Intercept Obligations Sample Clauses

Open Split View

Download

Share

Cite

Intercept Obligations 

Sample 1

Save

Copy

Related to Intercept Obligations

• Client Obligations 3.1 The Client warrants and represents that: 3.1.1 it shall co-operate with Centaur as required for the proper performance of the Services; 3.1.2 it shall provide, for Centaur, its agents, subcontractors, consultants and employees, in a timely manner and at no charge, access to the Client's premises during normal office hours (being Monday – Friday 8am – 6pm), office accommodation, data and other facilities as is reasonably required by Centaur or any of them for the proper performance of the Services; 3.1.3 all information it has provided to Centaur in relation to the Services as at the date of the Order Form is accurate, complete and is not misleading and it shall provide, in a timely manner, such further information and Client Material as Centaur may require for the proper performance of the Services, and ensure that such information and Client Material is accurate, complete and not misleading; 3.1.4 it shall be responsible (at its own cost) for preparing and maintaining the relevant premises for the supply of the Services; 3.1.5 it shall inform Centaur of all health and safety rules and regulations and any other reasonable security requirements that apply at any of the Client's premises; 3.1.6 it shall only use the Services for internal business purposes and, without prejudice to the foregoing, shall not use the Services, the Deliverables or any Centaur Materials to develop a product or service that competes with any of the products or services provided by Centaur; 3.1.7 the Client Materials shall not infringe any third party rights, including any third party Intellectual Property Rights; and 3.1.8 it shall obtain and maintain all necessary licences and consents and comply with all relevant legislation in relation to the Services, before the date on which the Services are to start. 3.2 If Centaur's performance of its obligations under this Agreement is prevented or delayed by any act or omission of the Client, its agents, subcontractors, consultants or employees, Centaur shall not be liable for any costs, charges or losses sustained or incurred by the Client that arise directly or indirectly from such prevention or delay.

• Joint Obligations A. The University and the student share the responsibility for ensuring the quality of life within the residence halls, their maintenance, furnishings and facilities, and for a physical environment secure from fire and other hazards. The University will work with students to promote effective security of persons and property in the residence halls.

• Recipient Obligations 2.1 The Recipient agrees to support the Project in accordance with this Agreement. 2.2 In supporting the Project, the Recipient must: (a) exercise reasonable diligence, care and skill; (b) administer the Funding in accordance with the Agreement to support the Fellow to complete the Project; (c) not replace the Fellow named in the Application with another person; (d) complete the Project Deliverables by the relevant Deliverable due dates. This includes the provision of the required Reports, Financial Acquittal Statements and valid tax invoices; (e) ensure that the Fellow completes the Project Milestones annually; (f) ensure it makes the Recipient Contribution to the Project as per the Application and summarised in Item 11 of Schedule 1; (g) ensure the Partners provide the Partner Contributions to the Project as per the Application and summarised in Item 12 of Schedule 1; (h) ensure that the Project expenditure is managed in accordance with the project expenditure table in the Application; (i) notify the Department within 20 Business Days of any matter that may affect the Fellow or Recipient’s eligibility for funding under the Guidelines, including but not limited to: (i) the Fellow ceasing employment with the Recipient; (ii) the Fellow moving residence to outside of Queensland; (iii) the Fellow travelling outside of Queensland for more than six weeks; (iv) the Fellow taking extended leave or being unable to undertake the Project for an extended period; (v) the Fellow changing the proportion of their time committed to the Project; (vi) the Recipient Contributions or Partner Contributions changing; (vii) the Project Partner organisations changing; and (viii) the Project expenditure changing. (j) ensure that (where relevant): (i) the Project complies with National Health and Medical Research Council Guidelines; (ii) the Project complies with the Code of Ethical Practice for Biotechnology in Queensland; (iii) the Project is cleared by all relevant ethical committees prescribed by the Recipient organisation’s research rules; and (iv) evidence of compliance with this clause is provided, if requested by the Department; (k) not assign, transfer or subcontract its obligations, without prior written consent of the Department; (l) notify the Department of any breach of these terms or any matter that may affect the performance of the Agreement; and (m) comply with all relevant laws.

