Force Majeure, provided the Applicant makes commercially reasonable efforts to remedy the cause of such Force Majeure.
Indemnification Clause The Union agrees to indemnify and hold the County of Los Angeles harmless from any liabilities of any nature which may arise as a result of the application of the provisions of this Article.
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
Name and Organizational Changes (a) PSP must provide TFC with written notification of all name changes and organizational changes relating to PSP including, but not limited to, merger, acquisition, corporate reorganization, or sale no later than sixty (60) days prior to such change. PSP, in its notice, shall describe the circumstances of the name or organizational change, state its new name, provide the new Tax Identification Number, if available, and describe how the change will impact its ability to perform under the Agreement. All written notifications of organizational change must include a detailed statement specifying the change and supporting documentation evidencing continued right of Agreement or successor entity, as applicable, to maintain its status as a party to this Agreement. If the change entails personnel changes for personnel performing the responsibilities of the Agreement for PSP, PSP shall identify the new personnel and provide resumes to TFC, if resumes were originally required by the solicitation. TFC may require other information or documents related to the change and its impact on the PSP and Agreement shall supply the requested information within five (5) working days of receipt of the request.
