Maintenance Repairs Utility Installations Trade Fixtures and Alterations (a) Subject to the provisions of Paragraphs 2.2 (Lessor’s warranty as to condition), 2.3 (Lessor’s warranty as to compliance with covenants, etc.), 7.2 (Lessor’s obligations to repair), 9 (damage and destruction), and 14 (condemnation), Lessee shall, at Lessee’s sole cost and expense and at all times, keep the Premises and every part thereof in good order, condition and repair, structural and non-structural (whether or not such portion of the Premises requiring repair, or the means of repairing the same, are reasonably or readily accessible to Lessee, and whether or not the need for such repairs occurs as a result of Lessee’s use, any prior use, the elements or the age of such portion of the Premises), including, without limiting the generality of the foregoing all equipment or facilities serving the Premises, such as plumbing, heating, air conditioning, ventilating, electrical, lighting facilities, boilers, fired or unfired pressure vessels, fire sprinkler and/or standpipe and hose or other automatic fire extinguishing system, including fire alarm and/or smoke detection systems and equipment, fire hydrants, fixtures, walls (interior and exterior), foundations, ceilings, roofs, floors, windows, doors, plate glass, skylights, landscaping, driveways, parking lots, fences, retaining walls, signs, sidewalks and parkways located in, on, about, or adjacent to the Premises. Lessee shall not cause or permit any Hazardous Substance to be spilled or released in, on, under or about the Premises (including through the plumbing or sanitary sewer system) and shall promptly, at Lessee’s expense, take all investigatory and/ore remedial action reasonably recommended, whether or not formally ordered or required, for the cleanup of any contamination of, and for the maintenance, security and/or monitoring of, the Premises, the elements surrounding same, or neighboring properties that was caused or materially contributed to by Lessee, or pertaining to or involving any Hazardous Substance and/or storage tank brought onto the premises by or for lessee or under its control. Lessee, in keeping the Premises in good order, condition and repair, shall exercise and perform good maintenance practices. Lessee’s obligations shall include restorations, replacements or renewals when necessary to keep the Promises and all improvements thereon or a part thereof in good order, condition and state of repair. If Lessee occupies the Premises for seven (7) years or more, lessor may require Lessee to repaint the exterior of the buildings on the Premises as reasonably required, but not more frequently than once every seven (7) years.
(b) Lessee shall, at Lessee’s sole cost and expense, procure and maintain contracts, with copies to Lessor, in customary form and substance for, and with contractors specializing and experienced in, the inspection, maintenance and service of the following equipment and improvements, if any, located on the Premises: (i) heating, air conditioning and ventilation equipment, (ii) boiler, fired or unfired pressure vessels, (iii) fire sprinkler and/or standpipe and hose or other automatic fire extinguishing systems, including fire alarm and/or smoke detection. (iv) landscaping and irrigation systems, (v) roof covering and drain maintenance and (vi) asphalt and parking lot maintenance.
Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements:
(a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work.
(b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay.
(c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord.
(d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Landlord’s Work The Landlord will provide and carry out, in accordance with the provisions of the Lease, including, without limitation, this Schedule, at the Tenant’s expense, all equipment and work other than Tenant’s Work required to be provided in order to render the Premises complete and suitable to open for business (the “Landlord’s Work”) including, but not limited to the following: • Connecting all utilities including, power to building and distribution panels to the Premises, including the requirement to provide via separate metering. • Connecting water, including without limitation hot water, to greenhouse area and distribution water tank(s). • Installation of a storage cooler. • All concrete work around the greenhouse and drive-way to the compost hut and floor for compost piles as designed. • Installation of necessary or required ventilation fans. • Installation or replacement of lighting, including without limitation any required high upper grow lights. • Installation of hand wash stations in the Premises. • Gas heaters and controls. • Any repairs or refurbishing of outer panels, germination room walls. The Tenant’s consent (not to be unreasonably withheld, conditioned or delayed), shall be required prior to the commencement of the Landlord’s Work. The Landlord shall provide, in such detail as the Tenant may reasonably request, all material documentation relating to the Landlord’s Work, including without limitation, any proposed plans and drawings, proposed agreements with any contractors or subcontractors and estimated costs to complete the Landlord’s Work. Subject to receiving the Tenant’s consent as contemplated herein, the Landlord shall commence the Landlord’s Work in accordance with the terms of this Lease. Upon completion of the Landlord’s Work, the Landlord shall provide the Tenant receipted invoices verifying the actual cost of completing the Landlord’s Work in the Premises. It is acknowledged and agreed that in consideration for the Tenant being responsible for all the costs associated with the Landlord’s Work as contemplated herein, the cost of the Landlord’s Work shall be included in total amount subject recoverable by the Tenant and to the Free Rent Period (as hereinafter defined) subject to the terms and conditions of this Schedule “D” and the Lease, generally.
Tenant’s Equipment Tenant shall provide notice to Landlord prior to moving any heavy machinery, heavy equipment, freight, bulky matter or fixtures (collectively, “Equipment”) into or out of the Building and shall pay to Landlord any costs actually incurred by Landlord in connection therewith. If such Equipment requires special handling, Tenant agrees (a) to employ only persons holding all necessary licenses to perform such work, (b) all work performed in connection therewith shall comply with all applicable Requirements and (c) such work shall be done only during hours designated by Landlord.
