Intellectual Property Indemnification Seller shall defend, indemnify and hold Purchaser and its Affiliates harmless from and against any and all expenses, costs, claims, demands, causes of action and damages of whatever kind which Purchaser may incur in connection with any suit or claim of infringement of any patent, copyright or trademark, or misappropriation of any trade secret or other intellectual property right resulting from (i) Purchaser's or its Affiliates' use of any portion of the Equipment as contemplated in the Proposal and otherwise in accordance with this Sales Agreement or applicable Equipment documentation delivered by Purchaser by Seller hereunder, or (ii) performance of the Work, except, in each case with respect to each of the foregoing clauses (i) and (ii), to the extent directly attributable to Third-Party Hardware or Third-Party Software. Seller shall receive written notice from Purchaser within ten (10) days after proper legal service is received by Purchaser of any such suit or claim, provided that failure to receive such notice shall not relieve Seller of its obligations under this Article 3 except to the extent that Seller's ability to defend such suit or claim is materially impaired due to such failure. Seller is hereby authorized by Purchaser to, at Seller's expense, appear in and assume the defense of, and be given the complete control of the settlement of, any such suit or claim; provided that (a) if Purchaser or any of its Affiliates wishes to participate in the defense and settlement of the claim, Purchaser or any of its Affiliates may do at its own cost, (b) Purchaser is kept timely informed of all material actions taken by Seller in connection with any such settlement, suit or claim (including, without limitation, of settlement offers and responses (to the extent the delivery of such information does not require Seller to waive work product immunity or attorney/client privilege or otherwise violate the terms of any protective order between Seller and any third party plaintiff or defendant)); and (c) Seller shall not enter into or acquiesce to any settlement admitting to or stipulating to any guilt, fault, liability or wrongdoing on the part of Purchaser or any of its Affiliates without Purchaser's prior written consent. In the event that Purchaser's right or ability to use the Equipment is threatened or impaired as a result of any such suit or claim, Seller shall, at its own expense, do one of the following, (1) diligently procure for Purchaser the right to continue using the Equipment, or (2) modify the Equipment or, if necessary and by mutual agreement, substitute functionally equivalent Equipment, to the extent necessary to avoid infringement or misappropriation; provided in each case that if such modified or substituted equipment fails to comply with all Specifications applicable to the original, unmodified Equipment, Purchaser shall be entitled to equitable compensation with respect to such noncompliance. Seller hereby assigns to or otherwise transfers to the benefit of Purchaser all of its right, title and interest in and to any intellectual property right infringement or misappropriation indemnification or defense rights Seller may have with respect to Third Party Software and Third Party Hardware, and will, at its expense, take any actions as may be necessary to enable Purchaser to exercise such rights and realize such benefit to the fullest extent possible. It is mutually agreed that the provisions set forth herein are Seller's only obligations with respect to infringement of any patent, copyright or trademark, or misappropriation of any trade secret or other intellectual property right.
Intellectual Property Indemnity The Seller shall indemnify, defend and hold harmless, the Buyer, its Affiliates and its and their officers, employees, agents, Financing Parties, and Subcontractors against all liabilities, damages, losses, costs or expenses (including, without limitation, attorneys’ fees and expenses) arising out of any suit, claim, or proceeding (a “Claim”) alleging that the Equipment or Services provided under this Contract violate or infringe any Intellectual Property if: (a) the Buyer promptly notifies the Seller in writing of the Claim; (b) gives the Seller sole authority, at the Seller’s expense, using counsel reasonably acceptable to the Buyer, to direct and control the defense and any settlement and compromise negotiations; provided, however, that the Buyer shall have the right to participate at the Seller’s expense in any such settlement and compromise negotiations that would require any changes to the Services or Equipment or that would require any action or restraint of action by the Buyer and that the Buyer shall have the right to approve any settlement that would require any changes to the Services or Equipment or that would require any action or restraint of action by the Buyer (which consent shall not be unreasonably withheld); and (c) the Buyer provides the Seller, at the Seller’s expense, with such disclosure and assistance of the Buyer as may be reasonably required to defend any such Claim. If the Seller does not promptly undertake defense of any such claim after notice of same from the Buyer, the Buyer shall be entitled but not required to undertake the defense of such claim and shall have the right to direct and control the defense and any settlement and compromise negotiations concerning such claim with counsel selected by the Buyer and that the Seller shall have the right to approve any settlement (which consent shall not be unreasonably withheld); all at the Seller’s expense. For the avoidance of doubt, the Buyer’s election to undertake or not to undertake such defense will not limit in any way the Seller’s indemnification obligations hereunder.
Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement or (b) that use of the Licensed Marks by Licensee in accordance with the terms and conditions of this Agreement infringes or otherwise violates a third party’s Trademarks. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
Intellectual Property Infringement To the knowledge of the Company and the Operating Partnership and except as disclosed in the Registration Statement, the Pricing Disclosure Package and the Prospectus, neither the Company nor any of its Subsidiaries has infringed or is infringing the intellectual property of a third party, and neither the Company nor any of its Subsidiaries has received notice of a claim by a third party to the contrary, except for any such notice that would not reasonably be expected to have a Material Adverse Effect.
Indemnification by Lessee Lessee shall indemnify and hold Operator harmless against all claims, demands, actions, liabilities, losses, damages, lawsuits and other proceedings at law or in equity, judgments, awards, commissions, fees, costs and expenses (including, without limitation, attorneys’ fees and expenses), of every kind and nature whatsoever to or of any party connected with or arising out of, or by reason of any gross negligent act or omission, breach of contract, willful misconduct, or tortious actions by Lessee or any Affiliate of Lessee, or any officer, employee, agent, contractor, subcontractor, or other person or entity working for Lessee or any Affiliate of Lessee. The indemnification provisions of this Section 5.03 are subject to the limitations set forth in Section 5.02. Lessee will indemnify and hold Operator harmless from all costs, expenses, claims, damages and liabilities, including without limitation, lawyers’ fees and disbursements, arising or resulting from Lessee’s failure following the expiration or earlier termination (for whatever cause) of this Agreement to provide all of the services contracted for in connection with the business booked on commercially reasonable terms for the Hotels on or prior to the date of such expiration or termination. The provisions of this Section will survive any expiration or termination of this Agreement and will be binding upon Lessee and its successors and assigns, including any successor or assign that becomes the beneficial or legal owner of the Hotels after the effective date of any such expiration or termination.
Intellectual Property Claims Borrower is the sole owner of, or otherwise has the right to use, the Intellectual Property. Except as described on Schedule 5.9,(i) each of the material Copyrights, Trademarks and Patents is valid and enforceable, (ii) no material part of the Intellectual Property has been judged invalid or unenforceable, in whole or in part, and (iii) no claim has been made to Borrower that any material part of the Intellectual Property violates the rights of any third party. Exhibit D is a true, correct and complete list of each of Borrower’s Patents, registered Trademarks, registered Copyrights, and material agreements under which Borrower licenses Intellectual Property from third parties (other than shrink-wrap software licenses), together with application or registration numbers, as applicable, owned by Borrower or any Subsidiary, in each case as of the Closing Date. Borrower is not in material breach of, nor has Borrower failed to perform any material obligations under, any of the foregoing contracts, licenses or agreements and, to Borrower’s knowledge, no third party to any such contract, license or agreement is in material breach thereof or has failed to perform any material obligations thereunder.
Standard of Liability Indemnifications Confidential material redacted and filed separately with the Commission.
Licensee Indemnification Licensee shall and shall cause its affiliates to indemnify, defend and hold harmless NCIT and its Subcontractors and their Representatives and successors and assigns (each, a “NCIT Indemnitee”) from and against any and all Losses incurred by such NCIT Indemnitee in connection with any Action that arises out of or relates to this Agreement or any of the following:
Indemnification by Client Client shall indemnify and hold Dalmore, its affiliates and their representatives and agents harmless from, any and all actual or direct losses, liabilities, judgments, arbitration awards, settlements, damages and costs (collectively, “Losses”), resulting from or arising out of any third party suits, actions, claims, demands or similar proceedings (collectively, “Proceedings”) to the extent they are based upon (i) a breach of this Agreement by Client, (ii) the wrongful acts or omissions of Client, or (iii) the Offering.