• Third Party Obligations 3.1. The THIRD PARTY shall:- 3.1.1. not divulge the Confidential Information to any party other than as provided for in this Confidentiality Agreement; 3.1.2. use the Confidential Information only for the purposes necessary in providing the services for which he is engaged by the AUTHORITY; and 3.1.3. make no commercial use of the Confidential Information or any part thereof. 3.2. Notwithstanding the foregoing, the THIRD PARTY shall be entitled to make any disclosure required by law of the Confidential Information and shall notify the AUTHORITY of so doing in accordance with the provisions of paragraph 6.

• Development Obligations 1. The College supports the development, production, and dissemination of copyrightable, trademarkable, patentable, and other intellectual properties by its employees. 2. It is understood that intellectual property developed by employees on or off College time, except for those materials for which the College had specifically contracted prior to June 9, 1998, shall remain the property of such employees, but shall continue to be used for the benefit of the College while the employee remains an employee of the College.

• Obligations of the Parties Clause 8

• Issuing Bank’s Duties Regarding Letters of Credit; Unconditional Nature of Reimbursement Obligations In examining documents presented in connection with drawings under Letters of Credit and making payments under such Letters of Credit against such documents, the Issuing Bank shall only be required to use the same standard of care as it uses in connection with examining documents presented in connection with drawings under letters of credit in which it has not sold participations and making payments under such letters of credit. The Borrower assumes all risks of the acts and omissions of, or misuse of the Letters of Credit by, the respective beneficiaries of such Letters of Credit. In furtherance and not in limitation of the foregoing, none of the Issuing Bank, Administrative Agent or any of the Lenders shall be responsible for, and the Borrower’s obligations in respect of Letters of Credit shall not be affected in any manner by, (i) the form, validity, sufficiency, accuracy, genuineness or legal effects of any document submitted by any party in connection with the application for and issuance of or any drawing honored under any Letter of Credit even if such document should in fact prove to be in any or all respects invalid, insufficient, inaccurate, fraudulent or forged; (ii) the validity or sufficiency of any instrument transferring or assigning or purporting to transfer or assign any Letter of Credit, or the rights or benefits thereunder or proceeds thereof, in whole or in part, which may prove to be invalid or ineffective for any reason; (iii) failure of the beneficiary of any Letter of Credit to comply fully with conditions required in order to draw upon such Letter of Credit; (iv) errors, omissions, interruptions or delays in transmission or delivery of any messages, by mail, cable, facsimile, electronic mail, telecopy or otherwise, whether or not they be in cipher; (v) errors in interpretation of technical terms; (vi) any loss or delay in the transmission or otherwise of any document required in order to make a drawing under any Letter of Credit, or of the proceeds thereof; (vii) the misapplication by the beneficiary of any Letter of Credit, or of the proceeds of any drawing under any Letter of Credit; or (viii) any consequences arising from causes beyond the control of the Issuing Bank, Administrative Agent or the Lenders. None of the above shall affect, impair or prevent the vesting of any of the Issuing Bank’s or Administrative Agent’s rights or powers hereunder. Any action taken or omitted to be taken by the Issuing Bank under or in connection with any Letter of Credit, if taken or omitted in the absence of gross negligence or willful misconduct (as determined by a court of competent jurisdiction in a final, non-appealable judgment), shall not create against the Issuing Bank any liability to the Borrower, the Administrative Agent or any Lender. In this connection, the obligation of the Borrower to reimburse the Issuing Bank for any drawing made under any Letter of Credit, and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), shall be absolute, unconditional and irrevocable and shall be paid strictly in accordance with the terms of this Agreement and any other applicable Letter of Credit Document under all circumstances whatsoever, including without limitation, the following circumstances: (A) any lack of validity or enforceability of any Letter of Credit Document or any term or provisions therein; (B) any amendment or waiver of or any consent to departure from all or any of the Letter of Credit Documents; (C) the existence of any claim, setoff, defense or other right which the Borrower may have at any time against the Issuing Bank, the Administrative Agent or any Lender, any beneficiary of a Letter of Credit or any other Person, whether in connection with this Agreement, the transactions contemplated hereby or in the Letter of Credit Documents or any unrelated transaction; (D) any breach of contract or dispute between the Borrower, the Issuing Bank, the Administrative Agent, any Lender or any other Person; (E) any demand, statement or any other document presented under a Letter of Credit proving to be forged, fraudulent, invalid or insufficient in any respect or any statement therein or made in connection therewith being untrue or inaccurate in any respect whatsoever; (F) any non-application or misapplication by the beneficiary of a Letter of Credit or of the proceeds of any drawing under such Letter of Credit; (G) payment by the Issuing Bank under any Letter of Credit against presentation of a draft or certificate which does not strictly comply with the terms of such Letter of Credit; and (H) any other act, omission to act, delay or circumstance whatsoever that might, but for the provisions of this Section, constitute a legal or equitable defense to or discharge of the Borrower’s Reimbursement Obligations. Notwithstanding anything to the contrary contained in this Section or Section 12.10., but not in limitation of the Borrower’s unconditional obligation to reimburse the Issuing Bank for any drawing made under a Letter of Credit as provided in this Section and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), the Borrower shall have no obligation to indemnify the Administrative Agent, the Issuing Bank or any Lender in respect of any liability incurred by the Administrative Agent, the Issuing Bank or such Lender arising solely out of the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or such Lender in respect of a Letter of Credit as determined by a court of competent jurisdiction in a final, non-appealable judgment. Except as otherwise provided in this Section, nothing in this Section shall affect any rights the Borrower may have with respect to the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or any Lender with respect to any Letter of Credit.