Maintenance Repairs and Alterations A. Except to the extent such obligations are imposed upon Landlord hereunder, Tenant shall, at its sole cost and expense, maintain the interior of the Premises in good order, condition and repair throughout the entire Lease Term, ordinary wear and tear excepted. Tenant agrees to keep the areas visible from outside the Premises in a neat, clean and attractive condition at all times. Tenant shall, within thirty (30) days after Landlord’s written demand therefor, reimburse Landlord for the cost of all repairs, replacements and alterations (collectively, “Repairs”) in and to the Premises, Building and Property and the facilities and systems thereof, plus an administration charge often percent (10%) of such cost, the need for which Repairs arises out of (and provided Landlord has given prior written notice to Tenant of such need): (1) Tenant’s use of the Premises in contravention of the terms and conditions of this Lease, or Tenant’s failure to perform maintenance or repairs which are Tenant’s obligation hereunder, (2) the installation, removal, use or operation of Tenant’s Property, if undertaken by Landlord at Tenant’s request or by virtue of Tenant’s default in undertaking such obligations, (3) the moving of Tenant’s Property into or out of the Building, or (4) the act, omission, misuse or negligence of Tenant, its agents, contractors, employees or invitees.
B. Tenant shall not make or allow to be made any alterations, additions or improvements to the Premises (collectively, “Alterations”), without first obtaining the written consent of Landlord, which consent shall not be unreasonably withheld or delayed; provided however, Tenant shall have the right to perform, without Landlord’s consent, certain Alterations that do not cost in excess of $25,000.00 in the aggregate (at any one time), and do not affect any mechanical or electrical or life safety systems or plumbing in the Building, provided that advance notice has been given to Landlord in each instance. Landlord reserves the right to require Tenant to remove at the end of the Lease Term any Alterations installed without the Landlord’s consent. Prior to commencing any such Alterations and as a condition to obtaining Landlord’s consent where necessary, Tenant shall deliver to Landlord plans and specifications acceptable to Landlord; names and addresses of contractors reasonably acceptable to Landlord; copies of contracts; necessary permits and approvals; evidence of contractor’s and subcontractor’s insurance in accordance with Section 13 hereof; and a payment bond or other security, all in form and amount satisfactory to Landlord. Tenant shall be responsible for insuring that all such persons procure and maintain insurance coverage against such risks, in such amounts and with such companies as Landlord may reasonably require. All Alterations shall be constructed in a good and workmanlike manner using Building standard materials or other new materials of equal or greater quality. Landlord, to the extent reasonably necessary to avoid any disruption to the tenants and occupants of the Building, shall have the right to designate the time when any Alterations may be performed and to otherwise designate reasonable rules, regulations and procedures for the performance of work in the Building. Upon completion of the Alterations, Tenant shall deliver to Landlord “as-built” plans, contractor’s affidavits and full and final waivers of lien and receipted bills covering all labor and materials. All Alterations shall comply with the insurance requirements and with applicable codes, ordinances, laws and regulations. Tenant shall reimburse Landlord upon demand for all reasonable sums, if any, expended by Landlord for third party examination of the architectural, mechanical, electrical and plumbing plans for any Alterations. In addition, if Landlord so requests, Landlord shall be entitled to oversee the construction of any Alterations, and in such event, Tenant shall reimburse Landlord for Landlord’s actual out of pocket costs incurred in connection therewith, which may include the cost of management personnel working outside of Normal Business Hours. Landlord’s approval of Tenant’s plans and specifications for any Alterations performed for or on behalf of Tenant shall not be deemed to be representation by Landlord that such plans and specifications comply with applicable insurance requirements, building codes, ordinances, laws or, regulations or that the Alterations constructed in accordance with such plans and specifications will be adequate for Tenant’s use.
Tenant’s Maintenance A. Tenant shall at its own cost and expense keep and maintain all parts of the Premises (except those for which Landlord is expressly responsible under the terms of this Lease) in good condition, promptly making all necessary repairs and replacements, including but not limited to, windows, glass and plate glass, doors, any special office entry, interior walls and finish work, floor and floor covering, downspouts, gutters, heating and air-conditioning systems, dock boards, truck doors, dock bumpers, paving, plumbing work and fixtures, termite and pest extermination, regular removal of trash and debris, keeping the parking areas, driveways, alleys and the whole of the Premises in a clean and sanitary condition. Tenant shall not be obligated to repair any damage caused by fire, tornado, or other casualty covered by the insurance to be maintained by Landlord pursuant to subparagraph 13(a) below, except that Tenant shall be obligated to repair all wind damage to glass except with respect to tornado or hurricane damage. (See Addendum to Paragraph 5A).
B. Tenant shall not damage any demising wall or disturb the integrity and support provided by any demising wall and shall, at its sole cost and expense, promptly repair any damage or injury to any demising wall caused by Tenant or its employees, agents, licensees or invitees.
C. Tenant and its employees, customers and licensees shall have the exclusive right to use the parking areas as shown on the attached Exhibit ”A,” subject to such reasonable rules and regulations as Landlord may from time to time prescribe and subject to rights of ingress and egress of other tenants. Landlord shall not be responsible for enforcing Tenant’s exclusive parking rights against any third parties.
D. Tenant shall, at its own cost and expense, enter into a regularly scheduled preventive maintenance/service contract with a maintenance contractor for servicing all heating and air-conditioning systems and equipment within the Xxxxxx/nnnlease rev. 7/92 T DBS/L JCC
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter:
a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications).
b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows:
(i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and
(ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, Xxxxxxxxx XxxXxxx of Xxxxx Xxxx LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises.
c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
TENANT’S MAINTENANCE AND REPAIR Tenant at its sole expense shall comply with all applicable laws and governmental regulations governing the Premises and make all repairs necessary to keep the Premises in the condition as existed on the Commencement Date (or on any later date that the improvements may have been installed), excepting ordinary wear and tear, including without limitation the electrical and mechanical systems, any air conditioning, ventilating or heating equipment which serves the Premises, all walls, glass, windows, doors, door closures, hardware, fixtures, electrical, plumbing, fire extinguisher equipment and other equipment. Any damage or deterioration of the Premises shall not be deemed ordinary wear and tear if the same could have been prevented by good maintenance practices by Tenant. As part of its maintenance obligations hereunder, Tenant shall, at Landlord’s request, provide Landlord with copies of all maintenance schedules, reports and notices prepared by, for or on behalf of Tenant. Tenant shall obtain preventive maintenance contracts from a licensed heating and air conditioning contractor to provide for regular inspection and maintenance of the heating, ventilating and air conditioning systems servicing the Premises, all subject to Landlord’s approval. All repairs shall be at least equal in quality to the original work, shall be made only by a licensed contractor approved in writing in advance by Landlord (which approval shall not be unreasonably withheld), and shall be made only at the time or times approved by Landlord. Any contractor utilized by Tenant shall be subject to Landlord’s standard requirements for contractors, as modified from time to time. Landlord shall have the right at all times (upon at least 24 hours’ prior notice) to inspect Tenant’s maintenance of all equipment (including without limitation air conditioning, ventilating and heating equipment), and may impose reasonable restrictions and requirements with respect to repairs, as provided in Section 7.3, and the provisions of Section 7.4 shall apply to all repairs. Alternatively, Landlord may elect to make any repair or maintenance required hereunder on behalf of Tenant and at Tenant’s expense, and Tenant shall promptly reimburse Landlord for all costs incurred upon submission of an invoice. Notwithstanding anything to the contrary contained in this Section 7.1, in the event Tenant’s obligation for compliance with all applicable laws and governmental regulations, or making repairs, results in a capital improvement on Tenant’s part (or Tenant’s being obligated to reimburse Landlord for a capital improvement), Tenant shall only be responsible for the amortized cost of such capital improvement (amortized at a market cost of funds as reasonably determined by Landlord) over the useful life of such improvements during the Term (except in the event obligation for any such capital improvement is required due to Tenant’s particular use of the Premises, in which case Tenant shall be fully responsible for the entire cost and installation of such capital improvement).
Exterior Signage Subject to Landlord’s prior written approval, which shall not be unreasonably withheld, conditioned or delayed, and provided all signs are in keeping with the quality, design and style of the Building and Project, Tenant, at its sole cost and expense, may install (i) identification signage on the existing monument sign located on the exterior of the Building, (ii) at the entrance to the Building and (iii) internal directional and lobby identification signage (collectively, “Tenant Signage”); provided, however, in no event shall Tenant’s Signage include an “Objectionable Name,” as that term is defined in Section 23.3, of this Lease. All such signage shall be subject to Tenant’s obtaining all required governmental approvals. All permitted signs shall be maintained by Tenant at its expense in a first-class and safe condition and appearance. Upon the expiration or earlier termination of this Lease, Tenant shall remove all of its signs at Tenant’s sole cost and expense. The graphics, materials, color, design, lettering, lighting, size, illumination, specifications and exact location of Tenant’s Signage (collectively, the “Sign Specifications”) shall be subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed, and shall be consistent and compatible with the quality and nature of the Project. Tenant hereby acknowledges that, notwithstanding Landlord’s approval of Tenant’s Signage, Landlord has made no representation or warranty to Tenant with respect to the probability of obtaining all necessary governmental approvals and permits for Tenant’s Signage. In the event Tenant does not receive the necessary governmental approvals and permits for Tenant’s Signage, Tenant’s and Landlord’s rights and obligations under the remaining TCCs of this Lease shall be unaffected. Except as required by applicable law, Landlord shall not install any other signage on the Building. If Landlord elects to install a multi-tenant identification sign at the entrance to the Project, Tenant shall be entitled to install its name on such sign (subject to availability on a pro-rata basis based on the relative square footages leased by the tenants of the Project), at Tenant’s sole cost and expense.