• Independent Obligations The Guarantor acknowledges that its obligations hereunder are independent of the obligations of the Issuer with respect to the Capital Securities and that the Guarantor shall be liable as principal and as debtor hereunder to make Guarantee Payments pursuant to the terms of this Guarantee notwithstanding the occurrence of any event referred to in subsections (a) through (g), inclusive, of Section 4.3 hereof.

• Obligations of the Licensee 5.1.1. The Licensee’s Responsibilities and Duties shall include the following, in addition to and without prejudice to other obligations under this Agreement: a. to obtain due permits, necessary approvals, clearances and sanctions from Maha-Metro and all other competent authorities for all activities or infrastructure facilities including interior decoration, power, water supply, drainage & sewerage, telecommunication, etc.; b. to comply and observe at all times with all Applicable Permits, approvals and Applicable Laws in the performance of its obligations under this Agreement including those being performed by any of its contractors; c. to develop, operate and maintain the Licensed Area at all times in conformity with this Agreement; d. to furnish Maha-Metro with the “As built” Drawings of the Licensed Space(s) within the Moratorium Period; e. to ensure that no structural damage is caused to the existing buildings and other permanent structures at the station as a result of his activities or any of its agents, contractors etc.; f. to take all reasonable steps to protect the environment (both on and off the property business space) and to limit damage and nuisance to people and property resulting from construction and operations, within guidelines specified as per Applicable Laws and Applicable Permits; g. to duly supervise, monitor and control the activities of contractors, agents, etc., if any, under their respective License Agreements as may be necessary; h. to take all responsible precautions for the prevention of accidents on or about the property business space and provide all reasonable assistance and emergency medical aid to accident victims; i. not to permit any person, claiming through or under the Licensee, to create or place any encumbrance or security interest over whole or any part of the Licensed premises and/or other installed assets, or on any rights of the Licensee therein or under this Agreement, save and except as expressly permitted in this Agreement; j. to keep the Licensed Space free from all unnecessary obstruction during execution of works and store the equipment or surplus materials, dispose of such equipment or surplus materials in a manner that causes least inconvenience to the Xxxxx Xxxxxxx, metro commuters or Maha-Metro’s activities. k. at all times, to afford access to the Licensed Property Business Space to the authorised representatives of Maha-Metro, other persons duly authorised by any Governmental Agency having jurisdiction over the business of Licensed Property Business Space, to inspect the Licensed Property Business Space and to investigate any matter within their authority and upon reasonable notice; and l. use non-combustable material in the allotted space for creation/erection/installation of any kind of furniture, fixtures and or partitions within the space. Use of combustable material within the property business space shall not be permitted under any circumstances. m. to comply with the divestment requirements and hand over the Licensed Property Business Space to Maha-Metro upon Termination of the Agreement; 5.1.2. The Licensee shall be solely and primarily responsible to Maha-Metro for observance of all the provisions of this License Agreement on behalf of its employees and representatives and agents and any person acting under or for and on behalf of the Licensee, contractor (s) appointed for the Licensed Space as fully as if they were the acts or defaults of the Licensee, its agents or employees.

• Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement. (iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person. (iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority. (v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3. (vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event. (vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement: (a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws; (b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway; (c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement; (d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement; (e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement; (f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement; (g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice; (h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times; (i) cooperate with other contractors employed by the Authority and personnel of any public authority; and (j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others. (viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works. (ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor. (x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects. (xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement. (xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices. (xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.